                ARMED SERVICES BOARD OF CONTRACT APPEALS

Appeals of --                              )
                                           )
CCIE & Co.                                 )      ASBCA Nos. 58355, 59008
                                           )
Under Contract No. W91GFC-08-M-S012        )

APPEARANCE FOR THE APPELLANT:                     Mr. Alie Sufan
                                                   Owner

APPEARANCES FOR THE GOVERNMENT:                   Raymond M. Saunders, Esq.
                                                   Army Chief Trial Attorney
                                                  CPT Vera A. Strebel, JA
                                                  Erica S. Beardsley, Esq.
                                                   Trial Attorneys

            OPINION BY ADMINISTRATIVE JUDGE MELNICK
 ON THE GOVERNMENT'S MOTIONS TO DISMISS FOR LACK OF JURISDICTION

        In these appeals, CCIE & Co. (CCIE) seeks payment of $3,000 for five months of
refrigerator maintenance services. The government moves to dismiss the appeals for lack
of jurisdiction.

     STATEMENT OF FACTS (SOF) FOR THE PURPOSES OF THE MOTIONS

        1. On 28 June 2008, CCIE and the Joint Contracting Command - Iraq entered into
Contract No. W91GFC-08-M-S012. Under the contract, CCIE was required to deliver
one refrigeration container to the governance center at Saab Al Bor, Iraq and a second
refrigeration container to COP (Combat Outpost) Bassam, Iraq, at a price of $20,000
each. CCIE was also required to provide maintenance of the refrigeration containers for
12 months at a price of $600 per month. The total value of the contract was $47,200.
(R4, tab 1)

       2. The contract incorporated by reference Federal Acquisition Regulation (FAR)
52.212-4, CONTRACT TERMS AND CONDITIONS-COMMERCIAL ITEMS (FEB 2007) (R4,
tab 1 at 1of15). Subparagraph (i)(l) of FAR 52.212-4 provided that payment would be
made for items accepted by the government. Paragraph (d) of FAR 52.212-4 stated that
the contract was subject to the Contract Disputes Act of 1978 (CDA), as amended.

       3. Under the contract's invoicing procedures, CCIE was to prepare and submit
invoices to the contracting officer (CO) for work performed. The CO's representative
was then responsible for preparing and submitting a DD Form 250, Material Inspection
and Receiving Report, to the contracting office. The contract required the government to
pay an invoice within 30 days after receipt of the invoice and DD Form 250. (R4, tab 1
at 4-5of15, 15of15)

       4. The record shows that CCIE delivered both required refrigeration containers,
which the government accepted on 19 July 2008. A payment voucher indicates that the
government paid CCIE $40,000 for the two refrigeration containers on 25 August 2008.
(R4, tab 5 at 1, 3)

        5. The Rule 4 file contains the DD Form 250s, invoices, and payment vouchers
for the monthly maintenance periods from 16 July 2008 through 14 December 2008 (R4,
tabs 6-9). The Rule 4 file also includes a DD Form 250 and an invoice for the monthly
maintenance period from 15 December 2008 through 14 January 2009 (R4, tab 10),
although no payment voucher for this period is in the record.

        6. The Rule 4 file includes a document titled "ODS Document History," dated
8 January 2013, which indicates that the government disbursed $43,600 under the
contract ($3,600 less than the award amount). The document suggests that the
government made its last payment on or about 12 May 2009. Attached to the ODS
Document History is an undated spreadsheet listing the invoices submitted under the
contract, and the amount invoiced. The spreadsheet also lists payment voucher numbers
corresponding to the $40,000 payment for the two refrigeration containers and for the
monthly maintenance service periods from 16 July 2008 through 14 January 2009,
indicating that the government paid CCIE for the delivery of the refrigeration containers
and the six monthly maintenance service periods ending 14 January 2009. The
spreadsheet also indicates that CCIE sought payment for the five monthly maintenance
service periods from 15 January 2009 through 14 March 2009 and 15 April 2009 through
27 June 2009 1 via a single invoice, Invoice No. 1116. 2 The spreadsheet, however, does
not contain a payment voucher number that corresponds to this invoice. The spreadsheet
also includes a note with regard to the period from 15 June through 27 June 2009 that
states, "[T]his is not a complete month. For the number of days it would be $240." (R4,
tab 11)

       7. By email dated 13 October 2012, appellant contacted the Board stating that it
had a claim regarding "[r]efrigerator service." Treating appellant's email as a notice of
appeal, the Board docketed the appeal as ASBCA No. 58355.

       8. Along with its 13 October 2012 notice of appeal, CCIE submitted a copy of
Invoice No. 2005CCIE-N01l16 dated 1July2009. The invoice sought $3,000 for five

1
  The 27 June 2009 date is listed in the spreadsheet as "6/2/-7/09," which we consider to
       be a typographical error.
2
  We conclude that this is a reference to Invoice No. 2005CCIE-N01l16 (see SOF ~ 8).

                                             2
monthly maintenance periods, from 15 January 2009 through 14 March 2009 and from
15 April 2009 through 27 June 2009. The invoice also sought $100,000 as a "Claim due
to the delay and ignoring Our mails and request for our payment." The $103,000 invoice
did not contain a certification in accordance with the CDA, 41 U.S.C. § 7103(b).

        9. CCIE also submitted copies of September 2009 email correspondences between
CCIE and government officials with its 13 October 2012 notice of appeal. In a
2 September 2009 email to appellant, the CO stated that he had recently taken over the
contract. The CO noted that appellant had complained of "having payment issues" on the
contract and asked appellant to provide copies of all invoices and DD Form 250s for the
contract, stating, "I will see what I can do to have them processed promptly." In a
13 September 2009 email to the CO, appellant stated that he had resubmitted the invoices
on 2 September. Appellant further stated that he had been told that a government official
had prepared the DD Form 250 and had provided it to the previous CO. Appellant
asserted its right to payments, claiming it was "suppose to have our payments since eight
months." By email to various government officials dated 21 September 2009, appellant
stated that he had sent many emails to the CO regarding payment but had received no
reply. In a 27 September 2009 email to the CO, appellant reasserted its entitlement to
payment, inquiring again as to when it would be paid.

       10. By email dated 8 January 2013, a contract specialist at the Rock Island
Contracting Center, Reachback Division, contacted CCIE stating that the government
was in the process of closing out the contract and requested confirmation that there were
"no outstanding claims, disputes or other contractual issues" (R4, tab 12). Appellant
responded by email dated 9 January 2013 stating that it still had an outstanding invoice
since 2009. Appellant further stated that it had "sent many mails and wait[ ed] for my
payments," but no one replied to its inquiries. Appellant attached a copy of Invoice
No. 2005CCIE-N01116, seeking payment of $103,000, and an electronic funds transfer
form to its response. (R4, tab 13) Although not in the government's Rule 4 file, 3
appellant also attached to its response copies of the September 2009 email
correspondences it had submitted with its 13 October 2012 notice of appeal (ASBCA
No. 58355, compl., attachs.).

       11. The government moved to dismiss ASBCA No. 58355 for lack of jurisdiction,
arguing that appellant had failed to submit a proper claim.




3
    Appellant copied the Board on its 9 January 2013 email response, which the Board
        acknowledged as appellant's complaint in ASBCA No. 58355.

                                             3
       12. Appellant responded to the government's motion by letter dated 20 April
2013, stating:

              I sent my invoices on monthly basis for my payments. Until
              the last invoice No2005CCIE-N01116 I sent several mails to
              [various government officials] asking for the situation for my
              payment,



              Since 2009, I kept sending mails for almost one year but no
              reply and nothing happened ....



              I still insist on my statement for my claim for the amount
              $103,000 ($3000 for my Balance payment [and] $100,000
              I claim for the delay)due to damages with delay for several
              years.

(58355, app. resp.)

       13. In a 24 May 2013 email to government counsel, with a copy to the Board,
appellant submitted a second letter dated 20 April 2013 in which it stated:

             I felt I was unfair with my claim. As you know and it is very
             clear I have outstanding Balance for the refrigerator service
             amount $3000 where I claimed for this amount since 2008. If
             you don't wish to consider my claim but at least I can accept
             to get paid my balance due Since five years.
             I appreciate your reply concerning my outstanding balance
             $3000.00[.]

We conclude that by this letter appellant has withdrawn the $100,000 "Claim due to the
delay and ignoring Our mails and request for our payment" (see SOF ~ 8) from ASBCA
No. 58355.

       14. In a 10 July 2013 Order, the Board noted that the issues raised in the
government's motion to dismiss ASBCA No. 58355 might be resolved, without a
decision on the motion, if appellant were to submit a claim to the CO meeting the
requirements of the CDA and file a new appeal should the claim be denied or deemed
denied by the government. The Board therefore directed appellant to indicate whether it
would attempt to submit a claim to the CO.


                                            4
       15. By email dated 13 July 2013, and in apparent response to the Board's Order,
appellant submitted multiple documents to government counsel and the Board including a
revised copy of Invoice No. 2005CCIE-N01l16. The revised invoice omitted the
$100,000 demand, was signed by appellant's representative, and included the following
statement: "The Claim is made in good faith; the Supporting Data are accurate and
complete." The revised invoice, however, remained dated 1 July 2009.

        16. By reply dated 29 August 2013, the government asserted that appellant's
 13 July 2013 response was not a valid claim and renewed its motion to dismiss for lack of
jurisdiction (58355, gov't reply).

       17. In a 9 October 2013 Order, the Board directed appellant, to the extent it
considered its 13 July 2013 submission to be a claim, to notify the Board whether it
intended to file a new appeal based upon the submission.

       18. In response, appellant submitted a letter dated 15 October 2013. The letter
repeated much of appellant's 20 April 2013 response to the government's motion to
dismiss ASBCA No. 58355 (see SOF ~ 12), but only "insist[ed] on my statement for my
claim for the amount $3,000" (ASBCA No. 59008, notice of appeal). The Board
determined that the letter was a notice of appeal, and docketed the matter as ASBCA
No. 59008.

       19. The government moved to dismiss ASBCA No. 59008 for lack of jurisdiction,
arguing that appellant's 15 October 2013 letter was not a valid claim (59008, gov't mot.).
Appellant did not respond to the government's motion despite two opportunities to do so.

                                       DECISION

       Appellant, as the proponent of the Board's jurisdiction, bears the burden of
establishing jurisdiction by a preponderance of the evidence. Hanley Indus., Inc.,
ASBCA No. 58198, 14-1BCA~35,500 at 174,015. The facts supportingjurisdiction are
subject to our fact-finding upon a review of the record. Raytheon Missile Sys., ASBCA
No. 58011, 13 BCA ~ 35,241 at 173,016; Green Dream Grp., ASBCA No. 57413 et al.,
12-2 BCA ~ 35,145 at 172,520.

        The Board's jurisdiction under the CDA is dependent upon the contractor's
submission of its claim to the CO and a final decision on, or the deemed denial of, the
claim. 41 U.S.C. §§ 7103-7105; Parsons Global Servs., Inc., ASBCA No. 56731, 11-1
BCA ~ 34,632 at 170,653, aff'd sub nom. Parsons Global Servs., Inc. ex rel. Odell Int'l,
Inc. v. McHugh, 677 F.3d 1166 (Fed. Cir. 2012). Because the CDA does not define the
term "claim," we look to the definition in the FAR. See, e.g., Taj Al Safa Co., ASBCA




                                            5
No. 58349, 13 BCA if 35,278 at 173, 156. The FAR defines a "Claim" as follows:

                      Claim means a written demand or written assertion by
              one of the contracting parties seeking, as a matter of right, the
              payment of money in a sum certain, the adjustment or
              interpretation of contract terms, or other relief arising under
              or relating to the contract .... A voucher, invoice, or other
              routine request for payment that is not in dispute when
              submitted is not a claim. The submission may be converted
              to a claim, by written notice to the contracting officer as
              provided in 33 .206( a), if it is disputed either as to liability or
              amount or is not acted upon in a reasonable time.

FAR 2.101. We determine whether a contractor's communication is a CDA claim on a
case-by-case basis and apply a common sense analysis. Todd Pac. Shipyards Corp.,
ASBCA No. 55126, 06-2 BCA if 33,421at165,687. In determining whether a claim has
been submitted, we may examine the totality of the correspondence between the parties.
Vibration and Sound Solutions Ltd., ASBCA No. 56240, 09-2 BCA if 34,257 at 169,270.

        Additionally, the CDA requires contractor claims in excess of $100,000 to be
certified. 41 U.S.C. § 7103(b). It is well settled that certification, when applicable, is a
jurisdictional prerequisite for this Board. Special Operative Grp., LLC, ASBCA
No. 57678, 11-2 BCA if 34,860 at 171,480. Although a defective certification does not
deprive the Board of jurisdiction, the complete absence of one where required does and
dictates dismissal. Dev. & Evolution Constr. Co., ASBCA No. 58342, 13 BCA if 35,453
at 173,859.

ASBCA No. 58355

       With its first notice of appeal, appellant submitted a copy of an invoice seeking
$103,000 for five months of refrigerator maintenance and delay in payment (SOF if 8). In
its motion to dismiss ASBCA No. 58355, the government asserts that "there is no record
that appellant ever submitted a claim prior to filing a notice of appeal or complaint with
the Board" (58355, gov't mot. at 2). The government argues that appellant's invoice was
merely a routine request for payment and not a proper CDA claim (id. at 3). The
government further argues that the Board lacks jurisdiction because the invoice sought
more than $100,000 but was not certified (id.).

       The government's apparent position is that ASBCA No. 58355 involves only a
single request in the amount of $103,000. We view appellant's invoice as presenting two
separate demands, one for $3,000 for payment allegedly due under the contract and a
separate demand for $100,000 for damages caused by delays communicating with
appellant and processing its payment request. Whether appellant is owed money for


                                               6
work allegedly performed under the contract involves a different set of operative facts
than whether appellant may recover for an alleged delay communicating with it.
Accordingly, we examine whether we have jurisdiction over each demand separately.
See Gov't Bus. Servs. Grp., LLC, ASBCA No. 53920, 03-1BCAii32,202 at 159,171
("To the extent that the dispute pertains to such discrete, independent 'operative facts,' it
will be treated as a separate claim ... ").

       Appellant's invoice, dated 1 July 2009, seeks $3,000 for monthly refrigerator
maintenance services for the periods from 15 January 2009 through 14 March 2009 and
from 15 April 2009 through 27 June 2009 (SOF ii 8). Initially, appellant's invoice was a
routine request for payment, not a claim. See Moshman Assocs., Inc., ASBCA
No. 52320, 00-1BCAii30,906 at 152,488; see also Reflectone, Inc. v. Dalton, 60 F.3d
1572, 1576 n.6 (Fed. Cir. 1995) (en bane) ("The distinction excluding routine requests for
payment from the definition of 'claim' relieves COs from the requirement of issuing a
CDA final decision on each and every voucher that the government is obligated to pay
under the express terms of the contract during its ordinary progression ... "). Such a
routine request for payment may be converted into a claim, however, by written notice to
the CO if it is disputed or not acted upon within a reasonable time. FAR 2.101.

        In a 2 September 2009 email, the CO acknowledged that appellant had contacted
the government regarding payment issues on the contract (SOF ii 9). As of that date, a
government document indicates that appellant had been paid for the monthly refrigeration
maintenance periods through 14 January 2009 (SOF ii 6), and only the amount sought in
the 1 July 2009 invoice remained pending. At the CO's request, appellant resubmitted its
invoices (SOF ii 9). Appellant subsequently contacted the CO regarding the payment of
its invoice on 13 September 2009, and 27 September 2009 (SOF ii 9). Through these
repeated queries seeking payment after the government's continued failure to pay its
invoice, CCIE converted its routine request for payment into a claim. See JWA Emadel
Enters., Inc., ASBCA No. 51016, 98-2 BCA ii 29 ,960 at 148,240, aff'g on re con. 98-2
BCA ii 29,765; Westinghouse Elec. Corp., ASBCA No. 25787, 85-1BCAii17,910 at
89,691, aff'd sub nom. Westinghouse Elec. Corp. v. United States, 782 F.2d 1017 (Fed.
Cir. 1986). Because the claim is less than $100,000, it did not need to be certified. Dev.
& Evolution Constr., 13 BCA ii 35,453 at 173,859 (certification "not necessary for claims
of $100,000 or less").

       The government suggests that appellant failed to convert its invoice into a valid
claim because it did not submit the DD Form 250s with it. The government cites no
authority requiring an invoice to be accompanied by a Material Inspection and Receiving
Report before it can be converted into a claim. Written notice to the CO is all that is
required to convert an invoice into a claim after it becomes disputed or is not timely acted
upon. FAR 2.101. The only authority cited by the government, Northeastern
Communication Concepts, Inc., ASBCA No. 39053, 91-2 BCA ii 24,042, is inapplicable.



                                              7
It merely holds that, when converted to a claim, a termination for convenience settlement
proposal requires an explanation of the basis for the requested amount.

       We need not decide whether appellant ever submitted a claim to the CO regarding
its $100,000 demand for damages due to delays in communicating and processing
payment. Appellant has withdrawn this portion of its appeal (SOF if 13), and we dismiss it.

ASBCA No. 59008

      The government seeks to dismiss ASBCA No. 59008 for lack of jurisdiction,
arguing that appellant's 15 October 2013 submission is not a claim because it was not
submitted to the CO (59008, gov't mot. at 3-4).

        We need not decide whether appellant's submissions to the Board and government
counsel during the course of litigation could constitute proper claims under the CDA.
Assuming that they can, any such claim would seek the same relief on the same basis as
the $3,000 claim over which we retain jurisdiction in ASBCA No. 58355. Accordingly,
we dismiss ASBCA No. 59008 as duplicative of ASBCA No. 58355. DayDanyon Corp.,
ASBCA No. 57611 et al., 14-1BCAif35,507 at 174,038; Thompson Aerospace, Inc.,
ASBCA Nos. 51548, 51904, 99-1BCAif30,232 at 149,570. The government's motion
is therefore denied as moot.

                                     CONCLUSION

       Appellant properly converted its $3,000 routine request for payment into a CDA
claim over which the Board retains jurisdiction in ASBCA No. 58355. Appellant has
withdrawn its $100,000 request due to delay communicating and processing payment
from ASBCA No. 58355, and the request is dismissed accordingly. ASBCA No. 59008
is dismissed as duplicative. The government's motions to dismiss for lack of jurisdiction
are denied.

      Dated: 12 August 2014


                                                ~~
                                                MARK A. MELNICK
                                                Administrative Judge
                                                Armed Services Board
                                                of Contract Appeals

(Signatures continued)




                                            8
I concur                                      I concur


                                               ~-r.~~
~~~
Administrative Judge
                                              MICHAEL T. PAUL
                                              Administrative Judge
Acting Chairman                               Acting Vice Chairman
Armed Services Board                          Armed Services Board
of Contract Appeals                           of Contract Appeals

     I certify that the foregoing is a true copy of the Opinion and Decision of the
Armed Services Board of Contract Appeals in ASBCA Nos. 58355, 59008, Appeals of
CCIE & Co., rendered in conformance with the Board's Charter.

      Dated:



                                              JEFFREY D. GARDIN
                                              Recorder, Armed Services
                                              Board of Contract Appeals




                                          9
