                ARMED SERVICES BOARD OF CONTRACT APPEALS

Appeals of --                               )
                                            )
Garco Construction, Inc.                    )      ASBCA Nos. 57796, 57888
                                            )
Under Contract No. W912DW-06-C-0019         )

APPEARANCES FOR THE APPELLANT:                     Steven D. Meacham, Esq.
                                                   John V. Leary, Esq.
                                                    Peel Brimley, LLP
                                                    Seattle, WA

APPEARANCES FOR THE GOVERNMENT:                    Thomas H. Gourlay, Jr., Esq.
                                                    Engineer Chief Trial Attorney
                                                   Francis X. Eugenio, Esq.
                                                    Engineer Trial Attorney
                                                    U.S. Army Engineer District, Seattle

               OPINION BY ADMINISTRATIVE JUDGE CLARKE
              ON APPELLANT'S MOTION FOR RECONSIDERATION

       Garco Construction, Inc. (Garco), timely moves the Board to reconsider its
22 September 2015 decision denying Garco's appeals. 1 In order to succeed in a
motion for reconsideration the moving party must demonstrate a compelling reason for
the Board to modify its decision. We look to whether the party presents newly
discovered evidence or whether there were mistakes in the decision's findings of fact
or errors of law. Motions for reconsideration are not intended to provide a party with
an opportunity to reargue issues previously raised and denied. C!2, Inc., ASBCA
No. 56257, 15-1BCA~35,829 at 175,194.

       Garco presents two arguments in support of its motion, both suggesting errors
oflaw. The first is essentially an argument that the Board's regulatory interpretation
was erroneous. The language we interpreted was: "[a] 911 Dispatcher will run the
employees name through the National Criminal Information Center system for a wants
and warrants check. Unfavorable results will be scrutinized and eligibility will be
determined on a case-by-case basis by the 341 SFG/CC." Garco Construction, Inc.,
ASBCA Nos. 57796, 57888, 15-1BCA~36,135 at 176,381. We concluded that

1
    Garco's motion caption references ASBCA Nos. 57796, 57888 and 57889. Our
        22 September 2015 decision concerns only ASBCA Nos. 57796 and 57888.
        ASBCA No. 57889 was settled and dismissed with prejudice on 6 September
        2012. We have no reason to believe Garco's reference of ASBCA No. 57889
        was intentional.
although a literal reading of this language might support appellant's interpretation, the
fact that no one with wants or warrants would be allowed to enter the base renders the
rest of the language inconsistent with the regulatory scheme and leads to the "absurd"
result that convicted felons not currently wanted by law enforcement would be allowed
access to Malmstrom Air Force Base (MAFB). Id. at 176,382. Garco complains that
the language does not notify it that individuals with "wants and warrants" would be
detained (app. mot. at 1). Although Mr. Ward provided testimony to that effect, we
consider it self-evident that an individual wanted by law enforcement would not be
allowed entrance to MAFB. In its reply brief the Air Force argues that Garco's
interpretation fails to take into consideration Space Wing Pamphlet 31-101
(15 October 2002) and Space Wing Pamphlet 31-103 (21 July 2005) "maintain the
Base Commander's flexibility in granting base access" (gov't opp'n at 2). We agree.
Garco raises nothing new in its reply brief to change our opinion.

       We reject Garco's argument that "[a] reasonable and natural reading without
bias would lead the reader, in this case JTC, £21 to interpret it to mean that not all
individuals with a want or warrant would be immediately detained, but rather
scrutinized and eligibility determined on a case by case basis" (app. mot. at 2). As we
found in our decision, it is unreasonable to adopt an interpretation that would allow an
individual currently wanted by law enforcement to be allowed access to MAFB. There
was no error of law in our regulatory interpretation.

        In its second argument Garco suggests that the Board should allow
compensation for constructive acceleration (app. mot. at 3). In its opposition brief the
Air Force argues that Garco cites to no clause or case that allows for monetary
compensation for delay caused by a sovereign act (gov't opp'n at 3). It also points out
that the contract was completed early (id.). In its reply brief Garco reiterates the
argument made in its motion for reconsideration (app. reply at 2; app. mot. at 3-5).

        In our decision, we recognized a contractor harmed by a sovereign act might be
entitled to additional time but not compensation:

                It is true that Garco might have been able to specifically
                request additional time to perform as a result of the
                sovereign acts. Troy Eagle Group, ASBCA No. 56447,
                13 BCA, [35,258] at 173,060 ("Actions taken by the
                United States in its sovereign capacity shield the
                government from liability for financial claims resulting
                from those acts, although a contractor is allowed additional
                time to perform.") (citations omitted). However, even if
                appellant had a right to a time extension it does not provide

2
    James Talcott Construction, Inc. (JTC), was the subcontractor with a pass-through
        claim. Garco, 15-1BCA,36,135 at 176,372.
                                             2
               it a path to entitlement to monetary damages resulting
               directly from the sovereign act of limiting access to
               MAFB.

Garco, 15-1BCA~36,135 at 176,383-84. Garco relies upon Dougherty Overseas,
Inc., ENG BCA No. 2625, 68-2 BCA ~ 7165 stating, with respect to that case that "the
government's order to continue construction by whatever means possible despite
difficulties imposed by a border closure was an acceleration order because at that time
appellant would have been within its legal rights to suspend or pace its operations to
adapt them to the situation in which it found itself with its supply line cut-off' (app.
mot. at 4-5). Garco failed to mention that the "border closure" was Afghanistan
closing its border with Pakistan, "[a]ppellant was well along in contract performance
on 6 September 1961 when the Afghanistan Government decided for political reasons
to close the border without notice." Dougherty, 68-2 BCA ~ 7165 at 33,245. There
was no sovereign act on the part of the United States involved in Dougherty.

       Garco provided no support for its argument that it should be compensated for
the harm caused by the sovereign act of enforcing entrance screening requirements at
MAFB. We are unwilling to establish a new limit on the breadth of the sovereign act
doctrine by agreeing with Garco that because it might be entitled to additional time
and was not given any3, it somehow avoids the provisions of the default clause and the
doctrine. There was no error of law in our analysis of this argument.

                                     CONCLUSION

       There being no errors of law in our decision, Garco's motion for reconsideration
is denied.

        Dated: 27 January 2016




                                                   CRAIG S.
                                                   Administr ive Judge
                                                   Armed Se ices Board
                                                   of Contract Appeals

(Signatures continued)

3   While there is evidence that Garco notified the Air Force that it was delayed by the
        access restrictions (15-1 BCA ~ 36,135 at 176,376, finding 19), there is no
        evidence in the record or argument in appellant's briefs that JTC asked for more
        time.
                                            3
 I concur



 MARK N. STEMPLER                              RIC             CKLEFORD
 Administrative Judge                          Administrative Judge
 Acting Chairman                               Vice Chairman
 Armed Services Board                          Armed Services Board
 of Contract Appeals                           of Contract Appeals




      I certify that the foregoing is a true copy of the Opinion and Decision of the
Armed Services Board of Contract Appeals in ASBCA Nos. 57796, 57888, Appeals of
Garco Construction, Inc., rendered in conformance with the Board's Charter.

      Dated:



                                               JEFFREY D. GARDIN
                                               Recorder, Armed Services
                                               Board of Contract Appeals




                                         4
