                                      2014 IL 115330



                                 IN THE
                            SUPREME COURT
                                   OF
                          THE STATE OF ILLINOIS



                                   (Docket No. 115330)

     GILLESPIE COMMUNITY UNIT SCHOOL DISTRICT NO. 7, Macoupin County,
              Illinois, Appellant, v. WIGHT & COMPANY, Appellee.


                              Opinion filed January 24, 2014.



        JUSTICE THOMAS delivered the judgment of the court, with opinion.

        Chief Justice Garman and Justices Freeman, Kilbride, Karmeier, Burke, and Theis
     concurred in the judgment and opinion.



                                         OPINION

¶1       Plaintiff, Gillespie Community Unit School District No. 7 (School District), filed
     suit against defendant, Wight & Company, alleging professional negligence, breach of
     implied warranty, and fraudulent misrepresentation by concealment of material fact,
     with respect to the building of an elementary school in Benld, Illinois.

¶2       Wight moved for summary judgment in its favor on all counts, arguing that the
     School District’s claims for professional negligence and for breach of implied warranty
     were barred by the four-year statute of limitations in section 13-214(a) of the Code of
     Civil Procedure (the Code) (735 ILCS 5/13-214(a) (West 2010)) and that the claim for
     fraudulent misrepresentation was barred by the five-year statute of limitations in
     section 13-205 (735 ILCS 5/13-205 (West 2010)) of the Code. The circuit court of
     Macoupin County agreed and granted Wight’s motion for summary judgment.
¶3       The Appellate Court, Fourth District, affirmed. 2012 IL App (4th) 111001-U.
     Relevant to the instant appeal, the appellate court held that the five-year statute of
     limitations in section 13-205 of the Code applied to the School District’s claim for
     fraudulent misrepresentation, so that the trial court properly found that the claim was
     barred by the statute of limitations.

¶4       Thereafter, this court allowed the School District’s petition for leave to appeal. Ill.
     S. Ct. R. 315 (eff. Feb. 26, 2010).



¶5                                        BACKGROUND

¶6       The School District’s complaint alleged that in 1998, the board of education of the
     School District decided to proceed with an investigation into the construction of a new
     elementary school. One possible site for the school was on School District property in
     Benld, Illinois, immediately adjacent to the existing elementary school. Wight and the
     School District entered into a contract, referred to as the “Pre-Referendum Service
     Agreement” (the Agreement), wherein Wight agreed to provide services preliminary to
     the actual designing and construction of the new school building. As part of the
     Agreement, Wight agreed to perform a “site mine investigation.” The Agreement
     specifically provided that:

            “The design team will investigate and examine the extent of mining in the
            Gillespie/Benld region. This investigation will result in an analysis of the
            proposed building site for suitability of construction and implications on
            proposed structural systems.”

¶7       Thereafter, as part of its site mine investigation, Wight hired Hanson Engineers,
     Inc., to conduct a study of the School District property in Benld to assess the potential
     for coal mine subsidence. On February 16, 1999, Charles Burgert, a physical engineer
     at Hanson, sent a letter to the attention of Mark Tucker of Wight. The letter was
     regarding the “Undermining Assessment for Gillespie School District Proposed
     Elementary School Benld, Illinois.” Burgert’s letter stated that it “describes the history
     and approximate extent of coal mining activity in the Benld/Gillespie area of Illinois,
     and also provides a general presentation regarding subsidence and its risk of
     occurrence.”

¶8      Burgert’s letter noted recorded subsidence events. The letter indicated that in 1934
     Quade performed an early mine subsidence investigation in the Benld/Gillespie area
                                            -2-
     and recorded numerous ground subsidence events, the locations of which were shown
     on an attachment to the letter, designated Figure 5. Four additional ground subsidence
     events were recorded in the Benld/Gillespie area between 1982 and 1998, and also
     were shown on Figure 5. The letter further noted that the Illinois Mine Subsidence
     Insurance Fund had recorded five to six subsidence events since 1979, affecting more
     than 40 structures in the Benld/Gillespie area, but indicated that the locations of those
     subsidence events were confidential for insurance purposes.

¶9      Under the heading “Risk of Subsidence,” Burgert wrote:

                “No one can predict when or if the land above the roof-and-pillar mine will
            subside. If any coal has been removed from the area, subsidence of the
            overlying geologic materials is always a possibility. Subsurface investigations
            undertaken to predict the possibility of future subsidence are always very
            expensive (especially at the depths of the Superior Mines) and are generally
            inconclusive. The owner should consider the fact that there is no economically
            feasible corrective action (such as filling the mine void) that can be taken to
            guarantee against future subsidence.

                Based on the number of ground subsidence events shown on Figure 5, it can
            be intuitively concluded that there is a relatively high risk of subsidence in the
            Benld/Gillespie area. At first glance, there appears to be an area around the
            proposed school location shown on Figure 5 where subsidence events have not
            occurred. However, the following points should be considered:

               (1) Figure 5 does not include every ground subsidence event that has
            occurred in the Benld/Gillespie area. There is a significant 40 to 50 year gap
            between the privately funded 1934 Quade study and the start of the recording of
            mine subsidence events by public agencies in the late 1970s and 1980s.
            Apparently, the recording of mine subsidence events during this intervening
            time period was not performed.

               (2) The Superior Mines No. 1 to No. 4 converge near the city of Benld.
            Therefore, the Benld area may have been the last mined out area before the coal
            mines were abandoned in the 1950s. Subsidence events in the Benld area could
            possibly be delayed in comparison to earlier mined out areas.

               The risk of future subsidence at the proposed school location should be
            evaluated along with other features of the site (such as the desirability of the

                                             -3-
              location) with the knowledge that it will not be possible to completely avoid
              similar risks in the area closely surrounding the city of Benld, Illinois.”

¶ 10       Hanson followed the letter with a Foundation Engineering Report (the Report) for
       the proposed elementary school in Benld, Illinois. The Report was prepared by Hanson
       for Wight, and was dated March 23, 2000. The introduction to the Report stated that it
       “presents the results of a subsurface investigation by Hanson Engineers Incorporated
       (HEI) for the proposed new elementary school that is to be constructed at the existing
       elementary school property in Benld, Illinois.”

¶ 11      The Report included a heading titled “Geology,” which stated, inter alia:

              “Our review of the available Illinois State Geological Survey maps of the
              mined-out coal areas in Illinois indicates that the site is undermined, and that
              there have been documented occurrences of ground surface subsidence due to
              collapse of abandoned coal mines within the town of Benld and the surrounding
              vicinity. Records indicate that the Superior Coal Company operated mines in
              the site vicinity from about 1900 to 1955.”

¶ 12      Under the heading, “Risk of Coal Mine Subsidence,” the Report stated:

                  “Due to the many unknown variables involved in predicting both the chance
              of subsidence and its possible magnitude, it is nearly impossible to quantify the
              risk involved in building on an undermined site. Surface investigations
              undertaken to predict the possibility of future subsurface are always very
              expensive and are generally inconclusive. The owner should consider the fact
              that there is no economically feasible corrective action that can be taken to
              guarantee against future subsidence.

                  The risk of future subsidence must be valued along with the other features
              of the site with the knowledge that it will not be possible to completely avoid
              similar risks in the area closely surrounding Benld, Illinois.”

¶ 13       The Report from Hanson to Wight did not include or attach a copy of Burgert’s
       February 16, 1999, letter, nor did it include or attach Figure 5 from that letter. Wight
       delivered the Report to the School District, but did not provide the School District with
       a copy of Burgert’s letter.

¶ 14       The School District decided to construct the new elementary school at the proposed
       site in Benld. The School District then retained Wight as the architect for the
                                               -4-
       construction phase of the school. The parties entered into a “Standard Form of
       Agreement Between Owner and Architect with Standard Form of Architect’s Services”
       (Standard Agreement), which is a document issued by the American Institute of
       Architects. Included in the Standard Agreement was Article 1.3.7.3, which provided:

                “Causes of action between the parties to this Agreement pertaining to acts or
                failures to act shall be deemed to have accrued and the applicable statutes of
                limitations shall commence to run not later than either the date of Substantial
                Completion for acts or failures to act occurring prior to Substantial Completion
                or the date of issuance of the final Certificate for Payment for acts or failures to
                act occurring after Substantial Completion. In no event shall such statutes of
                limitations commence to run any later than the date when the Architect’s
                services are substantially completed.”

¶ 15      “Substantial Completion” was defined as “the stage in the progress of the Work
       when the Work or designated portion thereof, such as the Work of a Phase of the
       Project, is sufficiently complete in accordance with the Contract Documents so that the
       Owner can occupy or utilize the Work for its intended use.”

¶ 16       The School District began occupying and using the school building in August 2002.
       Construction of the school building was completed in the fall of 2002. In March 2009, a
       coal mine subsided beneath the school building, causing extensive structural damage.
       Within a few weeks of the subsidence event, the Illinois State Board of Education
       determined that the damage was so severe that the building was condemned.

¶ 17       In August 2009, the School District filed a three-count complaint against Union
       Pacific Railroad Company and Wight. Counts II and III were directed against Wight,
       alleging professional negligence and breach of implied warranty, respectively.

¶ 18      On April 26, 2010, the School District filed an additional claim against Wight,
       count VI, for fraudulent misrepresentation by concealment of a material fact. 1 That

           1
             Count VI appears to allege both fraudulent misrepresentation and fraudulent concealment, which
       are two separate causes of action. See People ex rel. Skinner v. Graham, 170 Ill. App. 3d 417, 437 (1988)
       (“There is a distinct difference between alleging fraudulent concealment of a cause of action, which
       requires affirmative acts which are calculated to prevent the discovery of a cause of action [citation], and
       alleging fraudulent misrepresentation, which requires that a plaintiff reasonably rely upon intentional
       misrepresentation to his detriment. [Citation.]”). The parties and the lower courts, however, have
       proceeded as though count VI alleges only a cause of action for fraudulent misrepresentation, so we
       likewise will refer to count VI as a claim for fraudulent misrepresentation.

                                                        -5-
       claim alleged that the Report included some of the generalizations contained within
       Burgert’s letter, but excluded the specific and material information supporting the
       conclusion that there is a relatively high risk of subsidence in the Benld/Gillespie area.
       The School District alleged that: Wight either directed or allowed the Report to be
       presented to the School District without the specific and material information in
       Burgert’s letter concluding that there is a relatively high risk of subsidence in the
       Benld/Gillespie area, including the site for the proposed elementary school; Wight
       participated in causing or allowing the Report to be presented to the School District,
       even though Wight knew the Report concealed and failed to contain the specific and
       material information from the letter; and Wight’s concealment of the specific and
       material information occurred with the intent to induce a false belief for the School
       District concerning the likelihood of a subsidence event at the proposed new school
       location, under circumstances that created a duty for Wight to disclose the specific and
       material information set forth in the letter.

¶ 19       The School District further alleged that it could not have discovered the relatively
       high risk for subsidence in the Benld/Gillespie area, including the site for the proposed
       elementary school, through its own reasonable inquiry, and that it relied on the
       information provided by Wight in the Report. The School District would have acted
       differently with respect to the site of the elementary school had it been provided the
       specific and material information in Burgert’s letter.

¶ 20        Wight filed a motion to dismiss the claims against it pursuant to section 2-619(a)(5)
       of the Code (735 ILCS 5/2-619(a)(5) (West 2010)). Wight argued that pursuant to
       Article 1.3.7.3 of the Standard Agreement, the parties had agreed to replace the
       discovery rule with their own definition of “accrual,” so that the applicable statutes of
       limitation began running at the time of “Substantial Completion,” as defined in that
       paragraph. The date of substantial completion was 2002. Wight further argued that the
       four-year statute of limitations in section 13-214(a) of the Code applied to counts II and
       III, and that the five-year statute of limitations in section 13-205 applied to count VI,
       the claim for fraudulent misrepresentation by concealment of a material fact. Because
       more than six years had passed since the date of “Substantial Completion,” Wight
       contended that the School District’s claims were contractually barred. The trial court
       denied Wight’s motion to dismiss.

¶ 21      Wight later raised the same arguments in a motion for summary judgment. The trial
       court granted Wight’s motion for summary judgment. The trial court found that the
       work was substantially completed in the fall of 2002, therefore, the four-year statute of
                                               -6-
       limitations applicable to counts II and III had passed, as had the five-year statute of
       limitations applicable to count VI. The trial court thereafter denied the School
       District’s motion to reconsider, to vacate and for rehearing.

¶ 22       The appellate court affirmed. 2012 IL App (4th) 111001-U. On appeal, the School
       District had argued that the accrual provision was not part of the Pre-Referendum
       Service Agreement, that the accrual provision applied only to its agreement with the
       contractor, Bercol Construction, Inc., and not to its agreement with Wight, and that
       there was a material issue of fact concerning when substantial completion occurred.
       The appellate court resolved these issues in favor of Wight, and the School District
       does not challenge that portion of the appellate court’s order.

¶ 23       With regard to the instant appeal, the appellate court noted that although the School
       District did not dispute that the four-year statute of limitations in section 13-214(a) of
       the Code applied to counts II and III of the complaint, the School District did deny that
       the five-year statute of limitations in section 13-205 of the Code applied to its claim for
       fraudulent misrepresentation by concealment of a material fact. 2012 IL App (4th)
       111001-U, ¶ 66. The School District argued that no statute of limitations applied to its
       action for fraudulent misrepresentation. Id.

¶ 24        The appellate court rejected the School District’s argument. The appellate court
       observed that section 13-214(e) of the Code stated that the periods of limitation in
       section 13-214 are inapplicable to fraudulent misrepresentation. Therefore, by default,
       the five-year period of limitation in section 13-205 of the Code was the applicable
       statute of limitations. 2012 IL App (4th) 111001-U, ¶ 67. In support, the appellate court
       noted that in Rozny v. Marnul, 43 Ill. 2d 54, 69 (1969), the court held that the
       all-inclusive phrase “all civil actions not otherwise provided for” in section 13-205 had
       been construed to cover actions for fraud and deceit, and further held that it also
       encompassed actions for tortious misrepresentation. The appellate court therefore
       affirmed trial court’s order granting summary judgment in favor of Wight.

¶ 25       As noted, in this court, the School District appeals only that portion of the appellate
       court’s order finding that the School District’s fraudulent misrepresentation claim was
       barred by the five-year statute of limitations in section 13-205.




                                                -7-
¶ 26                                          ANALYSIS

¶ 27        Summary judgment is proper when “the pleadings, depositions, and admissions on
       file, together with the affidavits, if any, show that there is no genuine issue as to any
       material fact and that the moving party is entitled to a judgment as a matter of law.” 735
       ILCS 5/2-1005(c) (West 2010). This court’s review of an order granting summary
       judgment is de novo. Schultz v. Illinois Farmers Insurance Co., 237 Ill. 2d 391,
       399-400 (2010). Likewise, the School District’s claim concerning the statute of
       limitations in section 13-214(e) involves an issue of statutory construction, which also
       is reviewed de novo. Metropolitan Life Insurance Co. v. Hamer, 2013 IL 114234, ¶ 18.

¶ 28      At issue in this case are sections 13-214 and 13-205 of the Code. Section 13-214
       provides, in pertinent part:

              “Construction—Design management and supervision. As used in this Section
              ‘person’ means any individual, any business or legal entity, or any body politic.


                  (a) Actions based upon tort, contract or otherwise against any person for an
              act or omission of such person in the design, planning, supervision, observation
              or management of construction, or construction of an improvement to real
              property shall be commenced within 4 years from the time the person bringing
              an action, or his or her privity, knew or should reasonably have known of such
              act or omission. ***

                  (b) No action based upon tort, contract or otherwise may be brought against
              any person for an act or omission of such person in the design, planning,
              supervision, observation or management of construction, or construction of an
              improvement to real property after 10 years have elapsed from the time of such
              act or omission. However, any person who discovers such act or omission prior
              to expiration of 10 years from the time of such act or omission shall in no event
              have less than 4 years to bring an action as provided in subsection (a) of this
              Section. ***

                                                  ***

                  (e) The limitations of this Section shall not apply to causes of action arising
              out of fraudulent misrepresentations or to fraudulent concealment of causes of
              action.” 735 ILCS 5/13-214 (West 2010).

                                               -8-
¶ 29   Subsection (a) of the statute, then, is the limitations portion, while subsection (b) is the
       repose portion of the statute. Hernon v. E.W. Corrigan Construction Co., 149 Ill. 2d
       190, 194 (1992).

¶ 30      Section 13-205 provides:

              “Except as provided in Section 2-725 of the ‘Uniform Commercial Code’, ***
              and Section 11-13 of ‘The Illinois Public Aid Code’, *** actions on unwritten
              contracts, expressed or implied, or on awards of arbitration, or to recover
              damages for an injury done to property, real or personal, or to recover the
              possession of personal property or damages for the detention or conversion
              thereof, and all civil actions not otherwise provided for, shall be commenced
              within 5 years next after the cause of action accrued.” 735 ILCS 5/13-205
              (West 2010).

¶ 31       The School District argues that the lower courts erred in looking to section 13-205
       to determine the statute of limitations for its fraudulent misrepresentation cause of
       action. The School District maintains that section 13-214(e) is clear and unambiguous
       in providing that no statute of limitations applies to its claim for fraudulent
       misrepresentation. The School District points to the language in subsection (e) that
       “[t]he limitations of this Section shall not apply to causes of action arising out of
       fraudulent misrepresentations or to fraudulent concealment causes of action.”
       (Emphasis added.) The School District reads the phrase “shall not apply” to mean that
       no statute of limitations whatsoever shall apply to construction based fraudulent
       misrepresentation or fraudulent concealment causes of action. Therefore, the School
       District argues that the trial court erred in granting summary judgment in favor of
       Wight based upon section 13-205’s five-year statute of limitations, and that the
       appellate court erred in affirming that decision.

¶ 32       This court’s primary objective in construing a statute is to ascertain and give effect
       to the intent of the legislature. Barragan v. Casco Design Corp., 216 Ill. 2d 435, 441
       (2005). The best indication of legislative intent is the language used in the statute,
       which must be given its plain and ordinary meaning. Metropolitan Life, 2013 IL
       114234, ¶ 18. It is improper for a court to depart from the plain statutory language by
       reading into the statute exceptions, limitations, or conditions that conflict with the
       clearly expressed legislative intent. Metropolitan Life, 2013 IL 114234, ¶ 18. Words
       and phrases should not be viewed in isolation, but should be considered in light of other
       relevant provisions of the statute. Midstate Siding & Window Co. v. Rogers, 204 Ill. 2d

                                                -9-
       314, 320 (2003). Further, each word, clause and sentence of a statute must be given a
       reasonable construction, if possible, and should not be rendered superfluous. Prazen v.
       Shoop, 2013 IL 115035, ¶ 21. Where statutory language is clear and unambiguous, it
       will be given effect without resort to other aids of construction. Kunkel v. Walton, 179
       Ill. 2d 519, 534 (1997).

¶ 33       The School District contends that the use of the word “shall” in subsection (e)
       evinces the legislature’s clear prohibition against applying a statute of limitations to
       fraud-based construction claims. The School District argues that the use of the word
       “shall” was a mandatory directive and that the statutory language is clear and
       unambiguous, so that the appellate court was required to give effect to the statute as
       written and enacted.

¶ 34       We agree with the School District that the statutory language in section 13-214(e) is
       clear and unambiguous. However, we find that the School District’s reading of the
       statute is contrary to the plain language of the statute. As Wight points out, subsection
       (e) provides that “[t]he limitations of this Section shall not apply to causes of action
       arising out of fraudulent misrepresentations or to fraudulent concealment causes of
       action.” (Emphasis added.) “[T]his Section” means section 13-214. Consequently, the
       plain language of section 13-214(e) expressly states that the limitations of section
       13-214 do not apply to causes of action arising out of fraudulent misrepresentations or
       fraudulent concealment. The statute does not provide that no limitations shall apply to
       causes of action arising out of fraudulent misrepresentations or to fraudulent
       concealment. Because the limitations of section 13-214 do not apply to fraud-based
       construction claims, the appellate court properly followed Rozny and looked to section
       13-205 to determine the applicable statute of limitations.

¶ 35       The School District, however, maintains that the appellate court erred in relying on
       Rozny to find that section 13-205 set forth the proper statute of limitations for
       fraud-based construction claims. The School District argues that Rozny is inapposite
       because the case was decided prior to the enactment of section 13-214. The School
       District notes that at the time Rozny was decided, no other statute of limitations applied
       to fraud-based construction claims. Therefore, absent any other applicable statute of
       limitations, the Rozny court applied the predecessor to section 13-205 to the
       fraud-based construction claim at issue. The School District argues that the
       legislature’s subsequent enactment of section 13-214 reflected its intent that
       fraud-based construction claims are exempt from statutes of limitations and repose, so


                                               - 10 -
       there no longer is any need to look to section 13-205’s limitation period for such
       claims.

¶ 36       We disagree with the School District’s attempts to distinguish Rozny from this case.
       As discussed, section 13-214(e) does not eliminate any statute of limitations or repose
       for fraud-based construction claims. The subsection merely states that the limitations
       set forth in section 13-214 do not apply to causes of action arising out of fraudulent
       misrepresentations or to fraudulent concealment causes of action. Because those
       limitations do not apply to fraud-based construction claims, the appellate court
       correctly relied on Rozny to find that section 13-205 applied to the School District’s
       claim for fraudulent misrepresentation.

¶ 37       The School District next contends that the appellate court improperly read language
       into section 13-214(e). The School District claims that following the language in
       subsection (e) that “[t]he limitations of this Section shall not apply to causes of action
       arising out of fraudulent misrepresentations or to fraudulent concealment causes of
       action,” the appellate court effectively added language stating, “and the limitations
       provided for in Section 13-205 of this Act shall instead control.” The School District
       argues that such an interpretation is improper, as it is well settled that a court may not
       depart from the plain statutory language by reading into the statute exceptions,
       limitations, or conditions that conflict with the clearly expressed legislative intent.

¶ 38       The School District is correct that a court may not depart from the plain statutory
       language by reading into the statute exceptions, limitations, or conditions that conflict
       with the clearly expressed legislative intent. However, it is the School District, and not
       the appellate court, that is reading exceptions, limitations or conditions into section
       13-214 that conflict with clearly expressed legislative intent. The School District is
       reading language into section 13-214(e) completely eliminating any cause of action for
       fraud-based construction claims. Such a reading is contrary to the clear language of
       section 13-214(e), which simply and clearly states that the limitations of “this Section
       [13-214] shall not apply to causes of action arising out of fraudulent misrepresentations
       or to fraudulent concealment causes of action.”

¶ 39       Moreover, as Wight points out in response, when the legislature intends to exempt
       causes of action from a limitations period, the legislature has expressly stated its
       intention. Thus, section 3-5 of the Criminal Code of 1961 states: “[a] prosecution for
       *** first degree murder, attempt to commit first degree murder, second degree murder,
       involuntary manslaughter, reckless homicide, *** concealment of homicidal death,

                                               - 11 -
       treason, arson, aggravated arson, [or] forgery *** may be commenced at any time.”
       (Emphasis added.) 720 ILCS 5/3-5 (West 2010).

¶ 40       Similarly, section 13-202.1 of the Code is entitled “No limitations on certain
       actions—Duties of Department of Corrections and State’s Attorneys.” Section
       13-202.1 states:

                 “(a) Notwithstanding any other provision of law, any action for damages
              against a person, however the action may be designated, may be brought at any
              time if —

                  (1) the action is based upon conduct of a person which constituted the
              commission of first degree murder, a Class X felony, or a Class 1 felony as
              these terms are utilized at the time of filing of the action; and

                 (2) the person was convicted of the first degree murder, Class X felony, or
              Class 1 felony.” (Emphasis added.) 735 ILCS 5/13-202.1(a) (West 2010).

¶ 41       Here, in contrast, section 13-214(e) does not state that a fraud-based construction
       claim may be brought at any time. Section 13-214(e) simply excludes fraud-based
       construction claims from the statute of limitations and repose set forth in subsections
       (a) and (b) of the section 13-214.

¶ 42       The School District’s remaining statutory arguments also must fail, as those
       arguments are premised on the erroneous conclusion that no statute of limitations
       applies to fraudulent misrepresentations or to fraudulent concealment
       construction-based causes of action. The School District has argued that the appellate
       court’s decision is contrary to precedent holding that courts are to construe statutes so
       that the specific, section 13-214, prevails over the general, section 13-205; and that the
       most recent enactment, section 13-214, prevails over the earlier enactment, section
       13-205. As Wight points out, however, those statutory principles apply when statutes
       are in conflict. There is no need to apply those statutory principles in this case because
       sections 13-214 and 13-205 are not in conflict. Section 13-214 sets forth a statute of
       limitations and repose for construction claims, but specifically excepts fraud-based
       construction claims from that section. Fraud-based construction claims are instead
       governed by the statute of limitations set forth in section 13-205. Absent a conflict,
       there is no need to harmonize the two statutes.

¶ 43      The School District next claims that the appellate court’s decision in this case
       conflicts with decisions in Village of Fox Lake v. Aetna Casualty & Surety Co., 178 Ill.
                                               - 12 -
       App. 3d 887 (2d Dist. 1989), Continental Insurance Co. v. Walsh Construction Co. of
       Illinois, 171 Ill. App. 3d 135 (1st Dist. 1988), and Champaign County Nursing Home v.
       Petry Roofing, Inc., 117 Ill. App. 3d 76 (4th Dist. 1983). Those cases, however, are not
       in conflict with the instant case.

¶ 44       In Village of Fox Lake, the court considered whether the trial court properly held
       that the four-year statute of limitations in section 13-214(a) barred the plaintiff
       Village’s two fraud causes of action. Village of Fox Lake, 178 Ill. App. 3d at 912. The
       evidence showed that the Village was aware of the fraud as early as September 27,
       1976, and filed its fraud claims on June 22, 1983, and November 21, 1983. Id. The
       Village argued that the proper statute of limitations for the claim filed on June 22, 1983,
       was the five-year statute of limitations in section 13-205, while the proper statute of
       limitations for the fraud claim filed on November 21, 1983, was the 10-year statute of
       limitations on a written contract in section 13-206 of the Code, so that both claims were
       timely filed. Id.

¶ 45       The Village of Fox Lake court held that although section 13-214 was the proper
       statute to consider in determining whether the Village’s fraud claims were timely filed,
       the trial court erred in holding that those claims were time barred. Id. at 912-13. The
       appellate court relied upon section 13-214(e) in reaching its conclusion, holding that
       because the counts at issue “arose out of the alleged misrepresentation[ ]” by
       defendants, the trial court erred in holding that those counts were barred by the
       four-year statute of limitations set forth in section 13-214(a). Id. at 913.

¶ 46       The School District seizes upon the court’s statement in Village of Fox Lake that
       “the Village’s fraud counts were not barred by the statute of limitations.” Id. The
       School District, however, misinterprets this statement as meaning that the fraud counts
       were not barred by any statute of limitations. In fact, the court’s holding was that the
       fraud claims were not barred by the statute of limitations set forth in section 13-214(a).
       There was no need for the appellate court to expressly address the statutes of
       limitations set forth in sections 13-205 and 13-206 of the Code because the Village’s
       fraud claims were timely under those statutes of limitation. The decision in Village of
       Fox Lake, then, is entirely consistent with the appellate court’s opinion in this case.

¶ 47       The School District similarly takes language out of context in the Continental
       Insurance and Champaign County cases. At issue in Continental Insurance was
       whether the plaintiff’s claim against the defendants for negligent services provided in
       the engineering and construction of an underground sewer system was barred by the

                                               - 13 -
       then two-year statute of limitations in section 13-214(a), or the five-year statute of
       limitations in section 13-205. The court held that section 13-214(a) applied to the
       plaintiff’s complaint. Continental Insurance, 171 Ill. App. 3d at 137. In so holding, the
       court stated that “section 13-205, which plaintiff asserts governs its cause of action, has
       been held inapplicable to architects, engineers, and contractors after passage of section
       13-214.” Id. at 139. The court noted that “[s]ection 13-214(a) unambiguously states
       that it governs actions ‘based upon tort, contract or otherwise against any person for
       any act or omission by such person in the design, planning, supervision, observation or
       management of construction, or construction of an improvement to real property.’ ” Id.
       The court further observed that, pursuant to section 13-214(e), “[i]njured parties whose
       claims arise out of fraudulent misrepresentations or fraudulent concealment are not
       governed by the two-year statute of limitations.” Id.

¶ 48       Contrary to the School District’s interpretation, the Continental Insurance court did
       not hold that no statute of limitations applied to claims for fraud-based construction
       claims. Rather, the Continental Insurance court correctly noted that subsection (e)
       excluded fraud-based construction claims from the then two-year statute of limitations
       in subsection 13-214(a). Further, the Continental Insurance court did not have to
       address whether the section 13-205 statute of limitations applied to fraud-based
       construction claims, as the claim in the case before it was a claim for negligence, which
       is expressly included in section 13-214(a). Consequently, the Continental Insurance
       decision does not support the School District’s argument that no statute of limitations
       applies to fraud-based construction claims.

¶ 49       At issue in Champaign County was whether the holder of a claim pursuant to
       section 13-214, which would have been timely by virtue of a savings clause that was
       later repealed, was time barred when filed some months after repeal of the savings
       clause. Champaign County, 117 Ill. App. 3d at 77. In addressing the issue, the court
       noted that at the time the plaintiff discovered the damage at issue in July 1979, the
       relevant statutes of limitations were 5 years for actions premised on negligent damage
       to property, and 10 years for actions premised on a written contract. Id. at 78. However,
       on “November 29, 1979, a special statute of limitations relative to actions based on tort
       or contract and arising out of the negligent design, planning, construction, etc., of
       buildings became effective. This legislation prescribed a limitation period of two years
       from discovery of the relevant act or omission with a maximum limitation period of 12
       years from the date of the act or omission.” Id.



                                               - 14 -
¶ 50       The School District points to the preceding language in support of its claim that the
       appellate court in this case ignored section 13-214’s “special statute of limitations”
       status. That section 13-214 is a special statute of limitations for actions based on tort or
       contract or otherwise with regard to construction design, management and supervision,
       however, has no bearing on the instant case because section 13-214(e) specifically
       excludes fraud-based construction claims from its statute of limitations. Accordingly,
       the School District’s attempts to find a conflict between the instant case and the
       decision in Champaign County are unavailing.

¶ 51       Finally, the School District cites case law from other jurisdictions which note that
       contract provisions shortening the time to commence suit or eliminating the discovery
       rule for accrual of actions are not enforceable for claims premised on fraud. In citing
       these cases, the School District is not arguing that the accrual provision in the parties’
       Standard Agreement is unenforceable with regard to its fraudulent misrepresentation
       claim. 2 Rather, the School District argues that in enacting section 13-214, the Illinois
       legislature made a policy decision consistent with that recognized in those other
       jurisdictions: that with regard to fraud-based construction claims, periods of limitation
       and repose shall not apply.

¶ 52       Again we disagree with the School District’s argument. To begin with, whether
       parties to a contract can agree to shorten the time to commence suit or agree to
       eliminate the discovery rule for fraud-based causes of action is an entirely separate
       issue from, and has no bearing on, the issue of whether section 13-214(e) eliminates
       any statute of limitations or repose for a fraud-based construction claim. The answer to
       the latter issue is no. The plain, unambiguous language of section 13-214(e) states that
       the limitations of “this section”—section 13-214—“shall not apply to causes of action
       arising out of fraudulent misrepresentations or to fraudulent concealment of causes of

           2
             In fact, although the heading to this portion of the School District’s argument is titled “Cases
       Upholding Contractual Provisions Which Shorten a Statute of Limitations and/or Eliminate the
       Discovery Rule Do Not Apply to Fraud-Based Claims,” the argument following this heading is, “[w]ith
       the enactment of Section 13-214, the Illinois Legislature made a policy decision consistent with that
       recognized in other jurisdictions — at least with regard to fraud-based construction claims, periods of
       limitation and repose ‘shall not apply.’ ” Moreover, the School District’s argument in this section
       expressly disavows that it is arguing against application of the accrual provision to its fraudulent
       misrepresentation cause of action. The School District states, “[a]s a result [of the Illinois legislature’s
       policy decision to eliminate periods of limitation or repose], Illinois’ enforcement of
       construction-related contract provisions which shorten the applicable statute of limitations or eliminate
       the discovery rule is simply not relevant to the issue presented– whether statutes of limitation apply to
       fraud-based construction claims.”

                                                       - 15 -
       action.” Section 13-214(e) does not state that no statute of limitation or repose shall
       apply to a fraud-based construction cause of action. The lower courts, therefore,
       properly held that the five-year statute of limitations in section 13-205 applied to the
       School District’s claim for fraudulent misrepresentation by concealment of material
       fact. We therefore affirm the appellate court’s order in this case.

¶ 53       In so holding, we wish to emphasize that our decision in this case is based solely on
       the issue before us: whether the lower courts erred in holding that the five-year statute
       of limitations in section 13-205 applied to the School District’s fraudulent
       misrepresentation cause of action. As discussed, we find that the lower courts did not
       err in finding that the five-year statute of limitations in section 13-205, rather than no
       statute of limitations, applied to the School District’s fraudulent misrepresentation
       claim.

¶ 54       Section 13-205 provides that “all civil actions not otherwise provided for, shall be
       commenced within 5 years next after the cause of action accrued.” 735 ILCS 5/13-205
       (West 2010). Rozny held that a cause of action accrues when the plaintiff “knew or
       should have known of the defendant’s error.” However, pursuant to Article 1.3.7.3 of
       the Standard Agreement, the parties agreed that causes of action shall be deemed to
       have accrued, and the applicable statutes of limitations shall commence to run, upon
       substantial completion. The trial court, with the appellate court affirming, held that
       substantial completion occurred in the fall of 2002. The School District does not
       challenge that finding on appeal, and does not challenge application of Article 1.3.7.3
       to its fraudulent misrepresentation cause of action. Under the Standard Agreement,
       then, the fraudulent misrepresentation cause of action accrued in the fall of 2002, so
       that the claim filed in March 2010 was untimely, and Wight was entitled to summary
       judgment in its favor on that claim.

¶ 55       We again point out that the School District has not challenged the enforcement of
       the accrual provision set forth in Article 1.3.7.3 of the Standard Agreement to its
       fraudulent misrepresentation cause of action. The School District did raise the issue in
       response to Wight’s motion to dismiss, arguing that “Wight’s dismissal argument also
       fails given that courts in other states addressing the issue hold that contractual
       provisions that purportedly shorten the time to commence suit (such as Article 1.3.7.3)
       are unenforceable relating to claims premised upon fraud.” After citing case law from
       other jurisdictions, the School District stated, “[i]n short, Article 1.3.7.3 cannot be
       applied to the School District’s fraudulent misrepresentation claim.”


                                               - 16 -
¶ 56       However, following the trial court’s denial of Wight’s motion to dismiss, the
       School District thereafter abandoned the argument that Article 1.3.7.3 of the Standard
       Agreement could not be applied to the School District’s fraudulent misrepresentation
       claim. The argument was not raised in the School District’s response to Wight’s motion
       for summary judgment, was not raised in the School District’s motion to reconsider, to
       vacate and for rehearing, was not raised on appeal to the appellate court, and was not
       raised in the instant appeal. Following the denial of Wight’s motion to dismiss, the
       School District has argued only that there is no statute of limitations for fraud-based
       construction claims, so that its fraudulent misrepresentation claim was timely.

¶ 57       Therefore, in affirming the grant of summary judgment in favor of Wight, we are
       expressing no opinion concerning the extent to which accrual provisions such as that in
       Article 1.3.7.3 of the Standard Agreement may or may not be enforceable with regard
       to fraud-based claims, as that issue is not before us. Neither this court nor our appellate
       court has addressed whether a provision altering the normal rules governing the time
       for accrual applies to claims for fraudulent misrepresentation. We reiterate that our
       holding in this case is limited to a finding that the statute of limitations in section
       13-205 applies to a fraud-based construction claim.



¶ 58                                         CONCLUSION

¶ 59       For all of the foregoing reasons, we affirm the appellate court’s decision affirming
       the trial court’s order granting summary judgment in favor of Wight.



¶ 60      Affirmed.




                                               - 17 -
