      TEXAS COURT OF APPEALS, THIRD DISTRICT, AT AUSTIN


                                        NO. 03-11-00699-CV



                             City of New Braunfels, Texas, Appellant

                                                   v.

                                  Carowest Land, Ltd., Appellee


     FROM THE DISTRICT COURT OF COMAL COUNTY, 433RD JUDICIAL DISTRICT
       NO. C2010-1519D, HONORABLE CHARLES R. RAMSAY, JUDGE PRESIDING



                                            OPINION


                 The City of New Braunfels appeals a district court order denying a plea to the

jurisdiction it has asserted in a suit brought against it by a local property owner, Carowest Land, Ltd.

(Carowest).1 We will affirm the district court’s order in part and reverse in part.


                                          BACKGROUND

                 Although the rivers flowing through New Braunfels are renowned for their

scenic beauty and sometimes-rowdy “tubers,”2 they are also known to flood their surroundings

periodically, and thus the City undertook the “South Tributary Regional Flood Control Project,” or

“South Tributary Project,” a multi-million dollar public-works effort that entailed the construction

of a large drainage channel to divert run-off waters into the Guadalupe River. To provide a portion



        1
            See Tex. Civ. Prac. & Rem. Code § 51.014(a)(8).
       2
        See Stop the Ordinances Please v. City of New Braunfels, 306 S.W.3d 919, 922
(Tex. App.—Austin 2010, no pet.).
of the drainage channel’s route, appellee Carowest—a limited partnership associated with the

Weston family—voluntarily conveyed to the City a strip of land (the Original Channel Tract)

that traversed a tract of approximately 240 acres Carowest owned in the area. But there followed

a succession of disputes between Carowest and the City, leading to the underlying litigation, which

has been quite acrimonious at times. Although the parties advocate divergent views of these

events, this appeal concerns only whether the district court possesses subject-matter jurisdiction to

adjudicate the merits of the parties’ claims, so we are to take as true the facts alleged by Carowest

in its live pleadings or for which it has presented evidence except to the extent the City has presented

evidence sufficient to negate those facts.3 The following summary of relevant events accordingly

reflects that analytical framework and the deference it requires to Carowest’s side of the story.

                According to Carowest, the origins of the parties’ disputes lie in objections

Carowest voiced to the City as early as 2008 regarding the configuration of the Original Channel

Tract. The path of the Original Channel Tract bisected Carowest’s 240-acre tract in a manner that

severed approximately forty acres from the rest. Although there was evidence suggesting that its

representatives had consented to this configuration or even specifically requested it, Carowest asked

the City to agree to reroute the drainage channel to run instead along an outer boundary of the 240-

acre tract, citing concerns with the larger tract’s value and the well-being of Weston family members

who resided there. A related concern, Carowest alleges, were indications from the City that it




       3
          See, e.g., Texas Dep’t of Parks & Wildlife v. Miranda, 133 S.W.3d 217, 226-27
(Tex. 2004); Creedmoor-Maha Water Supply Corp. v. Texas Comm’n on Envtl. Quality, 307 S.W.3d
505, 516 (Tex. App.—Austin 2010, no pet.); Hendee v. Dewhurst, 228 S.W.3d 354, 366-69
(Tex. App.—Austin 2007, pet. denied); see also University of Tex. v. Poindexter, 306 S.W.3d 798,
806-07 (Tex. App.—Austin 2009, no pet.) (explaining differences in standards of review for
evidence-based challenges to jurisdictional facts that implicate the merits versus those that do not).

                                                   2
had designs on acquiring the severed forty-acre portion of Carowest’s property. Despite repeated

requests by Carowest, the City refused to agree to relocate the Original Channel Tract. Ultimately,

in March 2009, Carowest asked the City to rescind Carowest’s conveyance of the Original Channel

Tract altogether in exchange for Carowest paying any expenses caused by removing it from the

South Tributary Project. The City refused this request as well.

                Thereafter, Carowest alleges, the City, principally through its then-City Manager,

Mike Morrison, “undertook a malicious campaign to harm Carowest.” The campaign began,

according to Carowest, with written notice in April 2009 that the City intended to condemn the

severed forty-acre portion of Carowest’s property for unspecified “public purposes,” although

subsequent correspondence from the City Attorney’s office purported to “clarify” that the City was

interested only in obtaining a few acres of it for a long-anticipated expansion of the municipal sewer

plant. Next, in early May 2009, “despite urgent pleas from Carowest not to proceed,” the City’s

contractor on the Project, YC Partners, Ltd. d/b/a Yantis Company (Yantis), allegedly at Morrison’s

direction, began excavating the drainage channel through the Original Channel Tract. Although

Carowest acknowledges that it had previously conveyed the Original Channel Tract to the City, it

alleges—and, indeed, there is undisputed evidence—that Carowest had a right to obtain, at its option,

the dirt or fill that Yantis would dig up there and that Carowest had, in fact, indicated to the City that

it wanted the fill.4 Nevertheless, Carowest complains, Morrison instructed Yantis to transport the

excavated fill to an undisclosed off-site location and to “offer zero information” to Carowest.




        4
         As we will subsequently discuss, however, there is evidence that Carowest had not advised
the City where Carowest wanted the fill delivered.

                                                    3
               Around the same time, according to Carowest, Morrison advised the New Braunfels

City Council, through the written agenda for the Council’s May 11, 2009 meeting, that Carowest

had “notified the [C]ity that they no longer wish to have the fill placed on their property.” Carowest

decries this representation as “false and made in bad faith,” and one or more Carowest

representatives responded by going to the May 11 Council meeting and “attempt[ing], in the interest

of transparency, to provide the City Council with relevant information in open session.”

“[P]rompted by Morrison,” Carowest alleges, “the Mayor literally ‘pulled the plug’ on the

microphone of Carowest’s representative when he attempted to publicly discuss these issues and to

correct Morrison’s false representations.” Then, Carowest adds, the Council “improperly convened

in closed executive session to deliberate the Carowest fill issue.”

               Following the Council meeting, Carowest claims, it “sent additional letters on May 12

and 14 requesting that digging cease and that fill no longer be removed from the Property,” but the

City nevertheless “continued and even accelerated excavation from May 11 to May 14.” However,

by May 15, the City relented, agreeing to temporarily stop excavation on the Original Channel Tract.

By then, over 15,000 cubic yards of fill had been removed—according to Carowest, “enough to

cover over 100 football fields with dirt an inch thick”—and valued by Carowest in excess of

$100,000.

               Thereafter, Carowest and the City negotiated and ultimately executed a June 27, 2009

letter agreement (Letter Agreement) “to resolve issues related to The South Tributary Project.” The

material terms of the Letter Agreement included the following:


•      Carowest would provide a “professionally engineered design modification” to re-route the
       portion of the Project that crossed Carowest’s 240-acre tract. Likewise, Carowest would be
       responsible for maintaining the modified channel after construction.

                                                  4
•      Upon City approval of the modified design, the parties would work in good faith to execute
       documents effecting “a return of ownership of the current channel tract in exchange for the
       granting of a permanent easement for the modified channel tract to the City and other
       conveyances as provided for below.”

•      Carowest agreed to compensate the City for any difference in value between the Original
       Channel Tract and the modified one, and to pay for any engineering, permitting, review, and
       construction costs attributable to the modification exceeding those that the City would have
       incurred without the modification.

•      Similarly, Carowest agreed to indemnify the City and hold it harmless for any claims brought
       by Yantis for any modification costs Yantis incurred, “such as delay costs claimed by Yantis
       and directly attributable to the Modification.”

•      Any fill generated from the South Tributary Project thereafter would be placed on Carowest’s
       property, at the City’s expense, within one-half mile of the source. Further, Carowest was
       afforded the option to obtain fill that would be generated by another anticipated City flood-
       control project known as the “North Tributary Project,” including 13,944 cubic
       yards—“the amount represented by the City to be equal to the amount of fill removed from
       [the] Carowest Property”—that would be provided at no cost to Carowest.

•      “In a spirit of cooperation, and to address and resolve prior discussions concerning possible
       condemnation of Carowest Property for NBU [New Braunfels Utilities] purposes,” Carowest
       agreed to sell the City approximately six acres of Carowest property “primarily for use in a
       NBU future expansion,” at a price to be determined through an appraisal process.

•      Carowest agreed to donate to the City an easement near the modified channel route for use
       as a hike-and-bike trail.


Subsequently, to effectuate these terms of the Letter Agreement, Carowest and the City executed:

(1) a September 2009 “Drainage Channel Development Agreement” whereby Carowest assumed

control over channel construction on its property and the City agreed to make certain payments

toward the construction; (2) a November 2009 “Drainage Channel Easement” granting the City the

easement along the modified route of the drainage channel; (3) a November 2009 “Deed Without

Warranty” (Deed) whereby Carowest conveyed to the City approximately five acres for the sole

“purpose of expanding the existing sewage treatment facilities operated by New Braunfels Utilities



                                                5
located adjacent . . . or other uses directly related to that purpose” (the NBU expansion tract);

and (4) a November 2009 “Recreational Easement” permitting use of certain Carowest property as

a hike-and-bike trail. Each of these agreements was expressly made in consideration for the parties’

respective obligations under the Letter Agreement and incorporated that earlier contract in full.

               The disputes between Carowest and the City would resume, however, with both

sides accusing the other of materially breaching the Letter Agreement and the related contracts.

Ultimately, the parties did not close on the City’s acquisition of the NBU expansion tract—while the

City would later accuse Carowest of refusing to accept payment for the tract, Carowest would allege

that the City tried to change the terms of the deal—and Carowest purported to revoke both

the Drainage Channel Easement and the Recreational Easement. A primary source of contention was

a claim by Yantis against the City for approximately $550,000 it attributed to work delays on the

portion of the South Tributary Project traversing Carowest’s property. Invoking the City’s right to

indemnification under the Letter Agreement, Morrison and the City referred Yantis’s claim to

Carowest and demanded that it “work out a payment” with Yantis. Carowest denied that it was

liable for any delays. Subsequently, in July 2010, Yantis re-submitted its delay claim to the City,

this time seeking approximately $275,000. As before, Morrison and the City referred Yantis’s claim

to Carowest and demanded indemnification. Again, Carowest denied there had been any delays for

which it was responsible.

               Carowest alleges that Morrison and the City engaged in two sets of wrongful acts

in regard to Yantis’s delay claim. First, Carowest contends that Morrison knew all the while that

Yantis’s delay claim was “bogus” because, in Carowest’s view, the claim had already been released

or waived through an October 2009 change order, and would again be released by a May 2010



                                                 6
release obtained in connection with a progress payment. Despite knowing that the delay claim was

meritless, Carowest adds, Morrison and the City “concealed” the existence of this change order and

demanded indemnification despite the waivers as a continuation of their “malicious campaign to

harm Carowest,” causing Carowest to incur “substantial losses of time and resources” in addressing

the claim. Second, Carowest alleges that the City ultimately resolved Yantis’s delay claim through

what Carowest characterizes as an unlawful quid-pro-quo arrangement—in May 2011, the City

awarded Yantis the $5 million contract to construct the North Tributary Project (the anticipated

public works project that was to be a source of fill to which Carowest was entitled under the Letter

Agreement) contemporaneously with Yantis’s release of the claim.

               As these disputes were continuing to evolve, Carowest filed suit against the City

and other defendants in November 2010. In the early stages of the litigation, Carowest sought only

money damages based on the City’s alleged breach of the Letter Agreement and Deed by failing to

pay Carowest the purchase price of the NBU expansion tract, a declaratory judgment that the

City had no right of indemnification from it under the Letter Agreement because Yantis had no

valid delay claim,5 and related attorney’s fees.6 The City asserted a plea to the jurisdiction seeking

dismissal of these claims, which the district court denied. The City perfected an appeal of the

district court’s order, but later dismissed the appeal voluntarily.7 Instead, contemporaneously with

moving to dismiss its appeal, the City returned to district court and asserted counterclaims against


       5
        See generally Uniform Declaratory Judgments Act (UDJA), Tex. Civ. Prac. & Rem. Code
§§ 37.001-.011.
       6
          See id. §§ 37.009 (UDJA’s attorney’s fees provision), 38.001(8) (authorizing award of
attorney’s fees in connection with a contract claim).
       7
        City of New Braunfels v. Carowest Land, Ltd., No. 03-11-00211-CV, 2011 Tex. App.
LEXIS 5039 (Tex. App.—Austin July 1, 2011, no pet.) (mem. op.).

                                                  7
Carowest. As later amended, the counterclaims alleged that Carowest had materially breached the

Letter Agreement and related contracts by refusing to accept payment for and close the conveyance

of the NBU expansion tract and by purporting to revoke the Drainage Channel Easement and

Recreational Easement. The City prayed for specific performance to compel Carowest “to close the

sale on the NBU expansion tract” and for declarations that the revocations were null, void, and

without effect on the two easements. In the alternative to this injunctive and declaratory relief, the

City requested breach-of-contract damages for the amounts it had expended in fulfilling its

contractual obligations to fund the drainage improvements on Carowest’s property, which it alleged

to be in excess of $840,000.

               Carowest then amended its pleadings to add a number of new claims against the City

for both money damages and declaratory relief, and it is this version of Carowest’s pleadings that

underlies this appeal. In them, Carowest asserts essentially three sets of claims for money damages:


•      Carowest seeks to recover the value of the fill that was removed from the Original Channel
       Tract in May 2009, relying on theories of (1) inverse condemnation; (2) violations of
       constitutional equal protection and “substantive” due process guarantees, for which it seeks
       relief under 42 U.S.C. § 1983; and (3) common-law tort theories of conversion, fraud,
       conspiracy to commit both conversion and fraud, breach of fiduciary duty, and tortious
       interference with an alleged 2008 agreement between Carowest and Yantis.

•      Carowest seeks to recover damages for the City’s alleged breach of the Letter Agreement
       and related agreements, including the purchase price for the Deed (as it had sought in its
       earlier pleadings) as well as various construction and engineering expenses that Carowest
       contends the City was obligated to pay under the Letter Agreement and Drainage Channel
       Development Agreement but had failed to pay.

•      Carowest seeks to recover the value of the “substantial losses of time and resources” that
       Carowest incurred in addressing the “bogus” Yantis delay claim, as well as various
       unspecified damages allegedly arising from the City’s conduct after execution of the
       Letter Agreement. Carowest relies on theories of (1) equal protection and “substantive”
       due process violations “in subjecting Carowest to fraudulent, coercive, and bad faith
       treatment in connection with the Project,” for which it seeks relief under Section 1983; and

                                                  8
       (2) common-law tort theories of breach of fiduciary duty, fraud, and conspiracy to commit
       fraud.


Carowest also seeks exemplary damages based on its common-law tort theories, as well as

attorney’s fees incident to its breach-of-contract claims under chapter 38 of the Civil Practice and

Remedies Code.8

                 As for its declaratory claims, Carowest seeks the following relief in addition to its

original claim concerning indemnification for Yantis’s delay claim:


•      Declarations that the City violated the Texas Open Meetings Act9 by (1) “refusing
       Carowest’s request to discuss public issues and convening in closed session at the May 2009
       Council Meeting”; and (2) “concealing the North Tributary Deal’s quid pro quo arrangement
       between the City and Yantis from Carowest, the public and from other bidders on the
       North Tributary Project at the May 2011 Council Meeting.”

•      Declarations that the “North Tributary Deal” between the City and Yantis—i.e., the contract
       to construct the North Tributary Project, which Carowest alleges was awarded in exchange
       for Yantis’s release of its delay claim—violates chapter 252 of the Local Government Code10
       and is, therefore, void.


In connection with its declaratory claims, Carowest also prays for attorney’s fees under the UDJA.11

                 Subsequently, alleging that work was beginning on the North Tributary Project

and insisting that it would be unable to exercise its option under the Letter Agreement to accept

the project’s “unique” and “valuable” fill before its legal challenges to Yantis’s contract were

adjudicated, Carowest filed an application for temporary restraining order (TRO) seeking to halt


       8
            See Tex. Civ. Prac. & Rem. Code § 38.001(8).
       9
            See Tex. Gov’t Code § 551.142.
       10
            See generally Tex. Loc. Gov’t Code §§ 252.001-.063.
       11
            See Tex. Civ. Prac. & Rem. Code § 37.009.

                                                   9
all work on the North Tributary Project. Around the same time, the City filed a second plea to the

jurisdiction. Both sides presented evidence to the district court. A hearing was held on both the

City’s plea to the jurisdiction and Carowest’s TRO request, at which the parties presented further

evidence. Following the hearing, the district court denied both the plea to the jurisdiction and

the TRO request by written order. The district court’s order did not elaborate on its grounds or

reasoning, nor were any findings of fact or conclusions of law requested or made. Seeking to

challenge the district court’s order denying its plea to the jurisdiction, the City perfected this

appeal.12


                                              ANALYSIS

                 In what it styles as three issues on appeal, the City argues that the district court erred

in denying its most recent plea to the jurisdiction.13


Standard of review

                 In addressing the City’s jurisdictional challenges, simply put, we consider whether

the facts Carowest presented in its live pleadings or evidence and not negated by evidence from the



        12
             See id. § 51.014(a)(8).
        13
           Carowest does not suggest that the City’s earlier plea to the jurisdiction serves to limit our
jurisdiction to review jurisdictional challenges raised in the City’s current plea that reurge or overlap
with challenges raised in its earlier plea. Cf. City of Houston v. Estate of Jones, 388 S.W.3d 663,
666-67 (Tex. 2012) (per curiam) (where jurisdictional challenges raised in subsequent plea to
the jurisdiction entirely duplicated grounds raised in earlier plea, subsequent plea was substantively
a motion for reconsideration of the earlier plea whose denial could not be appealed via
section 51.014(a)(8) of the Civil Practice and Remedies Code). To the extent Jones raises any
doubts in that regard, we conclude we possess jurisdiction over the entirety of the City’s present
appeal by virtue of its having perfected a timely appeal under section 51.014(a)(8) as to jurisdictional
challenges not raised in its earlier plea and the rationale of Rusk State Hospital v. Black, 392 S.W.3d
88, 94-96 (Tex. 2012).

                                                    10
City would affirmatively establish the district court’s subject-matter jurisdiction to adjudicate each

of Carowest’s claims.14 That ultimate determination is a question of law that we review de novo.15

                To invoke the district court’s subject-matter jurisdiction in this case, Carowest’s

chief challenge is to avoid or overcome the City’s governmental immunity. Governmental immunity

is a common-law doctrine that derives from the sovereign immunity that shields the State, its

agencies, and its officials.16 It protects local government units, such as the City, when performing

“governmental” functions, which are essentially those in which a unit is deemed to be acting as

an arm of the State and in the interest of the general public.17 The contemporary rationale for such

immunity is that the Legislature, not the Judiciary, is best suited to make the policy-laden judgments

as to how the resources of Texas governmental units should be expended.18 To that end, such

immunity deprives courts of subject-matter jurisdiction over suits brought against governmental units

and their agents, as well as those seeking certain remedies deemed to independently implicate that




       14
        See, e.g., Miranda, 133 S.W.3d at 226-27; Creedmoor-Maha, 307 S.W.3d at 516; Hendee,
228 S.W.3d at 366-69; see also Poindexter, 306 S.W.3d at 806-07.
       15
            See Miranda, 133 S.W.3d at 226.
       16
          See, e.g., City of Houston v. Williams, 353 S.W.3d 128, 134 (Tex. 2011); Tooke v. City
of Mexia, 197 S.W.3d 325, 345 (Tex. 2006).
       17
            See City of Galveston v. State, 217 S.W.3d 446, 469 (Tex. 2007); Tooke, 197 S.W.3d
at 343 (citing Dilley v. City of Houston, 222 S.W.2d 992, 993 (Tex. 1949)). Given the relationship
between the two doctrines, we cite a number of cases addressing sovereign immunity to support our
analysis of governmental immunity without noting the distinction. Similarly, we will often refer to
the two types of immunity interchangeably, or to either or both simply as “immunity.”
       18
         Texas Dep’t of Transp. v. Sefzik, 355 S.W.3d 618, 621 (Tex. 2011) (citing Texas Natural
Res. Conservation Comm’n v. IT-Davy, 74 S.W.3d 849, 854 (Tex. 2002)); Tooke, 197 S.W.3d
at 331–32.

                                                 11
immunity, such as retrospective monetary relief,19 unless the State has consented to suit through

legislative waiver of that immunity.20 A legislative waiver of immunity may be in the form of either

statute or resolution, but in either case the Legislature’s intent to waive immunity must be expressed

in “clear and unambiguous language.”21

                Without question, Carowest’s claims potentially implicate the City’s governmental

immunity—they are asserted against the City and, further, seek remedies that explicitly include

money damages. Accordingly, Carowest has advanced, and the City has disputed, a litany of legal

theories as to why Carowest’s factual allegations, the evidence, or both affirmatively demonstrate

that each of Carowest’s claims either does not implicate the City’s governmental immunity or comes

within a statutory waiver of that immunity.


       19
           See Bacon v. Texas Historical Comm’n, 411 S.W.3d 161, 173 (Tex. App.—Austin 2013,
no pet.) (“This principle of judicial deference embodied in sovereign immunity extends not only to
the Legislature’s choices as to whether state funds should be spent on litigation and court judgments
versus other priorities, but equally to the policy judgments embodied in the constitutional or statutory
delegations that define the parameters of an officer’s discretionary authority and the decisions the
officer makes within the scope of that authority.” (citing Sefzik, 355 S.W.3d at 621 (citing W.D.
Haden Co. v. Dodgen, 308 S.W.2d 838, 839 (Tex. 1958)); City of El Paso v. Heinrich, 284 S.W.3d
366, 372 (Tex. 2009); Director of Dep’t of Agric. & Env’t v. Printing Indus. Ass’n of Tex.,
600 S.W.2d 264, 265 (Tex. 1980))).

         Governmental immunity, like sovereign immunity, encompasses not only this immunity
from suit, but also liability even if immunity from suit is waived. Reata Constr. Corp. v. City of
Dallas, 197 S.W.3d 371, 374 (Tex. 2006). Immunity from liability is an affirmative defense; it does
not implicate the trial court’s subject-matter jurisdiction, and is, therefore, not before us here. See
Miranda, 133 S.W.3d at 224. Accordingly, we will, for convenience, generally use “governmental
immunity” to refer solely to the City’s immunity from suit.
       20
          Reata, 197 S.W.3d at 375; see also Wichita Falls State Hosp. v. Taylor, 106 S.W.3d 692,
695 (Tex. 2003) (noting that “Legislature is better suited to balance the conflicting policy issues
associated with waiving immunity” (citing, among other cases, IT-Davy, 74 S.W.3d at 854)).
        21
         Bacon, 411 S.W.3d at 173 (citing IT-Davy, 74 S.W.3d at 853-54 (citing General Servs.
Comm’n v. Little-Tex Insulation Co., Inc., 39 S.W.3d 591, 594 (Tex. 2001)) (quoting Tex. Gov’t
Code § 311.034; University of Texas Med. Branch v. York, 871 S.W.2d 175, 177 (Tex. 1994))).

                                                  12
Constitutional claims

                 We will begin with jurisdictional issues related to Carowest’s constitutional

claims, as they logically precede or supersede questions concerning the application and operation

of governmental immunity—which, again, is a doctrine of Texas common law—and whether the

Legislature has waived that immunity by statute.


       Inverse condemnation

                 As previously noted, Carowest seeks to recover the value of the fill that was removed

from the Original Channel Tract in May 2009 under a theory of “inverse” condemnation, also termed

a “takings” claim. Such claims are rooted in the takings clause of the Texas Constitution—article I,

section 17—which provides, in relevant part, that “no person’s property shall be taken, damaged, or

destroyed for or applied to public use without adequate compensation being made, unless by the

consent of such person.”22 Article I, section 17 thus “requires that the government compensate the

owner” whenever “private property is taken for a public purpose,”23 and “when the government takes

private property without paying for it” rather than initiating a formal condemnation proceeding,

article I, section 17 authorizes the property owner to sue the government for compensation (hence

the “inverse” condemnation and “takings” descriptors).24 Because this cause of action is created by

the Texas Constitution, a valid takings claim is not barred by common-law doctrines of sovereign




       22
            Tex. Const. art. I, § 17.
       23
         El Dorado Land Co., L.P. v. City of McKinney, 395 S.W.3d 798, 804 (Tex. 2013) (citing
Tex. Const. art. I, § 17).
       24
            See id.

                                                  13
and governmental immunity.25 Conversely, if a plaintiff “cannot establish a viable takings claim”

against a governmental entity, the claim would implicate immunity and potentially be barred by it.26

                 “[I]t is fundamental that, to recover under the constitutional takings clause, one must

first demonstrate an ownership interest in the property taken,”27 and if one “does not own the

disputed land, the takings claim is not viable and the trial court lacks jurisdiction.”28 Carowest has

not alleged or presented proof that it owned the Original Channel Tract at the time of the alleged

“taking” of the fill from that property in May 2009—to the contrary, the evidence reflects, and

Carowest acknowledges, that it had conveyed ownership of the Original Channel Tract to the

City back in 2008.29 Nor is there any allegation, evidence, or assertion that Carowest reserved any

ownership rights in the tract, or to the fill in particular, when making this conveyance.30 Rather,

Carowest’s theory, as it explains in its appellate brief, is that it “acquired its interest in the excavated

soil via a contractual agreement.” It pleads:


        25
             See State v. Holland, 221 S.W.3d 639, 643 (Tex. 2007); Little-Tex, 39 S.W.3d at 598.
        26
          Texas Dep’t of Transp. v. A.P.I. Pipe & Supply, LLC, 397 S.W.3d 162, 166 (Tex. 2013)
(citing Hearts Bluff Game Ranch, Inc. v. State, 381 S.W.3d 468, 491 (Tex. 2012)); see Little-Tex,
39 S.W.3d at 598.
        27
         A.P.I. Pipe, 397 S.W.3d at 166 (quoting Texas Dep’t of Transp. v. City of Sunset Valley,
146 S.W.3d 637, 644 (Tex. 2004)) (emphasis in original).
        28
             Id. at 166-67.
        29
           The evidence includes the Letter Agreement, which contemplates “a return of ownership
of the current channel tract to Carowest.” Similarly, Carowest acknowledges in its brief that,
“[a]s the City correctly states in its brief, the City owned the land from which the dirt was removed.”
However, the evidence does not include any deed or other instrument effecting this conveyance.
        30
           Cf. El Dorado, 395 S.W.3d at 800-04 (viable takings claim predicated on reversionary
interest reserved by claimant when conveying land); State v. Brownlow, 319 S.W.3d 649, 653-58
(Tex. 2010) (viable takings claim, to recover value of excavated fill, predicated on fee interest in
land retained when granting easement).

                                                    14
       The City and Carowest had previously agreed that Carowest would have the
       option to keep the fill from the drainage channel. Specifically, the City agreed to the
       following: “At Carowest’s option, and at the City’s cost, the fill material from the
       [Original] Channel Tract will be taken from the site by the City’s contractor and
       transported by the City’s contractor to any location requested by Carowest upon the
       Carowest Property or any location up to one-half mile outside the boundary of the
       Carowest Property.”


Carowest further alleges that it had exercised its option to obtain the fill prior to May 2009, citing

“an April 3, 2009 letter” in which “Morrison had personally acknowledged to Carowest [that] ‘you

have previously exercised your option via electronic mail that you want the fill material from the

Channel Tract.’”

               Although no agreement of the sort alleged by Carowest appears in the evidence,31 the

“April 3, 2009 letter” does. In it, Morrison, on behalf of the City, “respectfully declines” Carowest’s

request “that the right of way for the South Tributary Project that you voluntarily deeded to the City

be rescinded and the property be deeded back to Carowest.” Morrison then states:


       The City intends to proceed under the terms of the agreement executed on
       December 4, 2008. Accordingly, since you have previously exercised your option
       by electronic mail that you want the fill material from the Channel Tract,
       please designate a specific location for the City to move the material. In addition,
       construction of the South Tributary project has already commenced. Construction
       on the Carowest property shall proceed immediately.


The record also includes an April 21, 2009 letter to Carowest from the New Braunfels

City Attorney’s office, which similarly advises:




       31
         However, as we explain below, the evidence does contain references to the existence of
an “agreement” or “contract” between the City, Carowest, and Yantis dated December 4, 2008.

                                                   15
       The contractor on the [South Tributary] project is ready to begin work on the City’s
       property (the “Channel Tract”) that runs across the original Carowest tract. . . .
       Pursuant to the agreement between the City and Carowest, Carowest had elected
       to “accept the fill material from the channel tract” and that the contractor would
       transport it to a location on its property or up to one-half mile from its property. The
       contractor bid on the South Tributary Project with the assumption that Carowest
       would accept the fill material. The City and the contractor need to know if Carowest
       intends to honor its contractual commitment, and, if so, designate where it would like
       the fill material deposited. If not, the City has no other option but to instruct the
       contractor to remove the fill material from the site. It is estimated that the cost for
       removing the fill could be as much as $450,000, and the City will seek to recover
       those costs from Carowest since they will be incurred as a result of Carowest’s
       breach of its contractual agreement with the City. The City believes that using the
       fill on the Carowest property will be a benefit to that property, and it will avoid the
       cost of hauling off the fill, but that is a decision to be made by [Carowest].


                This evidence, which is undisputed, is significant for at least two reasons. First, it

does not negate but supports Carowest’s allegations that it had exercised its option and, therefore,

owned any fill that would be excavated from the Original Channel Tract. The City does not advance

any cogent reason why Carowest’s ownership of the fill would not be the sort of property interest

that could potentially give rise to a takings claim.32 On the other hand, as the City points out, the

same evidence negates one of the elements of a takings claim predicated on the City’s removal or

withholding of the fill.

                To recover under article I, section 17 of the Texas Constitution, Carowest must

plead and prove the following elements: (1) the City intentionally performed certain acts; (2) that

resulted in a “taking” of the fill; (3) for public use.33 A component of the intent element is that the

       32
           Although Carowest characterizes the excavated fill as “personal property” rather than
real property, cf. Brownlow, 319 S.W.3d at 653-58, compensable takings may involve both kinds
of property. See City of Dallas v. VSC, LLC, 347 S.W.3d 231, 234-36 (Tex. 2011) (takings claim
predicated on seizure of automobiles); Steele v. City of Houston, 603 S.W.2d 786, 789 (Tex. 1980)
(takings claim predicated in part on destruction of personal belongings).
       33
            See Little-Tex, 39 S.W.3d at 598-99.

                                                   16
City must have been acting in its capacity as sovereign—i.e., exercising eminent domain or police

powers34—as opposed to acting “akin to a private citizen.”35 And with regard to rights voluntarily

created by contract, such as we have here, “[t]he concept of a taking as a compensable claim theory

has limited application.”36


       Texas courts have long recognized that the State wears two hats: the State as a party
       to the contract and the State as sovereign. The State, in acting within a color of right
       to take or withhold property in a contractual situation, is acting akin to a private
       citizen and not under any sovereign powers. In this situation, the State does not have
       the intent to take under its eminent domain powers; the State only has an intent to act
       within the scope of the contract.37


Consequently, to establish the district court’s jurisdiction over its takings claim, Carowest had

to allege or present evidence of facts that would distinguish the City’s removal or withholding of

the fill as the exercise of sovereign powers, as opposed to the mere withholding of property or

performance in a contract dispute in the manner that a private individual could.38 The City argues

that Carowest failed to do so. We agree.

                 The essence of Carowest’s takings allegations is that the City removed large volumes

of fill from the Original Channel Tract in derogation of Carowest’s right—under a contract—to


       34
           See City of Dallas v. Stewart, 361 S.W.3d 562, 569 (Tex. 2012); Steele, 603 S.W.2d
at 789; Texas Workforce Comm’n v. Midfirst Bank, 40 S.W.3d 690, 697 (Tex. App.—Austin 2001,
pet. denied).
       35
            Holland, 221 S.W.3d at 643 (citing Little-Tex, 39 S.W.3d at 599).
       36
           Little-Tex, 39 S.W.3d at 599 (quoting Sun Oil v. United States, 572 F.2d 786, 818
(Ct. Cl. 1978)).
       37
            Id. (citations omitted).
       38
         See id.; MBP Corp. v. Board. of Trs. of Galveston Wharves, 297 S.W.3d 483, 489-91
(Tex. App.—Houston [14th Dist.] 2009, no pet.).

                                                  17
receive it. Without more, Carowest, as the City suggests, has merely alleged facts that might support

an ordinary breach-of-contract claim. Further, the evidence conclusively demonstrates that in the

days immediately preceding the City’s removal of the fill, the parties were locked in a dispute over

whether Carowest was in breach of a contractual obligation to advise the City where it wanted the

fill delivered. These facts establish that the City was merely asserting “its colorable contract rights”

rather than its sovereign powers.39

                In the face of this record, Carowest offers no persuasive reason for us to conclude

that it has asserted, or could assert, a viable takings claim.40 Accordingly, the district court erred

in denying the City’s plea to the jurisdiction as to this claim. And because the facts necessary to

support a viable takings claim have been negated by Carowest’s own pleadings and the evidence,

Carowest is not entitled to an opportunity to replead.41




       39
            See Holland, 221 S.W.3d at 643; Little-Tex, 39 S.W.3d at 599.
       40
            Carowest insists that Brownlow presents “facts remarkably similar to those in this
case”—specifically, a takings claim validated by the Texas Supreme Court that was rooted in
“respective rights . . . derived from a contractual arrangement.” To the contrary, Brownlow involved
a takings claim asserted by the fee owner of land (a type of real property interest) that had been
burdened by an easement (another type of real property interest) permitting the Texas Department
of Transportation to build and maintain a mitigation pond. See 319 S.W.3d at 651-52. Further, the
central issue in the case was whether the easement permitted TxDOT to take possession of fill
excavated during the pond’s construction for use on its highway projects elsewhere, and the
supreme court held that it did not. See id. at 655. While Brownlow perhaps reflects the unsurprising
notion that a property interest in excavated fill can serve as the basis for a takings claim, the court
did not have cause to address the critical issue in the present case—whether the government was
acting in its capacity as sovereign versus “akin to a private citizen” where rights have been
voluntarily established by contract. That distinction, again, is controlled by the Holland and Little-
Tex line of cases.
       41
        See Texas Parks & Wildlife Dep’t v. Sawyer Trust, 354 S.W.3d 384, 392 (Tex. 2011);
Texas A&M Univ. Sys. v. Koseoglu, 233 S.W.3d 835, 839-40 (Tex. 2007).

                                                  18
       “Civil rights violations”

                In addition to its takings claim under the Texas Constitution, Carowest seeks to

recover damages, including the value of the fill removed from the Original Channel Tract, through

a claim under Section 198342 for the City’s alleged “violation of the equal protection and substantive

due process clauses of the Fourteenth Amendment of the United States Constitution.”43 Similar to

Carowest’s takings claim, governmental immunity would not bar viable Section 1983 claims against

the City predicated on federal constitutional violations.44

                However, as the City observes, Carowest’s claims of federal constitutional violations

are predicated largely on the same factual allegations that underlie its takings claim. In fact, in

support of its Section 1983 claim, Carowest pleads that “[a]t all times relevant to this cause of

action” the City “acted under color of state law in depriving Carowest of its fill by removing it

from the Property.” This is significant because (1) Texas takings jurisprudence is materially similar

to federal takings jurisprudence;45 and (2) under federal law, where claims nominally asserted

under other constitutional provisions are based on what is substantively a takings claim, the former




       42
            See 42 U.S.C. § 1983.
       43
            U.S. Const. amend. XIV.
       44
           See Thomas v. Allen, 837 S.W.2d 631, 632 (Tex. 1992) (explaining that state court may
not refuse to entertain federal Section 1983 claim on ground that it is barred by sovereign immunity)
(per curiam) (citing Howlett v. Rose, 496 U.S. 356, 369, 374 (1990)); see also LTTS Charter Sch.,
Inc. v. C2 Constr., Inc., 358 S.W.3d 725, 738 (Tex. App.—Dallas 2001, pet. denied) (noting that
local government entities do not enjoy immunity from suit under Section 1983).
       45
           Hearts Bluff Game Ranch, Inc., 381 S.W.3d at 477 (“We consider the federal and state
takings claims together, as the analysis for both is complementary.”).

                                                 19
are deemed to be “subsumed” into the takings claim, and are not independently actionable.46

Consequently, the City contends that if Carowest’s takings claim is not viable, then it follows that

Carowest has failed to assert any viable “due process” or “equal protection” claim predicated on the

same facts.

                 Carowest does not appear to dispute this conclusion, at least to the extent its

“due process” or “equal protection” claims are predicated on deprivation of the fill. Instead, it insists

that these claims are not, in their entirety, based on the same facts and do not implicate the

same constitutional protections as its takings claim. Indeed, Carowest complains more broadly of

“fraudulent, coercive, and bad faith treatment in connection with the [South Tributary] Project.”

Liberally construing Carowest’s pleadings, as we must do,47 these allegations would appear to

reference purported conduct by the City beyond deprivation of the fill, such as its alleged acts in

connection with the Yantis delay claim.

                 On the other hand, these other factual allegations, while potentially sounding in the

common-law tort theories Carowest advances, would fall short of demonstrating any actions by the

City infringing on any constitutionally protected interest or amounting to constitutionally cognizable

unequal treatment.48 In short, Carowest has not alleged any viable claim for constitutional violations


        46
         See Sandy Creek Investors, Ltd. v. City of Jonestown, 325 F.3d 623, 626 (5th Cir. 2003);
John Corp. v. City of Houston, 214 F.3d 573, 582-83 (5th Cir. 2000).
        47
             See Miranda, 133 S.W.3d at 226.
        48
          See Liberty Mut. Ins. Co. v. Texas Dep’t of Ins., 187 S.W.3d 808, 827 (Tex. App.—Austin
2006, pet. denied) (“[I]n order to bring a substantive due process claim, an individual must show
they have a protected interest.”); John Corp., 214 F.3d at 577 (“The Equal Protection Clause protects
individuals from governmental action that works to treat similarly situated individuals differently”)
(citing City of Cleburne v. Cleburne Living Ctr., 473 U.S. 432, 439 (1985)); see also Ex parte
Morales, 212 S.W.3d 483, 500 (Tex. App.—Austin 2006, pet. ref’d) (explaining that equal
protection clause requires that “‘all persons similarly situated shall be treated alike’ under the law”).

                                                   20
that is substantively distinct from its non-viable takings claim. Consequently, the district court erred

in denying the City’s plea to the jurisdiction as to Carowest’s claim under Section 1983. However,

while Carowest’s pleadings regarding its Section 1983 claim are currently insufficient to invoke the

district court’s subject-matter jurisdiction, we also conclude that its pleadings do not affirmatively

negate jurisdiction either, nor has the City argued or otherwise suggested that Carowest has already

had sufficient opportunity to amend its pleadings to correct the jurisdictional defect. Consequently,

upon remand, Carowest is entitled to a reasonable opportunity to amend its pleadings to attempt to

cure the jurisdictional defect.49


Common-law monetary claims

                 We now turn to whether Carowest’s common-law contract and tort claims implicate

the City’s governmental immunity or come within a waiver of it.


        “Proprietary” vs. “governmental” functions

                 As previously noted, governmental immunity is a derivative of the State’s

sovereign immunity that shields local governmental units, including municipalities, when performing

“governmental” functions, those in which a unit is deemed to be acting on behalf of the State and the

general public.50 The converse of the “governmental” functions that are shielded by governmental



Furthermore, to establish municipal liability under Section 1983, a plaintiff must show that the
municipality acted pursuant to an official policy or custom and that this action caused a violation
of a particular constitutional right. Valle v. City of Houston, 613 F.3d 536, 541 (5th Cir. 2010)
(citing Monell v. Department of Soc. Servs., 436 U.S. 658, 691 (1978)).
        49
             See Miranda, 133 S.W.3d at 226-27.
        50
         See City of Galveston, 217 S.W.3d at 469; Tooke, 197 S.W.3d at 343 (citing Dilley,
222 S.W.2d at 993).

                                                  21
immunity are “proprietary” functions, which, generally speaking, are those in which a municipality

is deemed to be acting in its “‘private capacity, for the benefit only of those within its corporate

limits, and not as an arm of the government.’”51 As one of the jurisdictional bases for its claims,

Carowest has asserted that “[t]he City’s tortious conduct was committed while it was engaged in

proprietary, rather than governmental, functions,” such that governmental immunity does not shield

the City from Carowest’s claims arising from that conduct.52

                Although the distinction is rooted in the common law, the Texas Constitution

has authorized the Legislature to “define for all purposes those functions of a municipality that are

to be considered governmental and those that are proprietary, including reclassifying a function’s




       51
            Tooke, 197 S.W.3d at 343 (quoting Dilley, 222 S.W.2d at 993).
       52
            In these pleading allegations, as well as on appeal, Carowest appears to rely on the
“proprietary functions” classification solely to establish jurisdiction as to its tort claims, not
its breach-of-contract claims. Cf. Tooke, 197 S.W.3d at 33 (Texas Supreme Court observing that
while “[t]he proprietary-governmental dichotomy has been used to determine a municipality’s
[governmental] immunity from suit for tortious conduct . . . we have never held that this
same distinction determines whether immunity from suit is waived for breach of contract claims, and
we need not determine that issue here.”). To the extent Carowest seeks to extend this analysis more
broadly, we note that the Texas Supreme Court has assumed without deciding that if the proprietary-
governmental dichotomy applies beyond tort claims (i.e., to claims not directly governed by the
Tort Claims Act), courts should nonetheless defer to the Act’s classifications of proprietary-versus-
governmental functions (discussed below) in applying the dichotomy as a matter of the common law.
See id. at 343-44 (looking to Act’s classification scheme to determine whether breach-of-contract
claim implicated a municipality’s proprietary or governmental functions, as “we see no reason to
think that the classification would be different under the common law.”); accord PKG Contracting,
Inc. v. City of Mesquite, 197 S.W.3d 388, 388-89 (Tex. 2006) (per curiam) (similarly deferring to
Tort Claims Act’s classification scheme in determining that breach-of-contract claims implicated
municipality’s governmental rather than proprietary functions). As in Tooke and PKG Contracting,
Carowest has suggested no reason why the proprietary-governmental classification would apply any
differently to its contract claims versus its tort claims, nor can we conceive of any. Accordingly, to
the extent Carowest is relying on the “proprietary functions” distinction to establish jurisdiction over
its contract claims and not merely its tort claims, our analysis is the same.

                                                  22
classification assigned under prior statute or common law,”53 and the Legislature has done so in

the Tort Claims Act. In section 101.0215 of the Act, the Legislature has provided a non-exclusive

list of municipal functions and activities that are deemed to be “governmental” functions and

not “proprietary” functions.54 As the City emphasizes, these examples include “sanitary and

storm sewers,” “dams and reservoirs,” “health and sanitation services,” “water and sewer service,”

“waterworks,” “engineering functions,” “parks and zoos,” and “recreational facilities, including but

not limited to swimming pools, beaches, and marinas.”55

                 The City urges that Carowest’s claims concern City functions that are in the same

basic nature and character as these “governmental” functions identified in the Tort Claims Act,

namely, the City’s alleged actions in connection with its provision of a new flood-control project,

wastewater treatment plant expansion, and recreational facilities. We agree. In fact, Carowest

does not directly dispute the City’s assertions. Instead, Carowest insists that the City has made an

“implied judicial admission” that Carowest’s claims implicate “proprietary” functions. As support,

Carowest points to arguments advanced by the City in regard to Carowest’s takings claim. In that

context, the City, as previously discussed, invoked the principle that an actionable taking must be

predicated on a governmental entity’s exercise of its sovereign power in acquiring or withholding

property, as opposed to the entity’s acquisition or enforcement of such rights “in the same manner

as a private citizen,” such as by contract. Carowest’s arguments are without merit.




       53
            Tex. Const. art. XI, § 13.
       54
            See Tex. Civ. Prac. & Rem. Code § 101.0215(a), (c).
       55
            Id. § 101.0215(a)(2), (9), (11), (13), (19), (23), (30), (32).

                                                    23
               For one thing, Carowest conflates two distinct and independent legal

concepts—(1) whether the City has exercised sovereign power (i.e., eminent domain or police

power) as opposed to acting “in the same manner as a private citizen” in acquiring or withholding

property, for purposes of determining whether a taking actionable under article I, section 17 of

the Texas Constitution has occurred, and (2) whether the City was performing governmental or

proprietary functions, which goes to whether governmental immunity shields the City when

performing those functions as a matter of Texas common law. Carowest reasons, in essence, that the

parameters of sovereign power for purposes of takings analysis is coextensive with the parameters

of governmental functions shielded by governmental immunity. To demonstrate the fallacy in

Carowest’s reasoning, we need only observe that municipalities routinely enter into contracts to

perform governmental functions, such that a municipality would be deemed to be acting in

its governmental capacity and thus be shielded by governmental immunity.56 In any event, any

supposed “admission” by the City that it was engaged in proprietary rather than governmental

functions would not control the scope of governmental immunity here, as this is a question of

subject-matter jurisdiction and, accordingly, cannot be waived or conferred by agreement.57

               In short, the “implied judicial admission” on which Carowest relies is not material

to, much less dispositive of, whether its claims implicate the City’s proprietary versus governmental

functions. We agree with the City that Carowest has not asserted claims predicated on anything but

governmental functions.

       56
          See, e.g., PKG Contracting, Inc., 197 S.W.3d at 389 (“[W]e conclude that the City was
acting in its governmental capacity when it contracted with [contractor] to construct a storm
drainage system.”).
       57
          Rusk, 392 S.W.3d at 95; Texas Ass’n of Bus. v. Texas Air Control Bd., 852 S.W.2d 440,
445 (Tex. 1993).

                                                 24
       “Waiver” of immunity through the City’s own actions

                Carowest has also asserted that the City wholly or partly “waived” its own

governmental immunity in three ways: (1) by “expressly consenting to suit and liability” in the Deed

and the Drainage Tract Development Agreement;58 (2) through “egregious conduct” constituting

“waiver by conduct”; and (3) by asserting affirmative claims for relief against Carowest. Carowest’s

notion that the City can unilaterally waive its governmental immunity through its own actions

traces back to the Texas Supreme Court’s now-infamous footnote in Federal Sign v. Texas Southern

University intimating that “[T]here may be . . . circumstances where the State may waive its

immunity by conduct other than simply executing a contract so that it is not always immune

from suit when it contracts.”59 But in the years since it decided Federal Sign, the high court has

clarified—and repeatedly emphasized—that it defers to the Legislature, not the actions of individual

governmental units, to determine whether, when, and how sovereign or governmental immunity

should be waived.60 In so doing, moreover, it has squarely rejected the notion that a governmental


       58
            Specifically, Carowest points to the following language in the Deed:

       [T]his Deed is valid and enforceable in a court of law and . . . both parties [i.e.,
       Carowest and the City] are (a) subject to the jurisdiction of the court and (b) subject
       to suit and liability hereon.

It relies on the following language in the Development Agreement:

       [T]his Agreement is valid and enforceable in a court of law and that both parties
       [Carowest and the City] are (a) subject to the jurisdiction of the court, (b) subject to
       suit and liability hereon, and (c) have the right to any money damages and/or legal,
       equitable and/or other contract rights they have in the event of the other party’s
       default [except for] punitive damages . . . .
       59
            951 S.W.2d 401, 408 n.1 (Tex. 1997).
       60
         See, e.g., City of Dallas v. Albert, 354 S.W.3d 368, 373-74, 379-80 (Tex. 2011); City of
Galveston, 217 S.W.3d at 471; see also Reata, 197 S.W.3d at 374-75 (observing that “there is

                                                 25
entity with authority to enter contracts, or an agent acting on its behalf, can contractually waive

immunity from suit, as Carowest insists occurred here.61 It has similarly declined repeated requests

to recognize a “waiver by conduct,”62 and has never gone further than its suggestion in Federal Sign

that such a waiver might conceivably occur under some set of facts it has not yet seen. Similarly,

in the absence of further guidance from the supreme court, this Court (at least in recent years)

has consistently rejected requests that we recognize “waivers by conduct” under a variety of

factual scenarios.63

                If this notion of “waiver” of immunity “by conduct” has any current viability, it

has lived on within the rubric not of whether sovereign or governmental immunity has been

waived, per se, but in the threshold determination of whether immunity applies in the first place.

Although it defers to the Legislature to determine when and how immunity should be waived, the

Texas Supreme Court has explained that the applicability and parameters of immunity in the first



tension between the concept of a governmental entity waiving its immunity from suit by some action
independent from the Legislature’s waiving immunity and the principle that only the Legislature can
waive sovereign immunity . . . [and] tension between the concept of a governmental entity waiving
its immunity from suit and the principle that a court’s lack of subject-matter jurisdiction generally
cannot be waived.” (citing Federal Underwriters Exch. v. Pugh, 174 S.W.2d 598, 600 (Tex. 1943);
IT-Davy, 74 S.W.3d at 853)).
       61
            See IT-Davy, 74 S.W.3d at 857-58.
       62
             See, e.g., Sharyland Water Supply Corp. v. City of Alton, 354 S.W.3d 407, 414
(Tex. 2011); Koseoglu, 233 S.W.3d at 840; Catalina Dev., Inc. v. County of El Paso, 121 S.W.3d
704, 706 (Tex. 2003); IT-Davy, 74 S.W.3d at 857 (“Creating a waiver-by-conduct exception would
force the State to expend its resources to litigate the waiver-by-conduct issue before enjoying
sovereign immunity’s protections—and this would defeat many of the doctrine’s underlying
policies.”).
       63
          See, e.g., Employees Retirement Sys. of Tex. v. Putnam, LLC, 294 S.W.3d 309, 327
(Tex. App.—Austin 2009, no pet.); Smith v. Lutz, 149 S.W.3d 752, 761 (Tex. App.—Austin 2004,
no pet.).

                                                 26
instance remain a matter of the common law and, thus, squarely within judicial rather than legislative

prerogatives.64 Consistent with these principles, the Texas Supreme Court has come to analyze so-

called “waiver-by-conduct” issues as factors in an analysis of whether it should alter, as a matter of

the common law, the contours or boundaries of immunity in particular situations.65

                Only one of Carowest’s theories of “waiver” or avoidance of governmental

immunity based on the City’s unilateral actions implicates a common-law modification or abrogation

of immunity heretofore recognized by the Texas Supreme Court. That lone theory is Carowest’s

assertion that governmental immunity does not bar its contract and tort claims because the City

has asserted its own affirmative claims for relief. In instances where a “governmental entity has

joined into the litigation process by asserting its own affirmative claims for monetary relief,” the

Texas Supreme Court has explained, the entity “leave[s] its sphere of immunity from suit” with

respect to monetary claims against it, asserted as offsets, that are “germane to, connected with, and

properly defensive to” its affirmative claims.66 The supreme court has reasoned that such a claim

against a governmental entity would not implicate the fiscal concerns underlying the immunity

doctrines, considering that “the governmental entity . . . will presumably have made a decision to

expend resources to pay litigation costs” and that any recovery would merely offset the entity’s



       64
          See Albert, 354 S.W.3d at 374 (“[W]e have not . . . altered the principles that (1) the
boundaries of sovereign immunity are determined by the judiciary, and (2) waivers of sovereign
immunity . . . must generally be found in actions of the Legislature.” (citing City of Galveston,
217 S.W.3d at 468, 471)).
       65
         See id. at 374 (explaining that “prior decisions . . . including [Catalina Dev., Inc.,
121 S.W.3d at 705-06], in which we discussed the possibility that a governmental entity might waive
its immunity by conduct,” addressed a limited abrogation of “the common law doctrine of
governmental immunity”) (emphasis added).
       66
            Reata, 197 S.W.3d at 376-77.

                                                 27
recovery and not impact the “tax resources . . . [or] fiscal planning of the governmental entity.”67

As further justification, the court has added that “it would be fundamentally unfair to allow [the]

governmental entity to assert affirmative claims against a party while claiming it had immunity as

to the party’s claims against it.”68 But this modification of immunity and its underlying rationales,

the supreme court has emphasized, do not extend to claims for damages in excess of the amount

necessary to offset the governmental entity’s recovery,69 nor to claims that are not “germane to,

connected with, and properly defensive to those asserted by the governmental entity,” and the

governmental entity remains shielded by immunity to that extent.70

                  The City disputes that this jurisdictional theory has any application here. It first

argues that Carowest failed to properly raise the theory because it did not explicitly plead it in its live

petition. However, the City’s arguments rest on authority involving statutory waivers of immunity,

and whatever merit the City’s argument might have in that context, the issue here is instead

the substantive scope of immunity in the first instance.71 In any event, facts, not recitations of legal

conclusions, are what matters in determining whether Carowest has invoked the district court’s




        67
             Id. at 375.
        68
             Id. at 375-76.
        69
             See id. at 376-77.
        70
          See City of Irving v. Inform Constr., Inc., 201 S.W.3d 693, 693-94 (Tex. 2006)
(per curiam).
        71
             The City relies on Texas Department of Transportation v. Jones, 8 S.W.3d 636
(Tex. 1999) (per curiam), which involved a claim asserted under the Tort Claims Act. We note that
Jones concerned not the sufficiency of the claimant’s pleadings of the statutory waiver, but whether
the court of appeals had erred in holding that sovereign immunity was not a jurisdictional bar to suit
that could be raised through a plea to the jurisdiction. See id. at 637-39.

                                                    28
subject-matter jurisdiction,72 and the fact that the City had asserted claims for affirmative relief is

conclusively established by the copy of its live counterclaims that appears in the clerk’s record.73

We reject, in other words, the City’s notion that Carowest cannot rely on this jurisdictional theory

because Carowest did not file a pleading reciting that the City had filed a pleading asserting its

affirmative claims.

                Similarly, the City suggests that the timing of the parties’ respective claims has

some impact on the application of this jurisdictional theory, emphasizing that Carowest filed

some of its monetary claims after the City filed its counterclaims. The Texas Supreme Court has

squarely rejected that notion.74 The City further argues that its counterclaims do not implicate this

jurisdictional theory because (1) the theory operates only when a governmental entity asserts claims

for money damages, and (2) although the City asserted a counterclaim for money damages, that

claim is styled as an alternative to the City’s claims for specific enforcement of the Deed and

declaratory claims regarding the legal status of the Recreational Easement and the Drainage Channel

Easement. The City is correct to the extent the Texas Supreme Court, to date, has not extended

this jurisdictional theory to governmental claims seeking declaratory or equitable relief, as opposed




       72
            See Bacon, 411 S.W.3d at 171; Creedmoor-Maha, 307 S.W.3d at 513, 516 & n.8.
       73
           See Texas Real Estate Comm’n v. Nagle, 767 S.W.2d 691, 694 (Tex. 1989) (explaining
that court can take judicial notice of its own file).
       74
          See Inform Constr., Inc., 201 S.W.3d at 694 (governmental unit’s affirmative claims were
in form of a counterclaim, and whether counterclaim was compulsory or permissive did not impact
the analysis); Reata, 197 S.W.3d at 377 (affirmative claims were in form of intervention; noting that
“we see no substantive difference between a decision by the City to file an original suit and the
City’s decision to file its claim as an intervenor”).

                                                  29
to monetary relief.75 But it remains that the City did assert a claim seeking affirmative monetary

relief—over $840,000 in damages, in fact—based on Carowest’s alleged breach of the Letter

Agreement and related agreements. In so doing, the City has left its “sphere of immunity from suit”

to the extent of offsetting claims by Carowest that are “germane to, connected with, and properly

defensive” to the City’s monetary claim. The fact that the City asserts its monetary claim in the

alternative is relevant to, at most, whether the City will ultimately recover under that claim as the

litigation progresses. If the City ultimately does not recover on its monetary claim because it elects

its declaratory or equitable remedy instead (or, for that matter, because it nonsuits the claim or the

district court rules adversely on it), the effect, as the Texas Supreme Court has explained, would

merely be that Carowest “could not prevail on [its] claims because [it] could not recover a judgment

for damages,” as there would be no monetary award to the City against which Carowest’s award

could be offset.76 It is thus an issue that goes to the merits of Carowest’s offsetting claims, and does

not alter the scope of the district court’s limited jurisdiction to adjudicate those claims that arises by

virtue of the City’s assertion of its monetary claim.77




        75
            See Sharyland, 354 S.W.3d at 413-14 (assuming without deciding that immunity would
not bar offset claims against governmental entity based on declaratory counterclaim that would have
the effect of rescinding conveyance of property, and deciding claims on different ground); but see
Manbeck v. Austin Indep. Sch. Dist., 381 S.W.3d 528, 532-33 (Tex. 2012) (holding that principle
did not apply to governmental entity’s suit for judicial review from workers’ compensation decision;
observing that entity “never brought an affirmative claim for money damages against which [the
private litigant’s] claims could be offset.”).
        76
             Albert, 354 S.W.3d at 376.
        77
           See id.; see also Bland Indep. Sch. Dist. v. Blue, 34 S.W.3d 547, 554 (Tex. 2000)
(emphasizing that courts deciding pleas to the jurisdiction should not unnecessarily delve into the
merits). Similarly inapposite is considerable briefing the City devotes to attacking the merits of each
of Carowest’s common-law tort claims.

                                                   30
               The controlling inquiry, in other words, boils down solely to whether Carowest’s

breach-of-contract and common-law tort claims are “germane to, connected with, and properly

defensive” to the City’s monetary claim, so as to fall within the district court’s limited jurisdiction

to adjudicate such claims to the extent of offsetting any recovery by the City. The Texas Supreme

Court has equated “germane to” with “relevant to.”78 While the court has not yet delineated the

precise parameters of “connected with” in this context, claims that share common or related

core underlying facts appear to qualify.79 Similarly, a “properly defensive” claim appears to include,

at a minimum, one that would directly or inferentially rebut the facts on which the governmental

entity’s claim is predicated.80 Some of our sister courts, along with at least one respected

commentator, have further suggested that a claim that would be a compulsory counterclaim to the

governmental entity’s claim—i.e., it arises out of the same “transaction or occurrence” that is the




       78
          See Albert, 354 S.W.3d at 375 (citing Black’s Law Dictionary 756 (9th ed. 2009) (defining
“germane” as “relevant, pertinent”); see also Sweeny Cmty. Hosp. v. Mendez, 226 S.W.3d 584, 592
(Tex. App.—Houston [1st Dist.] 2007, no pet.) (observing that term “germane” generally means
“closely akin,” “being at once relevant and appropriate,” “closely or significantly related,”
“relevant,” and “pertinent” (citing Merriam-Webster’s Collegiate Dictionary 525 (11th ed. 2003);
Random House Webster’s Unabridged Dictionary 800 (2d ed. 2001))).
       79
            See Albert, 354 S.W.3d at 375 (claims “clearly were germane to . . . and connected with”
governmental entity’s claim where “they were both based on the question of pay for the Officers’
employment.”); see also Mendez, 226 S.W.3d at 592 (observing that, in common usage, “connected”
means “united, joined, or linked” and “joined together in sequence; linked coherently” and “having
parts or elements logically linked together” (citing Merriam-Webster’s Collegiate Dictionary at 525;
Random House Webster’s Unabridged Dictionary at 800)).
       80
           See Albert, 354 S.W.3d at 375 (“[T]he Officers’ claims were properly defensive to the
City’s counterclaim because a finding that an officer had been underpaid would at least inferentially
rebut the City’s claim that the officer had been paid correctly or overpaid for the particular period
for which the underpayment was made.”).

                                                  31
subject matter of the government’s claim81—would necessarily qualify as one that is “germane to,”

“connected with,” and/or “properly defensive” to it.82

                Each of Carowest’s claims at issue must independently be “germane to, connected

with, and properly defensive” to the City’s monetary claim in order for it to fall within the

district court’s limited jurisdiction.83   Nonetheless, Carowest’s claims can be conveniently

categorized into three groups for purposes of analysis: (1) its breach-of-contract claims; (2) its

tort claims arising from the City’s alleged conduct following execution of the Letter Agreement,

including its actions in relation to the Yantis delay claim; and (3) its tort claims centering on, and

seeking recovery for, the fill removed from the Original Channel Tract in May 2009.

                The core contention underlying the City’s claim for monetary relief is that

Carowest breached the Letter Agreement and related agreements by “revoking the Drainage Channel

Easement, revoking the Recreation Easement, and refusing to close on the sale of the NBU

expansion tract.” To prevail on this theory, the City must prove, among other operative facts, that

it performed its own obligations under these agreements,84 and it accordingly alleges that “it


       81
            Tex. R. Civ. P. 97(a).
       82
           See Harris Cnty. v. Luna-Prudencio, 294 S.W.3d 690, 697 (Tex. App.—Houston
[1st Dist.] 2009, no pet.); Mendez, 226 S.W.3d at 592-93; William V. Dorsaneo III, et. al,
Texas Litigation Guide § 293.01[1A] (2013) (citing these cases and concluding that “[a] defendant’s
compulsory counterclaim to a governmental unit’s affirmative claim for relief necessarily
qualifies under Reata as a claim that is germane to, connected with, and properly defensive to the
governmental entity’s claims.”); see also City of Dallas v. Redbird Dev. Corp., 143 S.W.3d 375, 383
(Tex. App.—Dallas 2004, no pet.).
       83
           See State v. Fidelity & Deposit Co. of Md., 223 S.W.3d 309, 311 (Tex. 2007) (per curiam)
(“In light of Reata, a court must . . . specify the claims” that arise from the governmental entity’s
affirmative claims).
       84
         See C.W. 100 Louis Henna, Ltd. v. El Chico Rests. of Tex., L.P., 295 S.W.3d 748, 752
(Tex. App.—Austin 2009, no pet.) (to prevail on cause of action for breach of contract, claimant

                                                 32
complied with its obligations under the agreements . . . [and] has not committed any material breach

of the Agreements.” Carowest’s breach-of-contract claims are essentially the converse of the City’s

contract claim, asserting that Carowest fully performed its obligations under the Letter Agreement

and related agreements and that it was the City that failed to perform and materially breached

its obligations. Carowest’s contract claims are thus “germane to, connected with, and properly

defensive to” the City’s contract claim.85 The same would be true of Carowest’s claim for attorney’s

fees incident to this breach-of-contract claim, to the extent they are otherwise recoverable.86

               We reach the same conclusion regarding Carowest’s tort claims predicated on

alleged conduct by the City occurring after the execution of the Letter Agreement. As a threshold

observation, the fact that Carowest’s claims sound in tort rather than contract does not in itself mean

that they cannot be “germane to, connected with, and properly defensive to” the City’s contract

claim, as the inquiry’s proper focus is on the operative facts rather than the particular legal theories



must prove that: (1) a valid contract existed between parties; (2) the claimant performed or tendered
performance; (3) the defendant breached the contract; and (4) the claimant was damaged as result
of breach); see also Lennar Corp. v. Markel Am. Ins. Co., 413 S.W.3d 750, 755 n.28 (Tex. 2013) (“A
fundamental principle of contract law is that when one party to a contract commits a material breach
of that contract, the other party is discharged or excused from any obligation to perform.” (quoting
Hernandez v. Gulf Grp. Lloyds, 875 S.W.2d 691, 692 (Tex. 1994))).
       85
            See Albert, 354 S.W.3d at 375; see also Redbird, 143 S.W.3d at 383 (holding that claim
of breach of lease was “incident to, connected with, arises out of, or is germane to” city’s claim for
unpaid rent and late charges because both parties’ claim arose from the lease and “resolution of the
rights of the parties [depended] on facts pertinent to the parties’ conduct regarding the same lease”).
       86
          See City of San Antonio v. KGME, Inc., 340 S.W.3d 870, 878 (Tex. App.—San Antonio
2011, no pet.) (construction company’s claims for attorney’s fees and interest under Texas Prompt
Pay Act were “germane to, connected with and properly defensive to” municipality’s claim of breach
of contract); see also Kinnear v. Texas Comm’n on Human Rights, 14 S.W.3d 299, 300 (Tex. 2000)
(per curiam) (explaining that because Commission had initiated proceeding under Fair Housing Act,
and “Kinnear claimed attorney fees as a consequence of that suit,” trial court had jurisdiction over
claim for attorney’s fees).

                                                  33
asserted.87 Turning to that inquiry, the chief focus of these tort claims, which are styled in terms of

“fraud,” “breach of fiduciary duty,” and “conspiracy” to commit fraud, is the City’s alleged efforts

to conceal or mislead Carowest as to the true status of Yantis’s delay claim while purporting to

enforce Carowest’s obligations under the Letter Agreement to indemnify the City against that claim.

These claims will thus require determination of whether Carowest had a duty to indemnify the

City against the Yantis delay claim at the time the City was making its indemnification demands.

Consequently, these tort claims, like Carowest’s contract claims, implicate the same core operative

facts underlying the City’s monetary claim—namely, whether the City and Carowest complied with

their respective obligations under the Letter Agreement and related agreements—and proof that

Carowest complied, the City did not, or both would inferentially rebut the City’s claim. The same

would be true to the extent Carowest’s claims complain of any additional conduct by the City that

would amount to a breach of the City’s contractual obligations or a defense to Carowest’s asserted

failure to perform.88 In these ways, Carowest’s tort claims addressing alleged conduct by the City

occurring after the execution of the Letter Agreement are “germane to, connected with, and properly

defensive to” the City’s contract claim.89

                The third and final category of Carowest’s claims at issue—its tort claims seeking to

recover the value of the fill removed from the Original Channel Tract—presents a closer question

at first glance. These claims center on Carowest’s asserted right to receive the fill from the Original


       87
           See Mendez, 226 S.W.3d at 592-93 (physician’s claims for tortious interference,
defamation, and retaliation were germane to, connected with, and properly defensive to government
hospital’s claim for breach of employment contract).
       88
            See Mendez, 226 S.W.3d at 592-93.
       89
           See Albert, 354 S.W.3d at 375. Of course, we are expressing no opinion as to whether
such tort (or “con-tort”) theories would ultimately be viable on the merits.

                                                  34
Channel Tract and the City’s alleged efforts to deprive it of that right. The parties’ disputes about

this fill were among the “issues related to The South Tributary Project” that were “resolve[d],” i.e.,

settled, by the Letter Agreement. In other words, in asserting claims predicated on both the City’s

alleged breach of the Letter Agreement and the City’s deprivation of the Original Channel Tract fill,

Carowest seeks recovery under both a settlement agreement and some of the claims that underlie

and were superseded by the agreement. These are separate sets of claims,90 and Carowest could

recover under one set of claims without proving the other. In fact, the theories would be logically

inconsistent with one another, as one theory relies on the Letter Agreement while the other presumes

it is ineffective. However, both sets of claims arise from the same “transaction” or “occurrence,”

to the extent the City’s removal of the Original Channel Tract fill was a basis for the Letter

Agreement.91 As noted, there is authority from our sister courts for holding, on this basis alone,

that Carowest’s claims based on deprivation of the Original Channel Tract fill are “germane to,

connected with, and properly defensive to” the City’s contract claims.92 In these ways, we believe,

the City left “its sphere of immunity from suit” as to Carowest’s underlying claims for deprivation

of the Original Channel Tract fill to the same extent as with Carowest’s claims under the Letter

Agreement.



       90
          See, e.g., Mantas v. Fifth Court of Appeals, 925 S.W.3d 656, 658-59 (Tex. 1996)
(per curiam) (citing Padilla v. LaFrance, 907 S.W.2d 454, 461-62 (Tex. 1995)).
       91
          See Lexington Ins. Co. v. Daybreak Express, Inc., 393 S.W.3d 242, 244-45 (Tex. 2013)
(per curiam).
       92
           See KGME, 340 S.W.3d at 877 (noting that construction company’s claim and city’s
counterclaim “arise from the same facts and controversy” and concluding that company’s breach of
contract claim was “germane to, connected with, and properly defensive to” city’s breach of contract
claim); Luna-Prudencio, 294 S.W.3d at 697; Mendez, 226 S.W.3d at 592-93; see also Redbird,
143 S.W.3d at 383.

                                                 35
                  In sum, we hold that each of Carowest’s common-law claims for money damages,

as well as its claims for any attorney’s fees recoverable incident to its breach-of-contract claims, is

“germane to, connected with, and properly defensive to” the City’s monetary claim, such that these

claims do not implicate the City’s governmental immunity to the extent of seeking a recovery

offsetting any by the City.93 To this extent, the district court possesses subject-matter to adjudicate

these claims.94


       Local Government Code chapter 271, subchapter I

                  In light of the limited nature of the district court’s jurisdiction that exists by

virtue of the City’s affirmative monetary claim, we must proceed to address another theory advanced

by Carowest that would establish an alternative basis of subject-matter jurisdiction over some

of its common-law monetary claims. Carowest invokes subchapter I of chapter 271 of the

Local Government Code, which specifies that when a “local governmental entity” (which includes

municipalities95 ) enters into “a contract subject to this subchapter,” it “waives sovereign immunity

to suit for the purpose of adjudicating a claim for breach of the contract, subject to the terms

and conditions of this subchapter.”96 A “contract subject to this subchapter” is defined as “a written


       93
            See Fid. & Deposit Co., 223 S.W.3d at 311.
       94
           See Reata, 197 S.W.3d at 377 (“[T]he City continues to have immunity from affirmative
damage claims against it for monetary relief exceeding amounts necessary to offset the
City’s claims.”); see also City of Angleton v. USFilter Operating Servs., Inc., 201 S.W.3d 677, 678
(Tex. 2006) (per curiam) (error to hold that governmental entity’s affirmative claim resulted in
complete loss of its immunity).
       95
            See Tex. Loc. Gov’t Code § 271.151(3)(A).
       96
            Id. § 271.152. As is apparent from context, “sovereign immunity” as used by the
Legislature in subchapter I would necessarily refer to and include governmental immunity, which,
again, is the derivative or version of sovereign immunity that applies to local governmental entities.

                                                  36
contract stating the essential terms of the agreement for providing goods or services to the local

governmental entity that is properly executed on behalf of the local governmental entity.”97

“Adjudication” explicitly includes “the bringing of a civil suit and prosecution to final judgment.”98

The subchapter’s “terms and conditions” on the waiver of immunity limit the monetary award in an

“adjudication brought against a local governmental entity for breach of a contract” solely to:


•      “[T]he balance due and owed by the local governmental entity under the contract . . .
       including any amount owed as compensation for the increased cost to perform the work as
       a direct result of owner-caused delays or acceleration.”

•      “[T]he amount owed for change orders or additional work the contractor is directed to
       perform by a local governmental entity in connection with the contract.”

•      “[R]easonable and necessary attorney’s fees that are equitable and just.”

•      [I]nterest as allowed by law.”99


Further, subchapter I does not waive immunity as to consequential damages (other than those

explicitly permitted by the foregoing provisions),100 exemplary damages,101 or “a cause of action for

a negligent or intentional tort,”102 nor does it waive defenses to liability (as opposed to immunity




       97
             Id. § 271.151(2)(A).
       98
             Id. § 271.151(1).
       99
             Id. § 271.153(a).
       100
             Id. § 271.153(b)(1).
       101
             Id. § 271.153(b)(2).
       102
             Id. § 271.157.

                                                 37
from suit).103 The Texas Supreme Court has recognized that subchapter I suffices as a “clear” and

“unambiguous” waiver of governmental immunity to the extent that statute prescribes.104

                  Carowest relies on subchapter I to establish the district court’s jurisdiction solely over

its breach-of-contract claims. In response, the City seems to acknowledge that the agreements

made the basis for Carowest’s breach-of-contract claims are “contracts subject to” subchapter I,105

but questions whether Carowest sufficiently pleads claims within the statute’s waiver. The City also

emphasizes that subchapter I does not waive its immunity as to claims other than Carowest’s breach-

of-contract claims (a proposition that Carowest does not appear to dispute) and that the waiver does

not extend to the full range of damages that might conceivably be recoverable under such a theory,

such as consequential damages. We conclude that Carowest’s contract claims have invoked the

district court’s subject-matter jurisdiction, via subchapter I, to the extent of seeking recovery of the

damages and attorney’s fees for which the statute waives immunity.

                  The agreements on which Carowest’s breach-of-contract claims are predicated,

principally the Letter Agreement, Drainage Tract Development Agreement, and the Deed, all of

which are in evidence, are each in writing, state their essential terms, and were properly executed on




        103
              Id. § 271.155.
       104
            See Ben Bolt-Palito Blanco Consol. Indep. Sch. Dist. v. Texas Political Subdiv.
Prop./Cas. Joint Self-Ins. Fund, 212 S.W.3d 320, 327 (Tex. 2006).
       105
            The City acknowledges that, in one of its filings below, it purported to “agree[] to be
bound by the provisions of Chapter 271 of the Local Government Code,” which, it observed,
“provides for a waiver of immunity with regard to breach of contract claims under specific
circumstances and specifically addresses the damages that a plaintiff may recover.” Of course,
it is the Legislature, not the City, that decides whether the City is “bound by the provisions of
Chapter 271,” but the thrust of the City’s statement, considered in context, seems to acknowledge
that the contracts at issue fall within subchapter I.

                                                     38
the City’s behalf.106 The Letter Agreement and Drainage Tract Development Agreement are also

plainly agreements “for providing goods or services” to the City107—namely, the construction of

drainage improvement on Carowest’s property.108 And while the Deed in itself concerns a real

estate conveyance rather than “goods or services” as ordinarily understood, it is a component of the

Letter Agreement, which is in part a contract “for providing goods and services” to the City, and

the Legislature did not require that provision of “goods and services” be the exclusive or even

primary purpose of the contract in order to come within subchapter I.109 Accordingly, we conclude

that the district court has subject-matter jurisdiction to adjudicate Carowest’s breach-of-contract

claims, including its related claims for attorney’s fees, to the extent of the recoveries permitted by

subchapter I.


       Conclusion regarding Carowest’s common-law monetary claims

                 Carowest has not invoked any further statutory waivers of the City’s governmental

immunity, or means of avoiding it, that would establish the district court’s jurisdiction over any

common-law monetary claims not already within its jurisdiction by virtue of Local Government


       106
             See Tex. Loc. Gov’t Code § 271.151(2)(A).
       107
             See id.
       108
           See, e.g., Kirby Lake Dev. Ltd. v. Clear Lake City Water Auth., 320 S.W.3d 829, 839
(Tex. 2010) (holding that contract for developers to construct water and sewer facilities and then
lease them to city free of charge was contract for “services” under subchapter I).
       109
            See id. (explaining that “the term [services] is broad enough to encompass a wide array
of activities” and “[t]he services provided . . . need not be the primary purpose of the agreement”);
see also City of Houston v. Williams, 353 S.W.3d 128, 138 (Tex. 2011) (noting that written contracts
may be embodied in more than one document); see also City of North Richland Hills v. Home Town
Urban Partners, Ltd., 340 S.W.3d 900, 907 (Tex. App.—Fort Worth 2011, no pet.) (rejecting
argument that development agreement with city was “merely a conveyance of real property” because
it also required appellees to provide various services to city).

                                                 39
Code chapter 271, subsection I.110 Consequently, we hold that the district court did not err in

overruling the City’s plea to the jurisdiction with respect to Carowest’s breach-of-contract

claims to the extent Carowest seeks recovery of damages and attorney’s fees within the waiver

of governmental immunity provided by subsection I. Additionally, the City’s affirmative monetary

claims give rise to an alternative and independent basis for jurisdiction to adjudicate both Carowest’s

contract and tort claims, to the extent of awarding damages as an offset to any recovery by the City.


Declaratory claims

               The parties also join issue as to whether the district court possesses subject-matter

jurisdiction over Carowest’s declaratory claims. The UDJA permits “[a] person interested under a


       110
            For example, Carowest does not purport to rely on the waivers in the Tort Claims Act.
However, as an additional independent basis for the district court’s jurisdiction over its breach-of-
contract claim concerning the City’s payment for the NBU expansion property, Carowest relies on
the principle, recognized in the Texas Supreme Court’s plurality opinion in Texas A&M University-
Kingsville v. Lawson, that a governmental entity is not immune from suit for breaching a settlement
agreement that resolved an underlying claim against which the government was not immune.
87 S.W.3d 518, 521-23 (Tex. 2002) (plurality op.). Carowest emphasizes that the City, as previously
explained, has no immunity against any claims for compensation based on its acquisition or “taking”
of private property for public use through the exercise of its sovereign power and that the Letter
Agreement, in part, explicitly “resolve[d] prior discussions concerning possible condemnation of
Carowest Property for NBU purposes” through Carowest’s agreement to sell the City “approximately
six (6) acres of Carowest Property primarily for use in a[n] NBU future expansion.” The Deed,
which explicitly incorporated the terms of the Letter Agreement, subsequently effectuated this
conveyance. On similar facts, the Fort Worth Court of Appeals, relying on the Lawson rationale,
and over a dissent, held that governmental immunity did not shield a municipality against claims for
breach of a contract whereby the plaintiffs had conveyed property to a city in lieu of the
city acquiring it through eminent domain. See City of Carrollton v. Singer, 232 S.W.3d 790, 796-
800 (Tex. App.—Fort Worth 2007, pet. denied); cf. id. at 800-04 (Cayce, C.J., dissenting). The City
urges that Singer is wrongly decided. We need not reach these contentions under the circumstances
here. See Tex. R. App. P. 47.1. We have already concluded that Carowest’s breach-of-contract
claims come within the waiver of immunity in subchapter I and, further, we conclude that this waiver
permits Carowest to recover the damages it seeks for breach of the City’s obligation to pay it the
purchase price of the Deed, the “balance due and owed by the local governmental entity under the
contract.” Tex. Loc. Gov’t Code § 271.153(a)(1).

                                                  40
deed, will, written contract, or other writings constituting a contract or whose rights, status, or

other legal relations are affected by a statute, municipal ordinance, contract, or franchise [to] have

determined any question of construction or validity arising under the instrument, statute, ordinance,

contract, or franchise and obtain a declaration of rights, status, or other legal relations thereunder.”111

To that end, the UDJA also provides a waiver of sovereign or governmental immunity, but it is

limited in scope to certain declaratory claims against governmental entities challenging the validity

of legislative enactments, including declaratory claims against municipalities concerning “the

validity of a municipal ordinance or franchise.”112 Otherwise, the UDJA does not alter the scope

of a trial court’s jurisdiction, but is “‘merely a procedural device for deciding cases already within

a court’s jurisdiction.’”113 Consequently, a UDJA declaratory claim asserted directly against a

governmental entity, like other types of claims, will ordinarily be barred by immunity, thereby

divesting the trial court of jurisdiction, unless the Legislature has waived immunity as to the subject

matter of the claim.114 Furthermore, “a litigant’s couching its requested relief in terms of declaratory

relief does not alter the underlying nature of the suit,”115 such that a UDJA claim that might



        111
              Tex. Civ. Prac. & Rem. Code § 37.004(a).
        112
           See id. § 37.006(b) (“In any proceeding that involves the validity of a municipal ordinance
or franchise, the municipality must be made a party . . . .”).
        113
          Sawyer Trust, 354 S.W.3d at 388 (quoting Texas Ass’n of Bus., 852 S.W.2d at 444); IT-
Davy, 74 S.W.3d at 855.
        114
             Sefzik, 355 S.W.3d at 622; cf. Heinrich, 284 S.W.3d at 371-72 (explaining “ultra-vires
exception” to sovereign or governmental immunity, whereby a claimant can sue a governmental
official, in his or her official capacity, to compel the governmental entity, through its agent, to
comply with non-discretionary delegated authority or duty).
        115
          Sawyer Trust, 354 S.W.3d at 388 (citing Heinrich, 284 S.W.3d at 370-71; IT-Davy,
74 S.W.3d at 855).

                                                    41
otherwise be permissibly asserted against a governmental defendant will still be independently

barred by immunity if it “has the effect of establishing a right to relief against [a governmental entity]

for which the Legislature has not waived . . . immunity,” like retrospective monetary relief or

contractual liability.116

                Through its declaratory claims, Carowest seeks determination of three sets of

“question[s] of construction or validity arising under [an] instrument, statute, ordinance, contract, or

franchise” that are within the UDJA’s general scope: (1) whether the City violated the Texas Open

Meetings Act during City Council meetings in May 2009 and May 2011; (2) the validity of the City

contract under which Yantis was to construct the North Tributary Project; and (3) the validity of

the Yantis delay claim or claims as they bear upon the parties’ respective indemnification rights

and duties under the Letter Agreement. The City has argued principally that these declaratory claims

are barred by its governmental immunity because they are asserted against it directly, would have

the further effect of establishing its liability under contracts, for damages, or both, and do not

come within any waiver of that immunity.117 In response, Carowest has not disputed that its claims,

asserted as they are against the City, would implicate the City’s governmental immunity, all

        116
            Id. (citing City of Houston v. Williams, 216 S.W.3d 827, 828-29 (Tex. 2007)
(per curiam)); Creedmoor-Maha, 307 S.W.3d at 515.
        117
            See, e.g., Williams, 216 S.W.3d at 828-29 (governmental immunity bars declaratory
claim that would have the effect of awarding retrospective monetary relief against governmental
entity); IT-Davy, 74 S.W.3d at 860 (immunity bars declaratory claim that would effectively impose
contractual liability on governmental entity).

         The City also seems to accuse Carowest of explicitly seeking to recover money damages
under the UDJA, emphasizing the portions of Carowest’s live petition in which it prays,
with reference to all of its liability theories, for money damages. Carowest responds that the City
is simply confused as to the content of its pleadings. We agree that Carowest’s pleading cannot
properly be construed as seeking monetary relief under the UDJA. See, e.g., Miranda, 133 S.W.3d
at 226 (we are to construe pleadings liberally in favor of jurisdiction).

                                                   42
other things being equal, nor has it purported to rely upon the UDJA’s limited waiver

permitting declaratory claims challenging the validity of municipal ordinances or franchises. Instead,

Carowest has insisted that the subject matter of each of its declaratory claims is already within the

district court’s jurisdiction by virtue of various statutory waivers of immunity that are independent

of and external to the UDJA. We consider these jurisdictional theories in turn.


       Open Meetings Act

                 To establish the district court’s jurisdiction over its declaratory claims concerning

alleged violations of the Texas Open Meetings Act (OMA), Carowest has relied upon an express

waiver of immunity found within OMA. Specifically, OMA provides that “[a]n action taken by a

governmental body in violation of [OMA] is voidable,”118 and creates a cause of action whereby

“[a]n interested person . . . may bring an action by mandamus or injunction to stop, prevent, or

reverse a violation or threatened violation of [OMA] by members of a governmental body.”119

Carowest asserts, and we agree, that the substance of Carowest’s declaratory claims regarding

alleged OMA violations by the City fall squarely within this waiver. Carowest alleges that the City

Council convened in executive sessions to discuss “public issues” and to “conceal[] the North

Tributary Deal’s quid pro quo arrangement between the City and Yantis,” in derogation of OMA’s

requirement that “[e]very regular, special, or called meeting of a governmental body shall be open

to the public.”120 Based on these allegations, Carowest seeks declarations that the City violated

OMA, the effect of which would be to “reverse” the violations by rendering the related City actions


       118
             Tex. Gov’t Code § 551.141.
       119
             Id. § 551.142(a).
       120
             See id. § 551.002.

                                                  43
void. The fact that Carowest has sought the remedy of declaratory rather than equitable relief does

not change the jurisdictional analysis here.121

                In attempting to persuade us that the district court lacks jurisdiction over these claims,

the City insists that Carowest’s pleadings do not adequately negate the applicability of OMA’s

exceptions allowing governmental bodies to convene in executive session. The City’s insistence on

such specificity appears to be grounded on a misunderstanding that Carowest is relying (or can

only rely) on the “ultra vires” exception to immunity to establish the district court’s jurisdiction, an

analysis that may indeed turn on whether alleged governmental actions would, as a matter of law,

actually exceed lawful delegated authority.122 But Carowest relies not on the “ultra vires” exception

to the City’s governmental immunity, but on OMA’s express waiver of immunity, which requires

only that Carowest bring an action seeking to reverse a violation or threatened violation of OMA,

and Carowest’s claims are plainly of this character. In that context, in short, the City’s arguments



       121
            See Texas State Bd. of Veterinary Med. Exam’rs v. Giggleman, 408 S.W.3d 696, 708
(Tex. App.—Austin 2013, no pet.) (observing that cause of action and waiver of immunity in the
Public Information Act parallel to that in OMA could provide “a jurisdictional basis” for UDJA
claims challenging withholding of information in alleged violation of the PIA); Hendee, 228 S.W.3d
at 379 n.31 (noting that if plaintiffs had standing under taxpayer exception to seek injunction to
prevent expenditures, then UDJA would also allow them to bring claim for declaratory relief);
but cf. Jackson v. State Office of Admin. Hearings, 351 S.W.3d 290, 301 (Tex. 2011) (illustrating
limitations on use of UDJA to recover attorney’s fees not obtainable though the underlying statutory
waiver that confers jurisdiction on the trial court).
       122
           See Heinrich, 284 S.W.3d at 372-73 (ultra vires suit “must not complain of a government
officer’s exercise of discretion, but rather must allege, and ultimately prove, that the officer
acted without legal authority or failed to perform a purely ministerial act”); Texas Dep’t of Transp.
v. Sunset Transp., 357 S.W.3d 691, 701-02 (Tex. App.—Austin 2011, pet. denied) (“To determine
whether appellees have asserted a valid ultra vires claim that invokes the district court’s subject-
matter jurisdiction, we would construe the provisions of the [statutes] that define the scope of [the
agency’s] legal authority, apply them to the facts that appellees have alleged, and ascertain whether
those facts constitute acts beyond [the agency’s] legal authority.” (citing Heinrich, 284 S.W.3d
at 372-73; Creedmoor-Maha, 307 S.W.3d at 516 n.8)).

                                                   44
implicate only the merits of Carowest’s claims, not the district court’s jurisdiction to decide them.123

Accordingly, the district court did not err in overruling the City’s plea as to Carowest’s declaratory

claims regarding OMA violations.


        Local Government Code chapter 252

                With respect to Carowest’s declaratory claim challenging the City’s contract with

Yantis on the North Tributary Project, it relies on an express waiver of immunity found within

chapter 252 of the Local Government Code. Chapter 252, entitled “Purchasing and Contracting

Authority of Municipalities,” imposes competitive-bidding requirements for certain purchases

made by municipalities.124 “If [a] contract is made without compliance with this chapter,”

chapter 252 further provides, “it is void, and the performance of the contract, including the payment

of any money under the contract, may be enjoined by” persons that include, of relevance here, “any

property tax paying resident of the municipality.”125

                Similar to its claims concerning OMA violations, Carowest asserts a declaratory

claim whose subject matter would fall squarely within chapter 252’s waiver of governmental

immunity—it seeks a declaration that the City violated chapter 252 in regard to the North Tributary

Contract, thereby rendering that contract void and unenforceable.126 The City advances no cogent


       123
             See Sunset Transp., 357 S.W.3d at 702; see also Bland, 34 S.W.3d at 554.
       124
             See Tex. Loc. Gov’t Code §§ 252.001-.063.
       125
            Id. § 252.061; cf. Texas Logos, L.P. v. Texas Dep’t of Transp., 241 S.W.3d 105, 121-22
(Tex. App.—Austin 2007, no pet.) (reasoning that otherwise proper declaratory claim predicated on
ultra vires conduct was barred by sovereign immunity to extent it sought to invalidate previously
executed state contract (citing Williams, 216 S.W.3d at 828-29)).
       126
         See Dallas Cnty. v. Cedar Springs Invs., L.L.C., 375 S.W.3d 317, 321 (Tex. App.—Dallas
2012, no pet.) (holding that analogous provision applicable to counties under chapter 262 of

                                                  45
argument to the contrary.127 However, the City argues that Carowest lacks standing to assert this

claim because it is not a “property tax paying resident” of the City, as chapter 252 requires.

               Carowest counters by pointing out evidence presented to the district court—namely,

records of the Comal Central Appraisal District—confirming that Carowest not only owns property

within the City, but has also paid taxes on that property to the City and other local governmental

entities since at least 1998. The City acknowledges these facts, but insists that merely owning

property in the City and paying property taxes to the City is not enough to make Carowest a

“property tax paying resident” of the City for purposes of chapter 252. And, in regard to Carowest’s

“residency,” the City emphasizes two additional documents in evidence, both of which were certified

copies of records on file with the Texas Secretary of State’s office: (1) Carowest’s certificate of

limited partnership, dated May 1998, stating that the addresses of Carowest’s registered office,

principal office, and sole general partner were each in San Antonio, not New Braunfels; and (2) a

certificate of fact from the Secretary of State, dated September 2011, stating that the address of



Local Government Code operates as a waiver of immunity); Labrado v. County of El Paso,
132 S.W.3d 581, 587-88 (Tex. App.—El Paso 2004, no pet.) (concluding that (1) standing for
injunctive relief under chapter 262 includes standing to seek declaratory relief to that effect and
(2) appellant’s claims for injunctive relief and declaratory relief under chapter 262 and UDJA were
not barred by sovereign immunity).
       127
            Although the City asserts that Carowest “has not demonstrated that the City has waived
its governmental immunity concerning the North Tributary Contract to assert this declaratory
judgment action against the City,” the sole support it offers for that contention consists of a
recitation of general substantive and procedural concepts related to pleas to the jurisdiction raising
sovereign or governmental immunity, followed by a brief argument disputing that its immunity
regarding claims challenging the North Tributary Contract has been waived by subsection I of
Local Government Code chapter 271, a contention that Carowest does not appear to be advancing.
The City never addresses, much less disputes, the contention that Carowest does make—whether
Carowest’s declaratory claim regarding the North Tributary Contract comes within the waiver of
Local Government Code chapter 252—apart from its assertions regarding Carowest’s standing to
assert that claim.

                                                 46
Carowest’s registered agent was in San Antonio. In the City’s view, these documents conclusively

negate that Carowest is a “resident” of New Braunfels and, thus, its standing to assert a claim

under chapter 252.

               In reply, Carowest insists that no Texas court has ever drawn a distinction

between property ownership and “residency” as that concept has been used within chapter 252 and

its statutory predecessors. Even if the statute drew such a distinction, Carowest further asserts, its

principal place of business at times relevant to this litigation has been in New Braunfels. Indeed, the

district court heard evidence to that effect, including provisions of the Letter Agreement and some

of the related agreements prescribing that any notices to Carowest required under the agreement

may be directed to a Mrs. Elizabeth Weston at a New Braunfels street address located near the

street address of the Carowest property at issue in this case.

               Assuming without deciding that, as the City maintains, there is some material

distinction between property tax payment or property ownership and “residency” in determining

standing to assert a claim under chapter 252, the district court would not have erred in impliedly

finding that Carowest not only pays property taxes to the City, but is also a resident there.128




       128
            See Combs v. Entertainment Publ’ns, Inc., 292 S.W.3d 712, 719 (Tex. App.—Austin
2009, no pet.) (“Where the jurisdictional issues or facts do not implicate the merits of the case,
and the facts are disputed, the court—not the jury—must make the necessary fact findings to
resolve the jurisdictional issue.”). Alternatively, to the extent this standing issue is more properly
viewed as overlapping the merits of Carowest’s claim in reliance on chapter 252, a fact issue
exists as to Carowest’s residency, precluding the district court from granting the City’s plea to
the jurisdiction as to Carowest’s claim. Miranda, 133 S.W.3d at 227-28 (“[I]n a case in which the
jurisdictional challenge implicates the merits of the plaintiffs’ cause of action and the plea to the
jurisdiction includes evidence, the trial court reviews the relevant evidence to determine if a fact
issue exists. . . . If the evidence creates a fact question regarding the jurisdictional issue, then the
trial court cannot grant the plea to the jurisdiction, and the fact issue will be resolved by the
fact finder.”).

                                                  47
Consequently, the district court did not err in concluding that Carowest had standing to bring a

claim under chapter 252 and, in turn, denying the City’s plea to the jurisdiction as to Carowest’s

declaratory claim regarding the North Tributary Project contract.


        The Yantis delay claim

                The third and final declaratory claim at issue concerns the validity of the Yantis

delay claim as it bears upon the parties’ respective obligations in regard to indemnity under

the Letter Agreement. The City insists that Carowest’s declaratory claim seeks to improperly

“circumvent [governmental] immunity from suit by characterizing [a] suit for money damages as a

declaratory judgment claim,” an apparent reference to the principle that immunity bars a UDJA claim

otherwise properly asserted against a governmental entity or officer if the declaratory remedy would

have the effect of awarding relief that is independently barred by immunity, such as retrospective

monetary relief or a declaration of liability under a contract.129 The City is correct to the extent that

the declaration Carowest seeks would have the effect of establishing the City’s rights and potential

liability under the Letter Agreement. However, we have already held that these issues are within the

district court’s jurisdiction to adjudicate by virtue of the waiver of immunity in Local Government

Code chapter 271, subsection I130 and the limited jurisdiction that arises by virtue of the City’s claim




        129
           See, e.g., Williams, 216 S.W.3d at 828-29 (declaratory claim that would have the effect
of awarding retrospective monetary relief against governmental entity); IT-Davy, 74 S.W.3d at 860
(declaratory claim that would effectively impose contractual liability on governmental entity).
        130
           See Ben Bolt, 212 S.W.3d at 327-28 (concluding that section 271.152 of Local
Government Code waived immunity from suit with respect to declaratory claim seeking
determination of rights under contract covered by that statute); Texas Ass’n of Sch. Bds. Risk Mgmt.
Fund v. Benavides Indep. Sch. Dist., 221 S.W.3d 732, 739 (Tex. App.—San Antonio 2007, no pet.)
(same).

                                                   48
for monetary relief. In light of these holdings, we reject the City’s attempt to raise governmental

immunity as a jurisdictional bar to Carowest’s declaratory claim founded on the same subject matter.

               In addition to relying on governmental immunity, the City asserts that Carowest’s

declaratory claim concerning the Yantis delay claim is now moot because, as Carowest alleges,

Yantis released the delay claim in connection with the City’s award to it of the North Tributary

Project contract.131 The City’s argument obviously presumes the validity of the release, and as long

as Carowest is prosecuting a viable declaratory clam seeking to invalidate the “North Tributary Deal”

in which the delay claim purportedly was settled, there remains a justiciable controversy

regarding that underlying claim. Moreover, even if the release is assumed to resolve the delay claim

prospectively from the date of its execution, the validity of the delay claim would still remain a

live and justiciable issue to the extent it bears upon the parties’ past compliance with the Letter

Agreement’s indemnification provisions.

               In sum, the district court did not err in overruling the City’s plea to the jurisdiction

as to each of Carowest’s claims seeking declaratory relief under the UDJA.132


                                         CONCLUSION

               Based on the foregoing analysis, we:



       131
            In fact, the evidence includes a Rule 11 agreement dated May 9, 2011, and signed by
counsel for both the City and Yantis, agreeing that “Yantis will agree to fully release the City of
New Braunfels from Yantis’s asserted delay claim on the South Tributary Project if, after all
proper and legal process is completed, Yantis is awarded the North Tributary Contract . . . at the
New Braunfels City Council meeting scheduled for this evening.” “If the contract is not awarded
to Yantis tonight,” the agreement further provides, “this offer is hereby withdrawn.”
       132
          The availability of UDJA attorney’s fees may be another matter, however. See Jackson,
351 S.W.3d at 301; MBM Fin. Corp. v. Woodlands Operating Co., L.P., 292 S.W.3d 660, 669
(Tex. 2009); Giggleman, 408 S.W.3d at 707-08.

                                                 49
•      Reverse the district court’s order denying the City’s plea to the jurisdiction as to
       Carowest’s takings claim and render judgment dismissing that claim for want of subject-
       matter jurisdiction.

•      Reverse the district court’s order as to Carowest’s claims under Section 1983, and remand
       the claims so that Carowest may have a reasonable opportunity to amend its pleadings, if
       possible, to assert a Section 1983 claim that is not subsumed within its takings claim.

•      Affirm the district court’s order denying the City’s plea as to Carowest’s common-law
       tort claims, contract claims, and related attorney’s-fees claims to the extent the court has
       jurisdiction (1) to adjudicate Carowest’s breach-of-contract and related attorney’s fees claims
       by virtue of the waiver of immunity in chapter 252 of the Local Government Code; and
       (2) alternatively and independently, to adjudicate Carowest’s entitlement to an offset against
       any recovery obtained by the City on its monetary counterclaim.

•      Affirm the district court’s order denying the City’s plea to the jurisdiction as to Carowest’s
       declaratory claims.




                                              __________________________________________

                                              Bob Pemberton, Justice

Before Justices Puryear, Pemberton, and Henson;
  Justice Henson not participating

Affirmed in part; Reversed and Rendered in part; Reversed and Remanded in part

Filed: April 30, 2014




                                                 50
