               ARMED SERVICES BOARD OF CONTRACT APPEALS

Appeal of--                                  )
                                             )
FRASSON LODOVICO S.r.l.                      )      ASBCA No. 58645
                                             )
Under Contract No. W912PF-10-C-0028          )

APPEARANCE FOR THE APPELLANT:                       Mr. Mauro Frasson
                                                     Owner

APPEARANCES FOR THE GOVERNMENT:                     Raymond M. Saunders, Esq.
                                                     Army Chief Trial Attorney
                                                    MAJ Nancy J. Lewis, JA
                                                     Trial Attorney

       OPINION BY ADMINISTRATIVE JUDGE SHACKLEFORD ON THE
     GOVERNMENT'S MOTION TO DISMISS FOR LACK OF JURISDICTION

       The government moves to dismiss this appeal for lack of jurisdiction asserting that
because the appeal was filed more than 90 days after the contracting officer's (CO's)
final decision was emailed to a person assisting appellant, it is untimely. Appellant
opposed the motion, arguing its appeal was timely filed within 90 days of receipt of the
CO's final decision sent to appellant by registered mail. We conclude the appeal was
timely filed. The motion is denied.

        STATEMENT OF FACTS (SOF) FOR PURPOSES OF THE MOTION

       1. On 27 September 2010, the 409th Contracting Support Brigade, Regional
Contracting Office, Vicenza, Italy (government) awarded Contract No. W912PF-10-C-0028
(contract), a design-build construction contract in the amount ofEUR 369.688,20
($477,818.54), to FRASSON LODOVICO S.r.l. (Frasson or appellant) (R4, tab 1).

        2. In unilateral Modification No. P00005, dated 17 February 2012, the
government deleted work it alleged Frasson had failed to perform, and reduced the
contract amount by EUR 7.800,00. The government also assessed liquidated damages
in the amount ofEUR 28.557,80. (R4, tab 20)

       3. Appellant, in a 22 March 2012 letter, contested the government's assessment of
liquidated damages and requested an equitable adjustment for its installation of two heat
recovery units, along with additional work performed on the heating, ventilation, and air
conditioning system (R4, tab 22).
       4. In a 26 April2012letter, appellant submitted a certified claim for
                1
EUR 56.363,44 seeking an equitable adjustment for the purchase and installation of the
two heat-recovery units and the repair of the existing heating, ventilation and air
conditioning system (R4, tab 24).

        5. Frasson filed a petition with the Board on 3 December 2012, seeking an order
under Board Rule 1(e) compelling the CO to issue a final decision (R4, tab 27). The
Board docketed the request on 4 December 2012 (gov't mot., ex. G-1) and thereafter was
advised by the government a final decision would be forthcoming by 25 January 2013.
Deeming this date reasonable, on 8 January 2013, the Board issued an Order directing the
CO to make a final decision no later than 25 January 2013. The Order also stated that if
the CO failed to comply with the Order, such failure would be deemed a decision denying
the claim and the contractor could appeal it as such. (Gov't mot., ex. G-2)

       6. The CO, Mr. Jeffrey Neill, issued a final decision in a letter dated 22 January
2013, addressed to appellant to the attention of Mr. Frasson (R4, tab 32). It was sent via
email on 25 January 2013, to Mr. Rodolfo Prischich (gov't mot., ex. G-3, encl. 8).
Mr. Neill stated in a declaration that he believed Mr. Prischich was representing
Mr. Frasson, appellant's owner. Mr. Prischich was a former employee of the Regional
Contracting Office-Italy (RCO) and was a consultant/advisor to companies doing
business with the RCO. He and Mr. Neill had had conversations about the project in
question and Mr. Prischich had attended meetings between Mr. Frasson and Mr. Neill,
translating for Mr. Frasson. (Gov't mot., ex. G-3)

        7. Mr. Neill also had a copy of the final decision sent by certified mail to
appellant (gov't mot., ex. G-.3, encl. 8). The decision, addressed to "Frasson Lodovico
S.R.L.[,] ATTN: Mr. Frasson," was received by appellant 5 February 2013 (app. resp. at
7, encls. 3, 7). The decision stated, inter alia: "If you decide to appeal, you must, within
90 days from the date you receive this decision, mail or otherwise furnish written notice
to the agency board of contract appeals" (R4, tab 32 at 8).

        8. Mr. Neill issued a correction to his final decision in a letter dated 25 February
20 13, stating:

                The Contracting Officer's Decision letter dated 22 Jan 20 13
                contains some errors that might cause some confusion. This
                letter will clarify the decision. The contract number and dates
                of actions contained in paragraphs 2, 9, 13a, 13b were
                erroneous as they were referenced as occurring in calendar
                year 2012, when they occurred in a different calendar year.

1
    The amount claimed in Euros, when converted to dollars, is almost $73,000, well below
         the threshold of$100,000 requiring certification. 41 U.S.C. § 7103(b).
                                               2
              These paragraphs have been corrected to reflect the correct
              dates (only the year was erroneous).

              In addition, in paragraph 29, the decision contained therein is
              confusing as it says that the "claim is hereby denied in its
              entirety" when it was approved in part and denied in part in
              paragraphs 1 and 28a-c.

The letter indicated it contained an enclosure titled "Corrected Contracting Officer's
Decision." (R4, tab 33)

       9. By correspondence received at the Board 1 May 2013, Mr. Frasson filed an
appeal. The notice of appeal stated appellant was appealing "the attached final decision
ofthe contracting officer dated 22 January 2013, received on 5 February 2013 via
registered mail" and included the CO's 25 February 2013 letter indicating there were
corrections to the 22 January 2013 final decision, and a copy of the final decision
incorporating the corrections. The appeal was docketed 2 May 20 13.

       10. The government filed a motion to dismiss for lack of jurisdiction on
8 August 2013, asserting appellant's appeal was untimely as it was filed 97 days after
appellant received the CO's final decision. According to the government, the 90-day
appeal period began on 25 January 2013 when the final decision was emailed to
Mr. Prischich and the appeal was not filed "with the Board until2 May 2013." (Gov't
mot. at 1) The government contends Mr. Prischich was acting as appellant's
representative and had actual or apparent authority to do so, thus starting the 90-day time
period (gov't mot. at 4, 5). The government also argues that irrespective of
Mr. Prischich's authority to receive the CO's final decision, the Board must still find that
25 January 2013 is the date to be used in determining timeliness of the appeal because the
Board had ordered the CO to make a final decision no later than 25 January 2013, and if
he had not, the claim would be deemed denied and appealable (gov't mot. at 5-6).

        11. Appellant contests the motion and denies Mr. Prischich was its representative
or had any legal authority to make decisions for the company. According to appellant,
Mr. Prischich was only acting as a consultant and translator, was not an employee of the
company and had never been delegated authority to represent the company. (App. resp.,
encl. 2)

        12. Appellant's president also submitted an affidavit attesting that he had never
requested the government send the CO's final decision via email and none of his
"employees or key personnel received notice [of the final decision] prior to my receipt of
the original, certified letter which our records show was received on February 5, 2013"
(app. resp., encl. 3). Appellant has provided a copy of the envelope and the post office


                                             3
receipt indicating a 5 February 2013 delivery date and receipt by appellant (app. resp.,
encl. 7).

                                        DECISION

       The Contract Disputes Act of 1978 (CDA), 41 U.S.C. § 7103(d), requires a CO to
issue a decision in writing, and to "mail or otherwise furnish a copy of the decision to the
contractor." The Federal Acquisition Regulation (FAR) 33.211, CONTRACTING
OFFICER's DECISION, requires that the CO furnish the contractor with a copy of the
decision on the claim "by certified mail, return receipt requested, or by any other method
that provides evidence of receipt." The CDA, 41 U.S.C. § 7104(a), provides that an
appeal must be filed by a contractor within 90 days from the date of receipt of a
CO decision. This 90-day filing period is statutory and cannot be waived by the Board.
Cosmic Construction Co. v. United States, 697 F.2d 1389 (Fed. Cir. 1982).

        The government maintains that Mr. Prischich's receipt of the final decision by
email25 January 2013 begins the 90-day period for appeal, citing cases wherein receipt
of a final decision by those with actual or apparent authority, even if not employees ofthe
contractor, met the CDA requirement for receipt and started the ru~ing of the 90 days
(gov't mot. at 4). However, the government has provided no evidence Mr. Prischich was
authorized to receive communications on behalf of appellant, but instead has relied on the
CO's assumption based on conversations between himself and Mr. Prischich, along with
meetings wherein Mr. Prischich acted as translator for Mr. Frasson (SOF ~ 6). Appellant
denies Mr. Prischich was in any way an agent or representative of the company and
Mr. Frasson submitted a sworn affidavit that Mr. Prischich was not an employee of
appellant and had no authority to act for the company (SOF ~ 11 ).

       However, this case does not tum on Mr. Prischich's status and we need not
determine whether Mr. Prischich was a representative of appellant or not, due to the
confusion created by the CO's final decision sent by registered mail, addressed to and
received by Mr. Frasson on 5 February 2013, and the corrections thereto sent 25 February
2013.

        We have held that where multiple copies of a CO's final decision have been
provided appellant, the latest received decision begins the 90-day period for appeal. In
AST Anlagen-und Sanierungstechnik GmbH, ASBCA No. 51854, 04-2 BCA ~ 32,712,
the CO delivered a copy of his final decision to a colleague in the ~arne law firm of the
attorney representing appellant. The CO also mailed a copy of the final decision directly
to appellant, addressed toAST's general manager, which was received 3 days after the
copy received at the law firm. The decision contained language indicating an appeal had
to be taken within 90 days from the date "you receive this decision." AST's general
manager did not know about the previously delivered decision and forwarded the final
decision to appellant's legal representative. An appeal was taken. However, the appeal

                                             4
was filed 91 days after the hand delivery to appellant's attorney's colleague but only
88 days after the mailed delivery toAST. The Board, relying on Eastern Computers,
Inc., ASBCA No. 49185,96-2 BCA ~ 28,343, held appellant had the right to rely on
receipt of the later decision, had done so, and the appeal was timely filed. AST, 04-2
BCA ~ 32,712 at 161,836. In Eastern, the government sent out copies of the CO's final
decision by fax and certified mail on the same day. Eastern conceded it received the fax
on 23 June 1995 and the certified copy five days later. The appeal would be untimely if
receipt was counted from 23 June 1995 but timely if receipt was 28 June 1995. The
Board said that sending multiple copies of a CO's final decision confuses a contractor as
to the date for appeal of the decision and the contractor is entitled to compute the date
from receipt ofthe last copy. Eastern, 96-2 BCA ~ 28,343 at 141,550.

       The case before us is unlike that in Tyger Construction Company, ASBCA
Nos. 36100, 36101, 88-3 BCA ~ 21,149, in which the appeal was deemed untimely. The
CO issued a final decision with the language stating that if the contractor wished to
appeal, it must do so within 90 days from the date of receipt of the decision. A copy was
faxed to appellant on 9 September 1987 and receipt of the fax was confirmed via
telephone by the government on the same day. A copy of the final decision was mailed
to appellant and received 16 September 1987. Appellant's notice of appeal to the Board,
92 days after receipt of the faxed copy, stated appellant was appealing the CO's final
decision received 9 September 1987, the date of receipt of the faxed copy. Tyger, 88-3
BCA ~ 21,149 at 106,779. In the case before us, appellant's notice of appeal, received at
the Board 1 May 2013, stated it was appealing the CO's final decision "received
5 February 2013," included the CO's 25 February 2013 letter advising the contractor of
the corrections to the decision, and the corrected decision (SOF ~ 9). Thus, this appeal
was filed from the decision received by Mr. Frasson, the addressee, on day 85 after
receipt of the final decision sent registered mail.

       The government argues the 90-day appeal period should be calculated from receipt
of the emailed copy of the final decision, 25 January 2013, citing Quimba Software, Inc.,
ASBCA No. 57636, 12-1 BCA ~ 34,910. However, in Quimba, appellant specifically
requested the emailing and acknowledged receipt of the decision by return email on the
same day. Quimba, 12-1 BCA ~ 34,910 at 171,651. Because appellant filed the appeal
91 days after receipt of the emailed CO's final decision, the appeal was untimely. The
same reasoning controls in Board decisions finding the start of the 90-day appeal period
from receipt of a faxed copy of the CO's final decision, rather than a later copy received
by mail. These cases tum on the fact the contractor specifically requested the final
decision be sent by facsimile. See, e.g., Mid-Eastern Industries, Inc., ASBCA
No. 51287, 98-2 BCA ~ 29,907 at 148,065; Leixab, S.A., ASBCA No. 51581, 98-2 BCA
~ 29,962 at 148,245. That is not the case here. Mr. Frasson never asked that the final
decision be emailed to him and has indicated he knew nothing about the final decision
until he received the copy mailed to him (SOF ~ 12).


                                            5
        Taking into account only the 25 January 2013 emailing and 5 February 2013
 receipt of the registered mail copy of the final decision, we have a situation similar to that
 in AST and the cases cited therein, and thus a timely appeal. In light of this decision, we
 need not decide if Mr. Prischich was authorized to receive the final decision, nor do we
 need to determine the effect of the later received corrections to the final decision.

         The government's argument that the 8 January 2013 Board Order, which directed
  the CO to issue a decision by 25 January 2013 and stated failure to do so would permit
  the contractor to proceed with an appeal on the basis of a deemed denial, therefore
  requiring calculation ofthe 90-day appeal period from 25 January 2013 is without merit.
  The CDA 90-day appeal period runs only from the date of receipt of a CO final decision.
  The government has failed to cite any authority for the proposition that the CO's failure
  to issue a decision by a date ordered by the Board legally obligates the contractor to
  appeal within 90 days of the "deemed denial" date. Establishment of such a date by the
  Board does not operate as a substitute for the final decision. To start the appeal period,
  the CO must actually issue a final decision that the contractor receives. Government
  inaction by the "deemed denial" date authorizes the contractor to appeal, but the time
  period within which that appeal must be taken is not the subject of a mandatory statutory
  requirement. Cf Pathman Construction Company v. United States, 817 F.2d 1573 (Fed.
· Cir. 1987) (in extensive analysis, the Federal Circuit concluded that statutory 12-month
  period for filing suit in Court of Federal Claims does not commence in the case of a
  "deemed denial"); Marlowe Heating & Air Conditioning, ASBCA No. 39588, 90-2 BCA
  ~ 22,753 at 114,213-14 (where CO expressly decided only a portion of claim, the 90-day
  appeal period did not commence for the unaddressed part of the claim; failure to address
  portion of claim constituted a deemed denial of claim authorizing, but not requiring,
  appeal within 90 days of final decision receipt).

                                     CONCLUSION

      Appellant's appeal was timely filed and the Board has jurisdiction over the appeal.
Accordingly, the government's motion to dismiss is denied.

        Dated: 10 February 2014




                                                    Administrative Judge
                                                    Armed Services Board
                                                    of Contract Appeals
 (Signatures continued)


                                               6
I concur                                     I concur




Administrative Judge
                                             /./r~-
                                             Administrative Judge
Acting Chairman                              Acting Vice Chairman
Armed Services Board                         Armed Services Board
of Contract Appeals                          of Contract Appeals


     I certify that the foregoing is a true copy of the Opinion and Decision of the
Armed Services Board of Contract Appeals in ASBCA No. 58645, Appeal ofFRASSON
LODOVICO S.r.l., rendered in conformance with the Board's Charter.

      Dated:




                                             JEFFREY D. GARDIN
                                             Recorder, Armed Services
                                             Board of Contract Appeals




                                         7
