[Cite as Stocker v. Cochran's Decorative Curbing, Inc., 2010-Ohio-1542.]
                            STATE OF OHIO, MAHONING COUNTY

                                   IN THE COURT OF APPEALS

                                        SEVENTH DISTRICT

KIMBERLY STOCKER,            )
                             )                             CASE NO. 09 MA 128
       PLAINTIFF-APPELLANT,  )
                             )
       - VS -                )                                      OPINION
                             )
COCHRAN'S DECORATIVE CURBING )
INC, et al.,                 )
                             )
       DEFENDANTS-APPELLEES. )


CHARACTER OF PROCEEDINGS:                                  Civil Appeal from Common Pleas
                                                           Court, Case No. 07 CV 1249.


JUDGMENT:                                                  Affirmed.


APPEARANCES:
For Plaintiff-Appellant:                                   Attorney Matthew Giannini
                                                           1040 South Commons Place
                                                           Suite 200
                                                           Youngstown, OH 44514

For Defendants-Appellees:                                  Attorney Dominic Frank
                                                           Betras, Maruca, Kopp & Harshman
                                                           16233 St. Clair Avenue
                                                           East Liverpool, OH 43920




JUDGES:
Hon. Mary DeGenaro
Hon. Joseph J. Vukovich
Hon. Gene Donofrio


                                                           Dated: March 30, 2010
DeGenaro, J.
        {¶1}     This timely appeal comes for consideration upon the record in the trial court
                                                                                       -2-


and the parties’ briefs. Appellant, Kimberly Stocker appeals the July 23, 2009 decision of
the Mahoning County Court of Common Pleas that dismissed Stocker's complaint and
entered judgment in favor of Appellee, Cochran's Decorative Curbing, et al. (CDC) on
their counterclaim for $4,343.00, subsequent to a bench trial before a magistrate. The
trial court adopted the magistrate's decision, which found that CDC had performed their
duties pursuant to the written contract between the parties, and that Stocker was required
to render payment pursuant to the contract.
         {¶2}   On appeal, Stocker argues that the trial court's decision was against the
manifest weight of the evidence because CDC did not complete their contractual duties
within a reasonable amount of time and did not perform their texturized spray concrete
application service in a workmanlike fashion.        Stocker additionally argues that the
magistrate erroneously refused to lift a prior discovery sanction and allow Stocker to
present expert testimony at trial, after the magistrate caused a continuance of the bench
trial.
         {¶3}   Upon review, Stocker’s assignments of error are meritless. The trial court's
finding of no unreasonable delay or unworkmanlike performance was not against the
manifest weight of the evidence and the discovery sanction issue is not reviewable based
on the record provided to this court. Accordingly, the trial court's decision is affirmed.
                              Facts and Procedural History
         {¶4}   On April 9, 2007, Stocker filed a complaint against CDC, claiming breach of
contract, breach of warranty and negligence. The complaint arose from a contract
between the parties for the application of texturized concrete on an apartment building
owned by Stocker. CDC filed a timely answer and counterclaim, alleging breach of
contract, fraud, misrepresentation and unjust enrichment.
         {¶5}   The trial court scheduled a mediation between the parties for March 24,
2008. The mediation resulted in an impasse, and the case continued for trial. On July
17, 2008, Stocker filed a motion to continue the July 23, 2008 trial, stating that she would
be out of state on a vacation. The trial court granted the motion and rescheduled the trial
for January 14, 2009. For reasons not reflected in the docket, the trial did not take place
in January.
                                                                                         -3-


       {¶6}   On February 2, 2009, Stocker filed a motion to permit plaintiff to submit
expert discovery information, accompanied by a list of exhibits and expert witnesses.
Stocker conceded that she had previously failed to comply with discovery requests and
deadlines, and explained that her failure to make discovery efforts was due to an
oversight and due to being away on vacation. Stocker argued that the additional time
now afforded to the parties, due to the continuance of the trial to April 13, 2009, alleviated
any potential prejudice to CDC by the belated discovery. The exhibits attached to
Stocker's motion included a printout of high and low temperatures from November 1,
2006 to November 12, 2006, as well as an undated price quote from a company identified
as "CVS" for the replacement of window screens and capping. The expert witnesses
were identified as Lew Golden and Ray Van Dusen from CVS.
       {¶7}   On March 3, 2009, CDC filed a response to Stocker's motion, arguing that
Stocker had not provided any legitimate reasons for her prior lack of compliance with
discovery. CDC alleged that between Stocker's April 9, 2007 complaint and the trial
previously scheduled for January 14, 2009, Stocker failed to respond to any of CDC's
repeated requests for disclosure of witnesses and discovery materials. CDC alleged that
all parties had appeared for the January 14, 2009 trial, and CDC objected to Stocker's
untimely attempt to introduce exhibits and witnesses not previously disclosed. CDC
alleged that the trial court concluded that Stocker would not be permitted to present
evidence or witnesses other than that which she disclosed at the March 20, 2008
mediation hearing. CDC alleged that they had consented to the trial court's proposed
continuance of the trial to April 13, 2009 based on the continued imposition of the
discovery sanction against Stocker. Finally, CDC pointed out that Stocker's expert list
only included the names of two window installers, and did not include any written report
from the proposed expert witnesses as required by the Mahoning County Civil Local
Rules of Court. On March 4, 2009, the trial court overruled Stocker's discovery motion.
       {¶8}   On April 13, 2009, a bench trial took place before the magistrate. Stocker
attempted to present the testimony of Lew Golden of CVS. CDC objected on the grounds
that the trial court had already prohibited the witness testimony in its March 4, 2009 ruling,
and the trial court sustained CDC's objection. Stocker was, however, permitted to
introduce the exhibit of daily temperatures included in her February 2 motion.
                                                                                        -4-


       {¶9}   Stocker testified that she was the owner of an apartment complex in
Struthers, Ohio, and had solicited CDC's services for decorative concrete work on the
apartment complex. Stocker testified that, before entering the contract, Stocker talked
with CDC about what services she wanted, including smoothing out areas in the block
work which were flawed or damaged, and giving the building a stucco-like appearance.
Stocker signed the contract on May 18, 2006, and Tara Cochran signed the contract on
June 1, 2006. Stocker submitted a faxed copy of the original estimate and proposed
contract signed by Dean Cochran of CDC, and stated that the contract consisted of one
page. The contract price was $8,685.00, with a requirement that half be paid before
performance. The contract indicated that the concrete application would be performed by
the end of August of 2006, but CDC did not perform the work until the beginning of
November of 2006.
       {¶10} Stocker called CDC repeatedly prior to November, asking them to complete
the work soon before it got too cold.        When the work was being completed, the
temperatures were in the forties or fifties during the day, but below freezing with snow
flurries at night. Prior to applying the concrete, CDC power washed the building and used
a chemical to remove excess debris. CDC performed the concrete work over two days,
and returned when Stocker complained that CDC had sprayed concrete on windows,
capping, sidewalks and plants.
       {¶11} Stocker submitted photographs that she had taken of her building shortly
after CDC's work had been completed. Stocker testified that various photos showed that
CDC had sprayed concrete on window screens and the capping around her windows and
doors, that CDC had not repaired mortar or filled in cracks prior to applying the spray
concrete, that the concrete was not applied evenly, and that color inconsistencies and
white patches had appeared in the concrete.              Stocker testified that the color
inconsistencies occurred because CDC had applied the material when it was too cold.
Stocker testified that CDC requested the remainder of the payment after the second day
of applying the concrete, and Stocker refused. CDC returned to repaint areas of trim on
the building affected by overspray. CDC also returned to apply additional concrete onto
certain areas after Stocker's complaint. Stocker testified that the additional application of
concrete was done poorly, leaving "big globs all over."
                                                                                        -5-


       {¶12} On cross-examination, Stocker denied that she had lost her original copy of
her contract with CDC, but stated that she had not brought the contract with her to trial.
CDC presented their copy of the contract, which consisted of two pages. Stocker denied
that there had been a second page on the contract that she had signed, though she
agreed that the front page of CDC's copy was identical to the faxed copy that she had
submitted. Stocker admitted that the contract did not state that CDC was to complete
repairs to cracks or block work prior to applying the spray concrete, and did not include
any "time is of the essence" term. Stocker explained that a delay in CDC's performance
was not a problem, but timing the performance during cold weather was a problem.
Stocker testified that CDC had informed her that the excessive rainfall over the summer
necessitated a delay in their performance.
       {¶13} Stocker testified that CDC did not put the concrete through a curing
process, and did not apply a sealant coat after applying the concrete. Stocker conceded
that the contract did not state anything about a sealant coat, but asserted that "it's just
common sense." Stocker had recently painted the trim around her windows prior to
CDC's work. Stocker testified that CDC failed to mask over the windows prior to applying
the concrete, though she admitted that she was not present during the first day of
application. Stocker stated that CDC's crew did not return to paint her trim, and that she
personally did it with the help of Tara Cochran of CDC. Stocker testified that CDC did not
return to power wash her window screens.
       {¶14} Stocker testified that after she complained about the first application, CDC
ordered additional materials and returned at the end of November to apply additional
concrete. Stocker was still not satisfied with CDC's work after they had returned to do
additional spraying as requested, and continued to refuse to render the second half of the
payment.
       {¶15} CDC offered the testimony of Ronald Dean Cochran. Cochran testified that
he and his wife, Tara Cochran, are the owners of CDC. CDC has performed concrete
work since 2001. Cochran has completed hundreds of spray coat concrete applications
before, though Stocker's building, along with a project for Bliss Hall at Youngstown State
University, were his first two instances of applying spray concrete onto vertical rather than
                                                                                     -6-


horizontal surfaces. Cochran could not recall if he completed the YSU job prior to
Stocker's building.
       {¶16} Cochran testified that before Stocker entered into a contract with CDC,
Cochran brought sample boards of the product to show Stocker the thickness of the
product. Cochran testified that Stocker's building had several different types of surfaces
and textures: some brick, some flat, and some very concaved block. Cochran testified
that he told Stocker prior to contracting that the spray concrete would not change the
surface texture of the building, and that Stocker's main concern was not having to paint
the building anymore.
       {¶17} When asked about the contract between CDC and Stocker, Cochran noted
that the installation date was set for the end of August. Cochran explained that the
August date on the contract was chosen in May as a tentative installation date. Cochran
noted that the back page of the contract indicates that the performance date can be
changed at any time. Cochran testified that CDC will not do work on any day with more
than a 40% chance of rain predicted. Cochran stated that 2006 was a very rainy year,
causing him to delay many jobs that were ahead of Stocker's, which in turn delayed his
performance on Stocker's building. Cochran talked with Stocker about pushing back the
date of performance, and Stocker did not cancel the contract or state that performance
needed to be completed immediately. Cochran testified that when he came to perform
the work on Stocker's building in November, Stocker did not tell him to leave or complain
about the cold weather and timing of the job.
       {¶18} Cochran testified that he began work on Stocker's building in October, and
that his final visit to Stocker's building was in December. In October, CDC first cleaned
Stocker's building with a pressure washer to remove any loose paint or debris, then
completes the stripping of debris with chemicals. CDC completed cleaning and stripping
in one and a half weeks.      Stocker sent pictures to CDC of the building prior to
performance of the job. The pictures provided did not show foliage or plants on the
ground around the building where CDC sprayed the concrete.
       {¶19} Cochran testified as to the various chemicals and minerals that a company
might mix into concrete to prevent freezing. Cochran stated that it was acceptable in his
trade to perform concrete work at any time of the year. Cochran testified that the
                                                                                       -7-


temperatures in November of 2006 were rather mild, in the forties through sixties during
the day and cooler at night. Cochran pointed out in a picture of the work during the
beginning of December that one of his crewmembers was wearing shorts. Cochran did
not add calcium or other materials to the concrete at issue to prevent freezing. Cochran
testified that the outside surface of concrete dries relatively quickly, and that curing the
concrete involves ensuring that the material hardens all the way through. Cochran
testified that the spray concrete is one sixteenth of an inch thick and dries very quickly,
and does not have the same freezing concerns as with laying a slab of concrete that is
four to six inches thick.
       {¶20} The trial court allowed one of Stocker's previously barred exhibits, and
Cochran testified from the exhibit that the nighttime temperatures during the contract
performance did reach freezing and that there was some snow. Cochran pointed out that
the temperatures in the exhibit were taken from an airport in Vienna, Ohio, not in
Struthers, and did not know if the airport was near Stocker's building. Cochran stated that
such temperatures would not affect the application of spray concrete, especially because
the concrete was applied during the day in fifty-degree weather, and dries quickly.
Cochran testified that sprayed concrete at one-sixteenth of an inch thick would dry in two
to three hours.
       {¶21} Stocker testified that he received training on the spray concrete in 2001, that
he attended approximately three additional training sessions afterwards, the most recent
of which was in the spring of 2006. Cochran was certified by the manufacturer upon
completing training. Cochran stated that, from his training and knowledge, the materials
for spray concrete are not affected by the cold, except for extreme temperatures such as
thirty degrees below zero. Cochran noted from his company's brochure about the product
that the optimum cure time for the product is 24 hours, with a minimum amount of four
hours. Cochran testified that he finished applying the concrete on Stocker's building at
approximately three or four o'clock in the afternoon. When asked about his training on
the spray concrete product, Cochran denied ever being told by the manufacturer that the
product should not be applied at temperatures below fifty degrees.
       {¶22} Cochran testified that CDC used shields to cover the windows of Stocker's
building while they were spraying the concrete. Cochran conceded that some material
                                                                                         -8-


got on the window screens. Cochran informed Stocker that they would have to spray
electrical wires and other items on the building, but did not specifically inform her that the
spray would get on the gutters and downspouts. Cochran did not use tarps to cover the
sidewalk or shrubs, though he stated that no spray concrete got onto the sidewalks, and
that there were no plants around the building where they had sprayed.
       {¶23} Cochran stated that he purchased part of the materials for Stocker's building
on August 21, 2006. Cochran testified that he used some materials he already had in
stock, and otherwise orders materials in advance and stores them so that they are
immediately available when he is ready to begin a particular job. Cochran testified that
when Stocker stated that she was dissatisfied and would not pay, Cochran asked what he
needed to do in order to satisfy her, then ordered the extra materials and completed the
extra work so that she would pay. Cochran ordered additional materials for Stocker's
building on November 9, 2006, in order to remedy the issues that Stocker had with
Cochran's performance. CDC performed a total of approximately two weeks of work on
the project for Stocker's building.
       {¶24} According to Cochran, Stocker stated that she would pay CDC if they used
more material with a rougher texture, which CDC did when they returned to spray a
second application. When CDC completed additional work in order to satisfy Stocker,
they spent an additional $368.92 for materials, and additional money for shipping and for
labor performed by employees. Cochran used additional coarse sand in his second
application of the product in order to get the rougher texture that Stocker said she
wanted. When Stocker complained about the overspray, Cochran removed every one of
the window screens, power washed them, cleaned all of the cappings around the
windows, and repainted even though he had advised Stocker not to paint them before the
application of the concrete.
       {¶25} Cochran came to Stocker's building and took pictures of the job during the
spring of 2007. Cochran did not think that the color of the concrete had faded, and did
not see any white film on the concrete.
       {¶26} Stocker returned for rebuttal testimony, and stated that there were still
particles of concrete in the window screens. Stocker conceded that her shrubs did not
end up getting damaged by the overspray of concrete. Stocker testified that there is still
                                                                                     -9-


concrete on the stoop to the front apartment, and on the building's downspouts. Stocker
testified that she did not take photographs of the screens or sidewalks as they exist now.
       {¶27} Both parties submitted proposed findings of fact and conclusions of law, and
on June 15, 2009, the magistrate issued his decision. The magistrate found that the
contract stated that the work was to be performed at the end of August, and that the
contract contained a term that CDC could change the installation date at any time The
magistrate found that Stocker did not prove that CDC had performed its spray concrete
application in an unworkmanlike fashion. The magistrate found that CDC performed work
beyond the contractual obligation by applying additional concrete product to the building,
power washing the windows, and painting all of the trim on the building. However,
because the additional work was not set forth in the contract, CDC was not entitled to
payment from Stocker for the additional work. The magistrate concluded that CDC was
entitled to the remainder of the contract price, plus interest and costs, and dismissed
Stocker's complaint.
       {¶28} On June 29, 2009, Stocker filed objections to the magistrate's decision,
specifically objecting to the magistrate's finding that Stocker's testimony regarding the
unreasonable performance by CDC was merely "self-serving." Stocker objected to the
finding that Stocker had failed to provide any proof of monetary damages outside of the
contract price, arguing that she should have been permitted to supply the previously
requested additional discovery. On July 23, 2009, the trial court filed a judgment entry,
finding no error of law or fact in the magistrate's decision, adopting the decision of the
magistrate, dismissing Stocker's complaint, and entering judgment on CDC's
counterclaim for $4,343.00 plus interest and costs.
                                     Manifest Weight
       {¶29} In the first of two assignments of error, Stocker asserts:
       {¶30} "The decision of the trial court is against the manifest weight of the
evidence."
       {¶31} As a preliminary matter, CDC did not file an appellate brief. Accordingly, we
may consider Stocker’s statement of the facts and issues as correct and reverse the
judgment if Stocker’s brief reasonably appears to sustain such action. App.R. 18(C).
                                                                                        - 10 -


       {¶32} Stocker argues that CDC's delayed performance constituted a breach of
contract, and that CDC further breached the contract by applying the concrete in a
careless and unworkmanlike fashion.
       {¶33} To succeed in an action for breach of contract, a plaintiff must prove by a
preponderance of the evidence that a contract existed, that the plaintiff fulfilled her
obligations under the contract, that the defendant failed to fulfill his obligations under the
contract and that damages resulted from his failure. John Snyder, Inc. v. Cooper, 7th
Dist. No. 99 JE 45, 2001-Ohio-3215. The determination of whether a party has materially
breached a contract is generally a question of fact. Creative Concrete v. D&G Pools, 7th
Dist No. 07 MA 163, 2008-Ohio-3338, at ¶20, citing Kersh v. Montgomery Developmental
Ctr. (1987), 35 Ohio App.3d 61, 63, 519 N.E.2d 665.
       {¶34} A trial court's decision on a question of fact should be reversed only if it is
against the manifest weight of the evidence. Seasons Coal Co., Inc. v. Cleveland (1984),
10 Ohio St.3d 77, 10 OBR 408, 461 N.E.2d 1273. Pursuant to a civil manifest weight of
the evidence standard of review, a reviewing court should defer to the judgment of the
trial court in factual determinations, and "[j]udgments supported by some competent,
credible evidence going to all the essential elements of the case will not be reversed by a
reviewing court." Creative Concrete at ¶17, quoting C.E. Morris v. Foley Construction Co.
(1978) 54 Ohio St.2d 279, 8 O.O.3d 261, 376 N.E.2d 578. A reviewing court should
make all reasonable presumptions in favor of the trial court's judgment and findings of
fact. Karches v. City of Cincinnati (1988), 38 Ohio St.3d 12, 19, 526 N.E.2d 1350.
       {¶35} Stocker contends that the manifest weight of the evidence indicated that
CDC was at fault for untimely performance and poor workmanship. Stocker's arguments
evoke two different areas of contract law: breach of contract for failure to perform within a
reasonable time, and breach of the implied warranty of performance in a workmanlike
manner.
       {¶36} Regarding timeliness of performance, the contract between Stocker and
CDC indicated that the time of performance was to be August of 2009, but an additional
term of the contract noted that CDC could delay the date of performance at any time.
Because the terms of the contract allowed for a possible indefinite time of performance,
we generally presume that the contract was to be performed within a reasonable time.
                                                                                   - 11 -


Rock v. Monarch Bldg. Co. (1912), 87 Ohio St. 244, 252, 100 N.E. 887. An unreasonable
delay in performance may constitute a material breach of the contract. See Morton
Bldgs., Inc. v. Correct Custom Drywall, Inc., 10th Dist. No. 06AP-851, 2007-Ohio-2788, at
¶16, citing 23 Williston, Contracts (4 Ed.2000) 487-488, Section 63:18. To determine
whether a party has breached a contract through unreasonable delay, the trier of fact
must consider the circumstances contemplated by the parties at the time the contract was
executed, and the circumstances surrounding performance. Catz Ent., Inc. v. Valdes, 7th
Dist. Nos. 07 MA 201, 07 MA 202, 08 MA 68, 2009-Ohio-4962, at ¶38.
      {¶37} The parties entered into the contract at the end of May 2006, with an initial
indication that CDC would perform services at the end of August of 2006. The contract
indicated that CDC could change the date of performance at any time, and the contract
did not contain any "time is of the essence" clause. According to Cochran's testimony,
the excessive rain during 2006, especially the summer of 2006, caused his company to
fall behind schedule. Cochran's testimony demonstrated that his business and the speed
of his performance on any job was dependant on the weather, and rainy conditions could
not be predicted at the time of contract formation for any particular job. For the job in
question, CDC was able to perform three months later, in November of 2006. The
foregoing presents some competent credible evidence to support the trial court's
conclusion that CDC's delay in performance did not constitute a material breach.
      {¶38} Moreover, Stocker did not provide any proof that she suffered damages as a
result of a delay in CDC's performance, such as a postponement of her ability to house
tenants, for example. Instead, Stocker conceded during her testimony that the timing,
rather than the timeliness, was at issue. Because the timing of CDC's performance was
during colder months, Stocker indicates that such timing contributed to the discoloration
of the concrete and thus the poor quality of CDC's performance. Had CDC further
delayed their performance and not installed the concrete until the warmer months of the
following year, the evidence does not indicate that there would have been a problem.
Thus Stocker's argument on this point falls less under an untimely performance
argument, and more a factor in analyzing the warranty that a service will be performed in
a workmanlike fashion.
                                                                                         - 12 -


       {¶39} As for Stocker's second argument, the obligation to perform a service in a
workmanlike fashion is an implied duty imposed by law. John Snyder, Inc., supra, citing
Velotta v. Leo Petronzio Landscaping, Inc. (1982), 69 Ohio St.2d 376, 378-379, 23
O.O.3d 346, 433 N.E.2d 147. In order to succeed on this kind of breach of warranty
claim, a plaintiff must prove lack of ordinary care and skill, or negligence. Velotta at 378.
An analysis of this claim requires the trial court to determine issues of fact as to whether
the breaching party demonstrated workmanlike skill and judgment. John Snyder, Inc.,
citing Mitchem v. Johnson (1966), 7 Ohio St.2d 66, 73, 36 O.O.2d 52, 218 N.E.2d 594.
When a trial court's decision on this factual issue turns on an assessment of credibility,
this court should not overturn the decision if there is any competent credible evidence
supporting the trial court's decision. C.E. Morris, supra.
       {¶40} Stocker largely failed to raise specific facts demonstrating that CDC
breached any duty under law or contract. As for the alleged discoloration of the sprayed
concrete, Stocker's photograph exhibits did indicate that there was some color variation in
the concrete.    However, the contract between the parties indicated "CDC is not
responsible for slight color variations from the color charts. Concrete inherently cures at
different rates and this affects the final coloring of the product." Stocker indicated that the
air temperature fell to a certain level during CDC's performance, but provided no proof to
support her claim that the application of concrete was inadvisable during such
temperatures, or proof that lower temperatures caused the discoloration. Additionally,
although Stocker's testimony indicated that the degree of discoloration was unreasonable,
Cochran's testimony indicated otherwise, and the trial court found Cochran to be the more
credible witness.
       {¶41} As for the overspray, Stocker did not provide proof to support her
assumption that the exercise of workmanlike skill and judgment would result in absolutely
no overspray of the concrete product. Moreover, CDC indicated that they took remedial
measures regarding the overspray, including cleaning and repainting, even after advising
Stocker not to paint prior to the concrete work.          Stocker's picture exhibits, dated
November 27, 2006, reflect the state of her building prior to CDC's remedial efforts, and
Stocker did not present any evidence of the condition or appearance of the building
subsequent to CDC's final work. Stocker conceded during her testimony that the
                                                                                     - 13 -


overspray did not damage her landscaping. The parties disagreed as to whether any
product landed on the sidewalks around Stocker's building, and the trial court presumably
chose to believe Cochran's testimony.
       {¶42} The magistrate's findings included the finding that Cochran advised Stocker
not to paint the trim on her building prior to the application of the spray concrete, that
Cochran was certified by the spray concrete manufacturer to apply the product, that
Stocker's claims of unworkmanlike performance were unsupported, and that Cochran
exceeded his contractual duties to remedy Stocker's possibly unsupported complaint of
unworkmanlike performance. We are guided by the presumption that the trial court's
factual findings are correct, and the testimony and exhibits provided constitute some
competent credible evidence supporting the magistrate's findings and the trial court's
decision. Accordingly, Stocker's first assignment of error is meritless.
                                Discovery Violation
       {¶43} In her second assignment of error, Stocker asserts:
       {¶44} "The trial court erred when, having continued the trial for an extended period
due to the unavailability of a courtroom, the magistrate denied plaintiff's contemporary
request to allow expert testimony and evidence of damages on the new trial date, which it
had previously denied because of her untimely response to defendant's discovery prior to
the January trial date."
       {¶45} Stocker contends that the court abused its discretion by refusing to lift a
prior discovery sanction, barring Stocker from presenting expert witness testimony, after
the trial court continued the trial for three months.
       {¶46} Trial courts have broad discretion over discovery matters. State ex rel.
Citizens for Open, Responsive & Accountable Govt. v. Register, 116 Ohio St.3d 88, 2007-
Ohio-5542, 876 N.E.2d 913, at ¶18. A trial court’s decision regarding a motion regarding
untimely discovery, or a motion to extend the time for discovery, is reviewed for an abuse
of discretion. See Harvey v. Republic Servs. Of Ohio II, L.L.C., 5th Dist. No. 2007 CA
00278, 2009-Ohio-1343, at ¶83. Further, a trial court has the discretion to exclude the
presentation of an expert witness by a party who failed to comply with pretrial orders.
Scibelli v. Pannunzio, 7th Dist. No. 05 MA 150, 2006-Ohio-5652, at ¶36; Kolidakis v.
Glenn McClendon Trucking Co., 7th Dist. No. 03 MA 64, 2004-Ohio-3638, at ¶23; Civ.R.
                                                                                        - 14 -


26; Civ.R. 37. “[C]hoices involving discovery sanctions are upheld unless the result is ‘so
palpably and grossly violative of fact or logic that it evidences not the exercise of will but
the perversity of will, not the exercise of judgment but the defiance of judgment, not the
exercise of reason but instead passion or bias.’” Scibelli at ¶35, quoting Nakoff v. Fairview
Gen. Hosp., 75 Ohio St.3d 254, 256, 1996-Ohio-159, 662 N.E.2d 1.
       {¶47} The record on this particular issue is extremely limited. Stocker’s argument
on appeal, as well as her February 2, 2009 motion and CDC’s March 3, 2009 response,
all reference a discovery sanction placed on Stocker by the magistrate. However, the
record before this court does not reflect when such a sanction occurred, the exact
circumstances giving rise to the sanction, the reasons used by the magistrate to impose
the sanction, or the extent of the sanction that the magistrate imposed on Stocker. This
court could infer from the parties’ references that the discovery sanction was imposed
when the parties appeared before the magistrate with the intent to proceed to trial on
January 14, 2009. However, there is no transcript submitted in the record of the parties’
discussions with the magistrate on that date, and no statement or supplement was
supplied regarding such discussions or events, pursuant to App.R. 9(C) or App.R. 9(E).
       {¶48} It is the appellant’s responsibility to demonstrate error on appeal, and the
appellant must provide a record which exemplifies the claimed error. State v. Kuhn, 7th
Dist. No. 02 BA 7, 2003-Ohio-4007, at ¶35, quoting State v. Funkhouser, 7th Dist. No. 02-
BA-4, 2003-Ohio-697, a ¶13. See, also, App.R. 9(E); App.R. 10(A). Here Stocker argues
that the trial court’s decision not to lift its previous sanction was an abuse of discretion.
However, with no information in the record regarding the original sanction, this court does
not have adequate information to review whether the trial court’s subsequent decision
regarding the sanction was or was not an abuse of discretion. In the absence of a
complete record on appeal, this court presumes the regularity of the proceedings below.
Kuhn at ¶20. Accordingly, Stocker's second assignment of error is meritless.
       {¶49}    In conclusion, there existed some competent credible evidence supporting
the trial court's conclusion that Stocker did not prove Cochran's unreasonable delay or
unworkmanlike performance, thus the trial court’s decision was not against the manifest
weight of the evidence. Stocker's failure to provide this court with an adequate record to
                                                                                - 15 -


review her second assignment of error waives review thereof. Accordingly, the judgment
of the trial court is affirmed.
Vukovich, P.J., concurs.
Donofrio, J., concurs in judgment only.
