                                                                                FILED
                                                                                 FEB 03 2011

                            NOT FOR PUBLICATION                             MOLLY C. DWYER, CLERK
                                                                              U.S. COURT OF APPEALS


                     UNITED STATES COURT OF APPEALS

                             FOR THE NINTH CIRCUIT


TOLL BROTHERS, INC., a Delaware                   No. 09-16955
corporation,
                                                  D.C. No. 3:08-cv-00987-SC
             Plaintiff-Counter-Defendant-
            Appellant,
                                                  MEMORANDUM*
  v.

CHANG SU-O LIN; HONG LIEN LIN;
HONG YAO LIN, individuals,

             Defendants-Counter-
            Claimants, Appellees.


                    Appeal from the United States District Court*
                       for the Northern District of California
                      Samuel Conti, District Judge, Presiding

                      Argued and Submitted November 4, 2010
                             San Francisco, California

Before: GOULD, CALLAHAN, Circuit Judges, and KORMAN, District Judge.**

       Toll Brothers, Inc. (“Toll”) appeals from a judgment entered in the United States

       *
             This disposition is not appropriate for publication and is not precedent
except as provided by 9th Cir. R. 36-3.
       **
             The Honorable Edward R. Korman, Senior United States District Judge,
Eastern District of New York, sitting by designation.
District Court for the Northern District of California following a bench trial in favor of

Chang Su-O Lin, Hong Lien Lin, and Hong Yao Lin (“the Lins”). The complaint, based

on diversity of citizenship, arose out of a purchase and sale agreement (“PSA”) in which

the Lins agreed to sell Toll–a national homebuilder– three separate parcels of land in

Dublin, California in three separate closings for a total sale price of $241,500,000. Toll

deposited $21,735,000 into an escrow account to be paid out in increments with each

property closing. Toll and the Lins successfully closed on two parcels of land, Sub-

Areas 1 and 2. The disputed issue here involves the Sub-Area 3 closing scheduled for

June 30, 2007.

      Specifically, without consulting Toll, the Lins had negotiated and executed an

easement to PG&E across Sub-Area 3 on December 12, 2005 for the construction of

temporary overhead power lines. In addition, the Lins installed six above-ground utility

vaults on the property, which Toll challenged on the basis that not all of the vaults were

necessary and the placement of the vaults interfered with Toll’s development plans for

the property. Although the Lins had proposed language terminating the recorded

easement on December 31, 2006, PG&E would not agree to a fixed termination date.

By September 2006 the Lins had completed all of the work necessary for the removal

of the temporary power lines from Sub-Area 3and applied to PG&E for removal of the

temporary overhead power lines. Despite numerous unsuccessful emails and phone

calls from the Lins to PG&E throughout 2007 attempting to get the easement

                                            2
extinguished, PG&E did not quitclaim the power line easement back to the Lins prior

to the scheduled closing of Sub-Area 3. With the easement still conveyed to PG&E, and

no knowledge or reasonable expectation of when it would be extinguished, Toll

terminated the PSA in December 2007, more than five months after the closing date for

Sub-Area 3 specified in the PSA.

       Toll then filed suit for a return of escrow for Sub-Area 3 in the amount of

$7,735,000 alleging that the conveyance and continued existence of the power line

easement to PG&E over Sub-Area 3 and the installation of the utility vaults constituted

breaches of the PSA. In the alternative, Toll alleged that the PSA was illegal and void

because it failed to comply with the Subdivision Map Act. Pursuant to § 4.4 of the PSA,

the Lins seek to retain Toll’s $7,735,000 deposit as liquidated damages.1

       Although numerous issues are raised, we need only address two of them here to

resolve the appeal.

A. The Power Line Easement

       The first and most significant issue is whether the power line easement across

Sub-Area 3 that continued to exist for more than five months after the scheduled close

of Sub-Area 3 constituted a breach of the PSA sufficient to permit Toll to rescind the

contract and recover its deposit.

       1
         Section 4.4 of the PSA provides that if the sale of property is not “consummated
as a result of the buyer’s default under the agreement and if seller is not also in default,”
the deposit “shall be retained by seller as liquidated damages.”
                                             3
       The district judge found that the Lins’ grant of an easement to PG&E for the

installation of temporary power lines did not constitute a breach of the PSA because it

did not interfere with Toll’s planning for Sub-Area 3. In arriving at this conclusion, the

district judge relied on the following findings of fact: 1) Toll knew the power lines were

intended to be a temporary installation; 2) Toll had ceased making plans to develop

Sub-Area 3 at the time of the scheduled closing in June 2007; and, 3) Toll’s planning

for the development of Sub-Area 3, if restarted, would have taken at least a year so the

easement, extinguished in June 2008, did not limit Toll’s ability to develop the land.

Despite finding that the Lins “had not complied with all the requirements in the PSA”

in granting the easement, the district judge held that the Lins’ violation of the PSA “was

not significant enough to justify Toll’s termination of the contract.” In sum, although

the Lins may have violated the contract, their conduct did not amount to a material

breach sufficient to justify Toll’s rescission. We disagree.

       Under California law, the buyers of real property are entitled to take title clear of

encumbrances or defects. See Eason v. Montgomery, 27 P. 280, 282 (Cal. 1891) (in

contracts “for the sale of land there is an implied condition that the title of the vendor

is good, and that he will transfer to the vendee... a title unencumbered and without

defect”); Crim v. Umbsen, 103 P. 178, 180 (Cal. 1909) (it is a buyer’s “right... to receive

a perfect title of record... within the time specified in the agreement”). A marketable

title “means a title which a reasonable purchaser, well informed as to the facts and their

                                             4
legal bearings, willing and anxious to perform his contract, would, in the exercise of that

prudence which business men ordinarily bring to bear on such transactions, be willing

and ought to accept.” Hocking v. Title Ins. & Trust Co., 234 P.2d 625, 649-50 (Cal.

1951).

         A seller’s failure to deliver unencumbered, marketable or agreed-upon title when

a contract matures constitutes a breach and allows rescission. See Post v. Palpar, Inc.,

7 Cal. Rptr. 823, 826 (Cal. Ct. App. 1960) (holding that the “failure to tender marketable

title at the time the contract matures is a material breach”); Fristad v. Thompson, 276

P.2d 116, 118 (Cal. Ct. App. 1954) (when seller deeds a perpetual easement to the city

for the construction of a sewer across property under contract to a homebuilder,

rescission by the homebuilder is valid because he was “entitled to a conveyance of the

full title and to possession of all of the property”); Thomas v. Spitzer, 260 P. 833, 833-34

(Cal. Ct. App. 1927) (where a seller’s failure to obtain a guarantee of title as stipulated

in the agreement permitted buyer’s rescission); Switzler v. Robert A. Klein & Co., 271

P. 367, 369-70 (Cal. Ct. App. 1928) (when seller grants an easement to the city to build

a sewer line without the knowledge or consent of buyers who had entered into an

agreement to purchase the land, consideration failed and the plaintiffs were entitled to

rescind the contract).

         Rescission by the buyer when seller cannot deliver marketable title after a

reasonable period of time is justified even when seller claims that a remedy to the

                                             5
encumbrance or defect is available or forthcoming, because a buyer “is entitled to a title

that is fairly deducible of record, free from reasonable doubt and litigation.” Whelan v.

Rosseter, 82 P. 1082, 1083 (Cal. Ct. App. 1905); Crim v. Umbsen, 103 P. 178, 180 (Cal.

1909); see also, Fristad v. Thompson, 276 P.2d 116, 118 (Cal. Ct. App. 1954) (a buyer

is “not obliged to accept a mere paper title, to bring an action for possession against

another party, and to rely upon their possible success in such an action”). A marketable

title “must not only be free of actual defects but also of reasonable doubt and probable

litigation.” Lansburgh v. Market St. Ry. Co., 220 P.2d 423, 426 (Cal. Ct. App. 1950).



      Particularly apposite here is Leiter v. Handelsman, 270 P.2d 563, 564-65 (Cal.

Ct. App. 1954), where the seller was unable to deliver clear title on the closing date

because the land contained guy wires and an easement in favor of the power company.

Although the power company agreed to remove the guy wires and quitclaim the land

back to the seller, these actions were delayed, leading the buyers to cancel escrow and

demand a return of their deposit. Id. at 564. Despite the fact that the power company

removed the wires and executed a quitclaim deed the day after the buyer’s rescission,

only three weeks after the scheduled closing date, id., the rescission was upheld because

the sellers were unable to deliver marketable title “[w]ithin a reasonable time after the”

scheduled closing. Id. at 568. Similarly, in Ward v. Downey, 213 P.2d 523, 526 (Cal.

Ct. App. 1950), it was held that the possibility of an estate tax in an unspecified amount

                                            6
on property to be sold constituted a defect in title that made it unmarketable, thereby

allowing buyers to rescind the contract even though the exact amount of such tax was

determined within 12 days of the scheduled closing and could have been cured by the

sellers if they paid the taxes.2   Moreover, as the dissent points out, under California law,

motive “is irrelevant to determining if there was a breach or inevitable breach on closing.”

Dissent at 4. Nevertheless, relying on the Restatement (Second) of Contracts, the dissent

suggests that motive is relevant “in assessing whether that breach was material.” Dissent at

4. Research has not uncovered a California case relying on the Restatement (Second)

of Contracts § 241 (1981) (or a comparably worded section in the Restatement (First)

of Contracts § 275 (1932)) in the context of a contract for the sale of real property.

Moreover, California law holds that a buyer’s motive in rescinding a contract for the

sale of land is not relevant to an assessment of his legal rights or fulfillment of legal

obligations under a contract, including whether a material breach occurred. Specifically,

as the Supreme Court of California has held:

               We cannot consider the motives which prompted respondent
               to rescind the contract of sale. It was his right under that

       2
         While these are, for the most part, intermediate appellate court decisions, under
Erie Railroad Co. v. Tompkins, 304 U.S. 64, 78 (1938), “[w]here an intermediate
appellate state court rests its considered judgment upon the rule of law which it
announces, that is a datum for ascertaining state law which is not to be disregarded by
a federal court unless it is convinced by other persuasive data that the highest court of
the state would decide otherwise.” West v. American Tel. & Tel. Co., 311 U.S. 223,
236-37 (1940); see also, Hangarter v. Provident Life and Acc. Ins. Co., 373 F.3d 998,
1012-13 (9th Cir. 2004).
                                             7
              instrument to receive a perfect title of record at the time or
              within the time specified in the agreement. This the
              plaintiffs could not give him. He was entitled to rest upon
              the provisions of the contract, whether or not his real purpose
              was to avoid taking and paying for a tract of land that had
              depreciated in value.

Crim, 103 P. 178, 180 (Cal. 1909); see also De Bairos v. Barlin, 190 P. 188, 191 (Cal.

Ct. App. 1920) (“The courts have held that the motives of the vendee in rescinding may

not be inquired into when he has a legal reason for rescinding and relies thereon”).

       Contrary to the dissent, we do not suggest that “California law requires us

invariably to view any failure to be in a position to tender clear title on the closing date

as per se a material breach.” Dissent at 1. Our decision that the power line easement

constituted a breach of the PSA is not based solely on the inability of the Lins to deliver

unencumbered title on the scheduled closing date. Indeed, Toll did not rescind because

the Lins had not cured the defect in title by the closing date specified in the PSA.

Instead, Toll waited over five months beyond the scheduled closing before rescinding

the contract. Moreover, despite the fact that the Purchase Sale Agreement gave the Lins

the option to extend closing in order to cure a breach of contract, the Lins made it clear

prior to the scheduled closing on June 30, 2007, that they would not extend closing.

Later, in negotiations after the scheduled closing, the Lins offered to extend the close

only if Toll provided additional security and agreed to accept the current location of the

utility vaults which was also in dispute between the parties.


                                             8
      Significantly, the dispute created by the power line easement was of the Lins own

making because they chose to violate the Purchase Sale Agreement by conveying an

easement to PG&E without Toll’s knowledge or consent and without requiring a

termination date on the conveyed easement. Moreover, the breach created by the power

line easement was, as the dissent acknowledges, “of uncertain and unspecified

duration.” Dissent at 2. Thus, despite seeking the removal of the power lines following

the completion of an underground trench in September 2006 and numerous

communications with PG&E throughout 2007, the Lins were unsuccessful in

extinguishing the easement and could not provide a date-certain as to when the easement

would be extinguished. While the dissent argues, with the benefit of hindsight, that the

easement had “no practical impact,” Dissent at 5, it ignores the fact that, when Toll

rescinded the contract, it did not know when or if the easement would be extinguished,

or if doing so would require legal action.

      Nor do we agree with the dissent that the “Lins suffer a major forfeiture over

what seems a hypertechnical breach.” Dissent at 5. We pass over the fact that the major

forfeiture here may be the $7,735,000 that Toll will forfeit to the Lins as liquidated

damages without regard to any actual damage suffered by the Lins. In essence, if the

Lins prevail, they will get to keep their land plus $7,735,000. This notwithstanding the

fact that they rejected the option to extend the closing of Sub-Area 3, insisting instead

upon closing as scheduled despite their inability to convey title “free from reasonable

                                             9
doubt and litigation,” Whelan v. Rosseter, 82 P. at 1083.3 Under California law, this

was more than a “hypertechnical breach.” Dissent at 5; see Ward, 213 P.2d at 526;

Leiter, 270 P.2d at 564-65. Moreover, although the dissent suggests that at issue here

is “a large development contract that placed certain obligations on each party, and that

called for cooperation,” Dissent at 6, our review of the record suggests that it was the

Lins rather than Toll whose conduct was consistent with this vague mandate. Toll

waited more than five months after the specified closing date before rescinding the

contract and, unlike the Lins, was willing to extend the closing date even further.

B. The School Site

      The PSA obligated Toll, as the buyer of Sub-Area 2, to reconvey a parcel of Sub-

Area 2 to the Lins after designating this land as a “School Site.” Reconveyance of the

school site was made a special closing condition for the third closing: “Buyer shall have

reconveyed to Seller or Seller’s assignee the elementary school parcel in Sub-Area 2.”

The Lins argue that reconveyance of the school site “was a fundamental governmental

      3
        Toll does not challenge the validity of § 4.4, the clause in the PSA that provides
for payment of liquidated damages to the Lins in the amount equal to the $7, 735,000
held in escrow in the event of Toll’s default, provided that the Lins are not in default.
While such clauses in the sale of real property are valid if the down payment is a
reasonable amount, when “the evidence establishes that it would not ‘be impracticable
or extremely difficult to fix the actual damage’... such a provision may not be enforced
as one for liquidated damages.” See Freedman v. Rector, Wardens & Vestrymen of St.
Mathias Parish, 230 P.2d 629, 633 (Cal. 1951) (internal citations omitted) (Traynor, J.).
Because Toll does not raise the issue of the enforceability of the liquidated damages
clause, however, we did not reach it here.

                                           10
and regulatory prerequisite for the entire development,” the failure of which permitted

the Lins “to extend the close of escrow past the original scheduled ‘close’ date.”

       The district judge held that “Toll’s failure to reconvey the school site was not a

failure to perform a condition precedent to the Lins’ duty to sell Sub-Area 3,” because

the school site had been assigned to another party prior to the closing of Sub-Area 3 and

therefore was not Toll’s to convey. Accordingly, Toll did not breach the PSA by failing

to reconvey the school site. Nevertheless, he held that Toll’s failure to comply with this

provision gave the Lins the right to extend closing beyond the scheduled date of June

30, 2007.

       We agree with the district judge that Toll did not breach the PSA by failing to

reconvey the school site – a holding that the Lins do not challenge on this appeal.

Notwithstanding his finding that there was no breach, the district judge held that Toll’s

failure to reconvey the school site gave the Lins the right to indefinitely extend the

closing date. Consequently, their failure to close, as late as five months after the

closing date specified in the PSA, did not constitute a breach entitling Toll to rescind the

agreement. While the logic of this argument escapes us, even if the Lins had the right

to extend closing, this right was effectively waived when they insisted, with full

knowledge that the school site had yet to be reconveyed, that the closing of Sub-Area

3 proceed as scheduled.

       The judgment of the District Court is

                                            11
REVERSED.




            12
                                                                                  FILED
Toll Brothers, Inc. v. Su-O Lin et al., No. 09-16955                              FEB 03 2011

                                                                             MOLLY C. DWYER, CLERK
GOULD, J., dissenting:                                                        U.S. COURT OF APPEALS



      I respectfully dissent. The district court held a trial that occupied nine days.

The district court made detailed factual findings that illuminate the grounds for its

decision that the Lins had not materially breached the purchase and sale agreement.

Those factual findings are not challenged on appeal and thus are conceded as true.

The majority rests its opinion primarily on the premise, I think questionable, that

California law requires us invariably to view any failure to be in a position to

tender clear title on the closing date as per se a material breach.1 Hence, the

majority reasons, the granting of a temporary easement to Pacific Gas & Electric

Company (PG&E) for overhead power lines constituted a material breach of the

purchase and sale agreement. The majority relies on California law for the

principle that there is an implied condition in every contract for sale of real

property that the seller will convey title unencumbered and without defect, and that

the failure to tender marketable title at the time a contract matures is a material

breach granting the purchaser the right to rescind. See, e.g., Crim v. Umbsen, 103

      1
        The majority disclaims reliance on this premise and mentions other
circumstances, such as the delay from scheduled closing to declaration of breach,
to support its conclusion. However, I believe the majority comes close to this
premise because the other circumstances cited do not significantly impact the
analysis.

                                           1
P. 178, 180 (Cal. 1909).

      In a case such as this, we are bound to apply state law, which requires us to

make our best estimate of how the California Supreme Court would rule on the

issue if tendered to it. See Vestar Dev. II, LLC v. Gen. Dynamics Corp., 249 F.3d

958, 960 (9th Cir. 2001). Here, in light of the consistent statements in the

California cases on the importance of tendering clear title, I concur in the

majority’s conclusion that at least the temporary power line easement, and perhaps

also the building of the six utility vaults without consent or consultation was a

breach. Nonetheless, I believe that in the unusual circumstances of this case, the

California Supreme Court would view the power line and utility vault easements as

at most partial breach. Largely for reasons supported by the district court’s

extensive and unchallenged factual findings, I would hold that only a partial breach

occurred, not one permitting Toll Brothers to rescind the contract.

      Here are some of the salient points that impact my analysis. First, the power

easement was temporary, and, although it was of uncertain and unspecified

duration and had to be removed by PG&E, it is also true that the local governing

authority, the city, would not allow above ground power lines to remain. Given the

temporary nature of these lines, I must view any breach by their introduction on the

land as a de minimis problem that surely would have been worked out before Toll

                                          2
Brothers had to do any development work or construction on the project.

       Second, although California law may compel us to conclude there was a

breach by inability to tender clear title, I do not accept the idea that all of the

circumstances detailed by the district court in its findings after trial are wholly

irrelevant to whether the breach was a partial breach or a material breach. There

are California cases, e.g. Fristad v. Thompson, 276 P.2d 116, 118 (Cal. Ct. App.

1954), suggesting that a failure to deliver clear title warrants rescission, but I see

nothing from the California Supreme Court stating that that must invariably be the

conclusion. Instead, I take the position that circumstances such as Toll Brothers

ceasing work on development efforts regarding Sub-Area 3 before the planned

closing date, its failure to cooperate in avoiding problems preventing closing, and

its motivation to avoid proceeding during an economic downturn can properly be

considered in assessing whether the breach was partial or material. I predict that

the California Supreme Court would not view this as a material breach. I am not

prepared to rest, so heavily in substance, see supra note 1, on the notion that the

California Supreme Court would make the transfer of clear title a per se

prerequisite to avoid a material breach.

       Third, much the same analysis applies to the utility vault issue. Again, title

was encumbered by the vaults and attendant easements, but I’m disinclined to view

                                            3
that as a material breach. There was clear testimony that the vaults could be

moved at a cost in the range of $300,000-500,000, and so I don’t see why, even if

damages are uncertain, a district court could not make a finding on partial breach

damages and deduct that from the obligations of Toll Brothers. In the total scheme

of the contract, the placement of the utility vaults did not constitute material

breach, and the evidence showed that a partial breach was compensable.

      Fourth, while some California authority suggests that motive is irrelevant,

see, e.g., Crim, 103 P. at 180, and I would agree it is irrelevant to determining if

there was a breach or inevitable breach on closing, I think motive can permissibly

be considered in assessing whether that breach was material. Under the

Restatement (Second) of Contracts, the key factors are (1) the extent to which the

injured party will be deprived of the benefit reasonably expected; (2) the extent to

which the injured party can be adequately compensated for deprivation of benefit;

(3) the extent to which the party failing to perform or to offer to perform will suffer

forfeiture; (4) the likelihood that the party failing to perform or to offer to perform

will cure his failure, taking account of all the circumstances including any

reasonable assurances; and (5) the extent to which the behavior of the breaching

party comports with standards of good faith and fair dealing. Restatement

(Second) of Contracts § 241 (1981). Here, those factors in my assessment tend to

                                           4
favor the Lins rather than Toll Brothers. And I see nothing in California law

indicating that this influential Restatement principle of contract law would not be

followed by the California Supreme Court. That the breach by the Lins in

delivering clear title does not seem motivated by any bad faith or errant intentions

to me counsels for viewing the breach as not material in context.

      Another factor that might be argued to favor Toll Brothers is whether the

encumbrance deprives it of what it expected to buy; however, given the temporary

nature of the easement, and given that Toll Brothers had suspended development,

there is no practical impact of deprivation. Toll Brothers reasonably could have

expected the temporary easement to have been removed before it was time for it to

start work on construction or antecedent planning. If the temporary easement

caused some delay, in my view it is no insurmountable obstacle for experts to give

testimony and for the district court to make a finding on the damages from the

delay. Conversely, as the majority sees this case, the Lins suffer a major forfeiture

over what seems a hypertechnical breach. Also, it was likely that the Lins could

cure the breach because of the temporary nature of the easement.

      The crux of material breach analysis is this: Toll Brothers was not deprived

of any significant part of its bargain as a result of the Lins’ breach, in light of Toll

Brothers’ own plans, a temporary delay on clear title caused it no harm. At the

                                            5
same time, the Lins did not act in bad faith. A determination of partial breach at

most, as made by the district court, is correct.

      Finally, there are pragmatic grounds favoring the district court’s approach.

This was a large development contract that placed certain obligations on each

party, and that called for cooperation. I fear that the majority’s approach will only

lead to gamesmanship and less than cooperative behavior between landowner and

developer, between a master developer and a developer of component parts, and

that aggressive jockeying for position without regard to cooperation will ultimately

impose higher prices on consumers who buy homes in the development.

      For the above reasons, I would characterize the failings of the Lins as

breaches but not as material breaches. Hence I respectfully dissent.




                                           6
