              In the United States Court of Federal Claims
                                         No. 04-541L
                                  (Filed February 28, 2013)
 ***********************                         *
                                                 *
 STOCKTON EAST WATER                             *   Contract damages; expectation
 DISTRICT and CENTRAL SAN                        *   damages; cost of cover;
 JOAQUIN WATER CONSERVATION                      *   reasonableness of mitigation;
 DISTRICT,                                       *   foreseeability; causation of
               Plaintiffs,                       *   damages.
                                                 *
            v.                                   *
                                                 *
 THE UNITED STATES,                              *
                                                 *
                     Defendant.                  *
                                                 *
 ***********************                         *


      Jennifer L. Spaletta, Stockton, CA, for plaintiff Stockton East Water District. Jeanne
M. Zolezzi and Alexis K. Galbraith, Herum Crabtree, Stockton, CA, of counsel. Roger J.
Marzulla, Washington, DC, for plaintiff Central San Joaquin Water Conservation District.
Nancie G. Marzulla, Marzulla & Marzulla, Washington, DC, of counsel.

       David A. Harrington, Barbara E. Thomas, Sharon A. Snyder, Washington, DC, and
Terry M. Petrie, Denver, CO, with whom was Principal Deputy Assistant Attorney General
Stuart F. Delery, for defendant. Amy Aufdemberge, Assistant Regional Solicitor, U.S.
Department of the Interior, Sacramento, CA, and Shelly V. Randel, Office of the Solicitor,
Washington, DC, of counsel.

              MEMORANDUM OPINION AND ORDER ON CLAIMS
                 OF STOCKTON EAST WATER DISTRICT

MILLER, Judge.

       This case, before the court on remand from the United States Court of Appeals for the
Federal Circuit, involves a dispute over two water supply contracts. Plaintiffs Stockton East
Water District (“Stockton East”) and Central San Joaquin Water Conservation District
(“Central”) (collectively, “plaintiffs” or the “districts”) are water agencies organized under
the laws of California with the authority to provide water to municipal, industrial, or
agricultural users within California’s San Joaquin Valley. In 1983 plaintiffs entered into
separate contracts (the “1983 Contracts” or the “Contracts”) with the United States Bureau
of Reclamation (“Reclamation”) for the appropriation of water from the New Melones
Reservoir. Reclamation breached the Contracts in the years 1999 to 2004 when it failed to
provide specified volumes of water to plaintiffs. Stockton E. Water Dist. v. United States,
583 F.3d 1344, 1356-69 (Fed. Cir. 2009) (“Stockton III”), reh’g en banc granted in part, 638
F.3d 781 (Fed. Cir. 2011), aff’g in part, rev’g in part, and remanding, Stockton E. Water Dist.
v. United States, 75 Fed. Cl. 321 (Fed. Cl. 2007) (“Stockton I”), modified, 76 Fed. Cl. 470
(2007) (“Stockton II”). The Federal Circuit remanded the case to this court for a
determination of damages for the breaches that occurred from 1999 through 2004. Id. at
1369. The Federal Circuit also vacated this court’s dismissal of plaintiffs’ takings claim and
tasked this court with deciding plaintiffs’ takings claim on remand. Id.

       In October 2011, following briefing by the parties, this court granted defendant’s
motion to dismiss plaintiffs’ takings claim. Stockton E. Water Dist. v. United States, 101
Fed. Cl. 352, 362 (2011) (“Stockton IV”). The parties proceeded with discovery regarding
contract damages, and this court held an eight-day damages trial during September 2012. On
remand the parties adopted the convention of filing separate briefs. Because both plaintiffs
presented distinct proofs and proceeded separately at trial, the court has issued separate
opinions regarding the contract damages for Stockton East and Central. The “Discussion”
section of this opinion concerns only the contract damages of Stockton East. However, the
“Facts” section of the separate opinions makes findings with respect to both districts because
the proofs addressed joint issues or otherwise overlapped.

        Plaintiff Stockton East seeks: (1) expectancy damages of $18,818,509.00 or, in the
alternative, $5,398,033.00; (2) damages of $6,740,890.78 to account for its costs of
mitigation; and (3) $1,599,960.00 in consequential damages related to the “stranded costs”
for the portion of the New Melones Conveyance System (the “NMCS”) that remained unused
as a result of the breach.

                                         FACTS 1/

        The factual background and circumstances underlying the 1983 Contract were recited
in the Federal Circuit’s 2009 opinion in Stockton III, 583 F.3d 1344, and this court’s 2007




       1/ The facts set forth in the “Facts” and “Discussion” sections of this opinion
constitute the court’s findings of fact pursuant to RCFC 52(a)(1). The legal standards
governing claims for contract damages sought by plaintiffs frame the context in which
relevant facts are found, so the particular findings appear in the “Discussion” section.
Rulings on mixed questions of fact and law also are set forth in the “Discussion” section.

                                              2
opinion on liability, Stockton I, 75 Fed. Cl. 321. Accordingly, this opinion discusses only
those facts necessary to resolve the damages issues that were tried.

I. The Central Valley Project and New Melones Unit

        The Central Valley Project (the “CVP”) – the largest federal water management
project in the United States – is situated entirely in California and is operated by the United
States through Reclamation. Stockton III, 583 F.3d at 1349. The CVP was built to serve the
water needs of California’s Central Valley Basin and contains numerous dams, reservoirs,
power plants, canals, and other facilities. Id. Completed in 1979, the New Melones Unit of
the CVP consists of a large concrete dam on the Stanislaus River and a reservoir with a
storage capacity of 2.4 million acre-feet of water. 2/ Id.

       The Flood Control Act of 1962, which modified the authorization of the New Melones
project, required Reclamation to “determine the quantity of water required to satisfy all
existing and anticipated future needs within [the Stanislaus River] [B]asin.” Pub. L. No. 87-
874, 76 Stat. 1173, 1191; see also Stockton III, 583 F.3d at 1350. In a 1980 Special Report,
Reclamation estimated that 180,000 acre-feet of water would be available annually for
agricultural, municipal, and industrial uses. Stockton III, 583 F.3d at 1350. Relying upon
the 1980 Special Report, Reclamation issued a Record of Decision (“ROD”) in 1981, which
recommended that Reclamation allocate a portion of the New Melones water supply to
Stockton East and Central. PX 15, at 00336; see also Stockton I, 75 Fed. Cl. at 337.

II. The 1983 Contracts

       The damages trial provided a forum for explicating several provisions of the 1983
Contracts. 3/ Accordingly, the court summarizes the provisions relevant for determining
contract damages, citing prior undisturbed or affirmed rulings from this court’s 2007 liability
opinion and the Federal Circuit’s 2009 opinion as necessary.

       1. Purposes of the Contracts

       In the early 1980s, Reclamation began contract negotiations to sell New Melones
water to Stockton East and Central. Stockton III, 583 F.3d at 1350. On December 19, 1983,
Stockton East and Central signed nearly identical contracts with Reclamation for delivery of


       2/ An acre-foot is the volume of water necessary to cover one acre of land with water
to a depth of one foot.

      3/ The term “Contract” refers to the respective 1983 Contracts of either Stockton East
or Central.

                                              3
water from the New Melones Reservoir. PX 36; 4/ PX 37. Both contracts recite that
“[Reclamation] is constructing and operating the Central Valley Project, California for the
purpose, among others, of furnishing water for irrigation, municipal, industrial, domestic, and
other beneficial uses[.]” PX 36, at 00352; PX 37, at 00382. The Contracts also state,
“[I]nvestigations by [Reclamation] indicate that [each district] has a present and potential
need for an irrigation and a municipal and industrial water supply[,]” and “[each district] has
sought a long-term water supply from the Folsom South Canal of the Central Valley Project
which is not currently available[.]” PX 36, at 00353; PX 37, at 00383. Stockton East and
Central both entered into their respective contracts due to depleted groundwater and the need
for surface water as both an alternative source and as a means of avoiding further depletion
of groundwater. Joint Stipulation of Fact, filed Aug. 31, 2012, ¶ 2 (“Jt. Stipl.”).

       2. Reclamation’s obligation to provide minimum quantities of water

       Article 3 of the Contracts sets forth the formula by which Reclamation was to make
water available to Stockton East and Central. See Stockton III, 583 F.3d at 1351-52;
Stockton I, 75 Fed. Cl. at 364-66. Article 3(c) of Stockton East’s Contract provides that
“[Reclamation] shall make available and [Stockton East] shall pay for, as a minimum, such
quantities of agricultural water as specified[.]” PX 36, at 00357; see Stockton I, 75 Fed. Cl.
at 365. Central’s contract contains an identical provision. PX 37, at 00388; see Stockton I,
75 Fed. Cl. at 365. Subsection (c)(1) states that for the first five years of contract
performance, beginning with the first full year after Reclamation notified the districts that
water was available for delivery, Reclamation was to make available the amount of
agricultural water that the districts requested. PX 36, at 00357; PX 37, at 00388. For years
six through ten, Subsection (c)(2) specifies a minimum volume of agricultural water that
increases from years eight to nine. PX 36, at 00357-58; PX 37, at 00389. If the districts
requested more water than the annual minimum during this period, however, the requested
amount became the new minimum for each subsequent year until exceeded by other
contractual minimums. PX 36, at 00357-58; PX 37, at 00389. The amount of water
scheduled in the eleventh year would be the minimum amount for each remaining year of the
Contract. PX 36, at 00358; PX 37, at 00389.

       Article 3(d) of Stockton East’s contract provides that “[Reclamation] shall make
available and [Stockton East] shall pay for, as a minimum, such quantities of M&I
[municipal and industrial] water as specified” and includes a table listing minimum quantities
of M&I water for each year of contract performance. PX 36, at 00358-59. Subsection (d)
of both contracts allows the districts to convert the agricultural water specified in Subsection


       4/ Both Stockton East and Central denoted their exhibits as “PX.” Exhibits
introduced by Central that are cited in this opinion are numbered beginning with 600, with
the exception of PX 37.

                                               4
(c) to M&I use. PX 36, at 00358, 00360; PX 37, at 00389. These provisions, taken together,
provide the following Build-Up Schedule of annual minimum quantities of water (in acre-
feet) that Reclamation was obligated to make available from 1993 through 2004:


             Year                  Stockton East Build-Up                Central Build-Up
             1993                              500                                0

             1994                             23,350                           28,000

             1995                             23,450                           28,000

             1996                             25,550                           28,000

             1997                             46,400                           56,000

             1998                             46,500                           56,000

             1999                             47,200                           56,000

             2000                             47,900                           56,000

             2001                             48,600                           56,000

             2002                             49,300                           56,000

             2003                             50,000                           56,000

             2004                             50,700                           56,000

See Jt. Stipl. ¶ 7; Stockton II, 76 Fed. Cl. at 489; see also Stockton III, 583 F.3d at 1351-
52. 5/ Article 3 of both contracts also specifies a maximum amount of water that



        5/ Shortly after this court issued its February 20, 2007 liability opinion, plaintiffs filed
a Motion to Amend or Modify Decision. See Stockton II, 76 Fed. Cl. at 471-72. In response
to defendant’s assertion that the court miscalculated the minimum volumes of water with
respect to Stockton East for the years 1999 through 2004, the court amended its February
2007 opinion to correct the computation for those years. Compare Stockton I, 75 Fed. Cl.
at 365, with Stockton II, 76 Fed. Cl. at 479-80, 489. The Federal Circuit’s opinion, however,
noted a Build-Up Schedule that was almost identical to the one appearing in the trial court’s
original opinion and therefore included incorrect minimum volumes for the six breach years.
Compare Stockton III, 583 F.3d at 1352, with Stockton II, 76 Fed. Cl. at 489. Prior to the
damages trial, the parties stipulated to the quantities specified in Stockton East’s Build-Up
Schedule for the years 1999 through 2004. Jt. Stipl. ¶ 7. The stipulated quantities for those
years differed from the quantities listed in this court’s amended liability opinion. Compare

                                                 5
Reclamation would make available annually. PX 36, at 00356-60; PX 37, at 00387-90; see
also Stockton III, 583 F.3d at 1350-51.

        This court found that Reclamation’s failure to provide the minimum quantities of
water listed in the Build-Up Schedule violated the requirements of Article 3, but held that
Reclamation would not be liable for breach if it had a valid excuse under the Contracts for
its non-performance. Stockton II, 76 Fed. Cl. at 489; Stockton I, 75 Fed. Cl. at 365-66. The
Federal Circuit affirmed this court’s finding that, absent a valid excuse, Reclamation would
be liable for breach of contract for its failure to deliver the minimum quantities of water
listed in the Build-Up Schedule. Stockton III, 583 F.3d at 1356-57 (“The record establishes
and the trial court found as a fact that Reclamation failed to provide the water that was
promised under the 1983 contracts for the years 1994, 1995, and 1999-2004. . . . Absent an
affirmative defense, that failure by the Government would constitute a breach of the contracts
and render the Government liable for damages for the breach.”). Reclamation’s non-
performance in the years 1999 through 2004 was not excused, and therefore Reclamation was
liable for breaching the Contracts in those years. Id. at 1364-65.

       3. “Take or pay” provision

        This court previously found that Article 3 not only obligated Reclamation to provide
the minimum amounts of water listed in the Build-Up Schedule, but also required each
district to purchase such amounts of water. Stockton I, 75 Fed. Cl. at 365 (referring to the
Build-Up Schedule as a “minimum purchase and supply schedule”). The Federal Circuit
affirmed that finding. Stockton III, 583 F.3d at 1351 (“Article 3 also establishes for each
year of the contract a minimum amount of water that Reclamation is obligated to make
available, and for which the Districts must pay[.]”).

       At the damages trial, Reid W. Roberts, Central’s General Counsel, testified as to his
understanding that Article 3 contained a provision requiring Central to purchase the
minimum quantities of water. Transcript of Proceedings, Stockton E. Water Dist. v. United
States, No. 04-541L (Fed. Cl. Sept. 10-19, 2012) (“Tr.”), at 1643-44 (Roberts). 6/ Mr.


       5/ (Cont’d from page 5.)

Jt. Stipl. ¶ 7, with Stockton II, 76 Fed. Cl. at 489. Consequently, and representing a final
consensus, the Build-Up Schedule listed above includes the stipulated quantities for the years
1999 through 2004.

        6/ Parentheses attribute statements by counsel and witnesses. Statements by counsel
do not constitute testimony or evidence, although they may prove useful for setting forth
litigating positions and for explaining uncontested terms.

                                              6
Roberts also testified, however, that Reclamation had a practice of requiring Central to pay
for only the volume of water that actually was delivered during both the breach and non-
breach years:

       Q. The practice in the 1999 to 2004 period was for Central to only pay for
       water actually delivered from the Bureau of Reclamation, correct?

       A. That’s correct[.]

              ....

       Q. So both before and after the period 1999 to 2004, the practice between
       Central and the Bureau of Reclamation was to pay for the volume of water
       actually delivered under the New Melones contract.

       A. That was the practice that we engaged in. Yes.

Tr. 1821, 1827 (Roberts). The evidence adduced at the damages trial therefore shows that
Reclamation did not enforce the “take or pay” provision with respect to Central. Although
no witnesses provided similar testimony regarding Reclamation’s enforcement of the “take
or pay” provision with respect to Stockton East, the latter impliedly concedes in its post-trial
brief that it paid only for the volumes of water Reclamation actually delivered. See Pl.
Stockton East’s Br. filed Nov. 9, 2012, at 8 (citing records depicting actual deliveries under
the Contract – PX 411 and PX 434 – as evidence of the volumes that Stockton East
purchased under its Contract).

       4. The Article 9(a) shortage provision

        Although Article 3 of the 1983 Contracts requires Reclamation to make minimum
quantities of water available to the districts annually, the Contracts also provided for certain
exceptions. One such exception, the shortage provision of Article 9(a), states that the United
States shall not be liable “if a shortage does occur in any year because of drought, or other
causes which . . . are beyond the control of the United States.” PX 36, at 00368; PX 37, at
00398; see also Stockton III, 583 F.3d at 1352, 1361-62. This court found that
Reclamation’s failure to provide the minimum amounts of water specified in the Build-Up
Schedule for the years 1994 and 1995 was excused due to the shortage provision of Article
9. Stockton I, 75 Fed. Cl. at 364. The Federal Circuit affirmed this court’s holdings with
respect to the years 1994 and 1995, Stockton III, 583 F.3d at 1363-64, 1369, explaining that
Article 9 is a force majeure provision that applies to causes “beyond the control of the United
States,” such as a drought, earthquakes, an internal failure of the dam, or other such causes,
id. at 1361-62. Citing the liability trial testimony of Edward M. Steffani, Stockton East’s


                                               7
former General Manager, and Central’s General Counsel Mr. Roberts, the Federal Circuit
further explained that when the parties executed the 1983 Contracts, both districts understood
that Article 9(a) provided for shortages caused by external circumstances, including dry
years, physical problems with the reservoir, or earthquakes. Id. at 1362.

       5. The districts’ obligation to submit annual schedules to Reclamation

        Article 4(a) of the 1983 Contracts requires the districts to submit annual schedules to
Reclamation “indicating the amounts of agricultural and M&I water required monthly.” PX
36, at 00361; PX 37, at 00391; see also Stockton III, 583 F.3d at 1352; Stockton I, 75 Fed.
Cl. at 362. Stockton East submitted valid schedules pursuant to the requirements of Article
4(a) from 1994-1996 and in 1998, and Central submitted a valid schedule in 1995. Stockton
I, 75 Fed. Cl. at 362. This court held, however, that the districts’ failure to submit valid
schedules in other years did not excuse Reclamation’s failure to provide the minimum
amount of water listed in the Build-Up Schedule. Stockton I, 75 Fed. Cl. at 363, 365-66.
The failure to provide valid schedules did not excuse Reclamation’s non-performance
because the districts’ payment for water and construction of conveyance facilities pursuant
to the 1983 Contracts constituted substantial performance. 7/ Id. The Federal Circuit
affirmed, and the parties did not further dispute, this court’s ruling that the districts’ failure
to submit schedules did not excuse any breach of contract by Reclamation. See Stockton III,
583 F.3d at 1352.

       6. Central’s so-called “priority right” to Stockton East’s water

       Article 9(b) of Stockton East’s Contract states: “During such water short years, the
quantity of water available to [Stockton East] pursuant to the terms of this contract shall be
reduced, as necessary, to meet the full needs of the Basin contractors and the needs of Central
San Joaquin Water Conservation District for its firm and interim water supply.” 8/ PX 36,
at 00368. Defendant asserts that this language granted Central a “priority right” as a third-
party beneficiary to Stockton East’s Contract and therefore entitled Central take all available
New Melones water during the six-year breach period. See Def.’s Br. filed Dec. 21, 2012
[366], at 11; see also Transcript of Proceedings, Stockton E. Water Dist. v. United States, No.


        7/ The districts’ construction of water conveyance facilities is discussed in greater
detail later in this section of the opinion.

       8/ Article 9(b) of Central’s Contract includes a similar provision, although it does not
specifically name Stockton East. See PX 37, at 00398 (“During such water short years, the
quantity of water available for [Central’s] firm and interim water supply pursuant to the terms
of this contract shall be reduced, as necessary, to meet the full needs of the Basin
contractors.”).

                                                8
04-541L (Fed. Cl. Jan. 4, 2013) (“Closing Arg. Tr.”), at 156-58 (Harrington). Defendant
cites two separate contracts between the districts (the “forbearance agreements”) signed in
1995 and 1996, see DX 847 and DX 864, as evidence of the “priority right” granted to
Central in Article 9(b) of Stockton East’s Contract. Closing Arg. Tr. at 157 (Harrington).
The “whereas” clauses of the forbearance agreements both state: “Stockton-East is entitled
to water under its contract [with Reclamation] only after Central has received or forgone the
water to which it is entitled[.]” DX 847, at SE17892; DX 864, at CSJW_005386. Defendant
also points to the deposition testimony of Mr. Roberts and Grant O. Thompson, Chairman
of Central’s Board of Directors, that Central had the option to take the first 80,000 acre-feet
of water that Reclamation allocated. DX 1184 (Deposition of Reid W. Roberts, May 3,
2012), at 64; DX 1185 (Deposition of Grant O. Thompson, May 22, 2012), at 98-99. Central
responds that no such “priority right” existed under the 1983 Contracts and that Messrs.
Roberts and Thompson “appear to have mistakenly believed” that such a priority right
existed. Pl. Central’s Br. filed Dec. 10, 2012, at 13.

       Although the forbearance agreements and deposition testimony of Messrs. Roberts
and Thompson manifest the districts’ understanding that Central had the option to request
the first 80,000 acre-feet of New Melones water, the evidence does not probatively
demonstrate that a priority right was, in fact, granted to Central under Article 9(b) of
Stockton East’s Contract. Indeed, the language of Article 9(b) in Central’s Contract shows
that Central did not have such a priority right because the “quantity of water available for
[Central]” in water short years “shall be reduced, as necessary, to meet the full needs of the
Basin contractors.” PX 37, at 00398. Rather than granting a right to Central, Article 9(b)
in Stockton East’s contract may operate as a defense for Reclamation in the event that
Reclamation determined it was “necessary” to reduce Stockton East’s allocation to meet the
full needs of Central in a “water short” year. See PX 36, at 00368.

       7. Transfers of New Melones water

       The 1983 Contracts also limit the ability of each district to sell water outside of its
respective service area. Article 10 of the Contracts – entitled “Transfers or Exchanges of
Water” – provides that “[w]ater furnished to the Contractor pursuant to this contract shall not
be sold, exchanged, or otherwise disposed of for use outside the Contractor’s service area
without prior written consent from the Contracting Officer.” PX 36, at 00368; PX 37, at
00398.

       In 1993 Reclamation adopted Interim Guidelines (the “Water Transfer Guidelines”)
for implementation of the water transfer provisions of § 3405(a) of the Central Valley Project
Improvement Act (the “CVPIA”). See PX 602. The Water Transfer Guidelines
acknowledge that § 3405(a) of the CVPIA authorizes transfers of New Melones water:



                                              9
       Section 3405(a) authorizes all individuals or districts who receive [CVP] water
       under water service or repayment contracts . . . to transfer, subject to certain
       conditions, all or a portion of the water subject to such contracts to any
       California water user or agency, State or Federal agency, Indian Tribe or
       private non-profit organization for [CVP] purposes or any purpose recognized
       as beneficial under State law.

Id. at 1. The Water Transfer Guidelines further explain that § 3405(a) is supplemental to
“Reclamation’s existing authority to allow annual transfers between Project water users,
which have historically been allowed and which are encouraged under existing contracts for
efficient and effective Project water management.” Id. Section 1 of the Water Transfer
Guidelines outlines the Guidelines’ three objectives: “to address all water transfers equitably,
to provide for a more efficient and effective use of the water supply developed by the [CVP],
and to provide greater flexibility to water users in transferring water developed by the
[CVP][.]” Id. Angela K. Slaughter, Chief of the Water Contracts and Policy Branch for
Reclamation, Sacramento, CA, testified that Reclamation has used the Water Transfer
Guidelines since 1993 in determining whether CVP contractors are permitted to transfer New
Melones water. Tr. 1709, 1718-19 (Slaughter).

        Section 5 of the Water Transfer Guidelines specifies the criteria for transfers
authorized under § 3405(a). PX 602, at 3-6. Criterion H, for example, states that “[a]ll
transfers will be limited to [CVP] water that would have been consumptively used or
irretrievably lost to beneficial use during the year or years of the transfer.” Id. at 4. Ms.
Slaughter testified that Criterion H requires a transferor to show that the water previously had
been used within the transferor’s district and would be used in the transferor’s district but for
the transfer. 9/ Tr. 1721-24 (Slaughter). In addition, Criteria L and M require a transferor
to comply with federal and state law, including the National Environmental Policy Act, the
Endangered Species Act, the Fish & Wildlife Service Coordination Act, the California
Environmental Quality Act (“CEQA”), and the California Endangered Species Act. PX 602,
at 4-5; Tr. 1724-25 (Slaughter).

       8. Construction of water conveyance facilities

       Article 7(b) of the 1983 Contracts requires the districts to “construct and install,
without cost or expense to the United States, facilities required by [the districts] to take and
convey the water from the point or points of delivery.” PX 36, at 00364; PX 37, at 00394;
see also Stockton III, 583 F.3d at 1351; Stockton I, 75 Fed. Cl. at 363.


      9/ Ms. Slaughter clarified that Criterion H is “subject to [Criterion] J,” Tr. 1724
(Slaughter), which means that “[t]ransfers between [CVP] contractors within counties,
watersheds or other areas of origin” satisfy the requirements of Crietrion H. PX 602, at 4.

                                               10
        Kevin M. Kauffman, Stockton East’s General Manager since June 1993, testified at
the damages trial that Stockton East completed construction of the NMCS in 1993 at a cost
of $65 million. 10/ Tr. 70, 95 (Kauffman). Stockton East financed construction of the
NMCS with a bond offering. Tr. 98 (Kauffman). The NMCS conveys New Melones water
from the Goodwin Dam to Stockton East via the Goodwin Tunnel, Upper Farmington Canal,
a natural creek system, and the Lower Farmington Canal. See Tr. 90-91 (Kauffman)
(discussing PX 518). The water enters Stockton East through the Lower Farmington Canal
at the Copperopolis Gates. Tr. 464 (Kauffman) (discussing PX 518)

       Although Central did not fund construction of the NMCS described above, see
Stockton I, 75 Fed. Cl. at 363 n.17, Central financed construction of a separate distribution
system with bonds at a total cost of $7.4 million. Tr. 1623, 1626 (Roberts) (latter discussing
PX 812). Central’s distribution system “tie[d] . . . together” a series of natural streambeds
and channels within Central’s boundaries. Tr. 1605-06 (Roberts) (discussing PX 518).
Central receives New Melones water from Reclamation at the Goodwin Dam, at which
Stockton East “wheels” the water through its conveyance system to Central’s boundary on
the western side of the Farmington dam. See Tr. 634-35 (Kauffman); Tr. 1692 (Roberts).
Central’s water then flows through the Farmington Dam and into its distribution system of
natural streambeds and creeks. Tr. 1605-06 (Roberts).

       9. Water rates under the Contracts

       The parties stipulated to the water rates under the 1983 Contracts for the six-year
breach period. Jt. Stipl. ¶¶ 3-5. From 1999 through 2004, Stockton East and Central were
required to pay the following rates, per acre-foot, for water purchased from Reclamation
under the 1983 Contracts:


    Year               Stockton East’s Water Rate                   Central’s Water Rate
                                                                        (Ag Water)
                    Ag Water                M&I Water
    1999               $9.24            $46.75 (Jan. - Sept.)                 $9.24
                                        $46.99 (Oct. - Dec.)



        10/ The court’s 2007 liability opinion found that the cost of the NMCS was
approximately $60 million, according to the testimony of Stockton East’s former General
Manager from 1983-1999 Edward M. Steffani. See Stockton I, 75 Fed. Cl. at 363 n.17
(citing Transcript of Proceedings, Stockton E. Water Dist. v. United States, No. 04-541L
(Fed. Cl. Oct. 30, 2006) (“Liab. Trial Tr.”), Tr. 415). As is evident from the varying water
delivery schedules in the different stages of this litigation, the parties have refined the
evidence and, unless a significant point is invalid, the court accepts the most recent iteration.

                                               11
    2000              $10.44            $43.80 (Jan. - Sept.)              $10.44
                                        $44.16 (Oct. - Dec.)

    2001              $11.14            $43.04 (Jan. - Sept.)              $11.14
                                        $43.56 (Oct. - Dec.)

    2002              $10.53            $40.77 (Jan. - Sept.)              $10.53
                                        $41.07 (Oct. - Dec.)

    2003              $11.85            $41.87 (Jan. - Sept.)              $11.85
                                        $42.13 (Oct. - Dec.)

    2004              $13.42            $44.36 (Jan. - Sept.)              $13.67
                                        $44.59 (Oct. - Dec.)

Jt. Stipl. ¶¶ 3-5.

III. Reclamation’s performance under the Contracts

       1. 1988-1992

        In 1988 Reclamation notified Stockton East and Central that water was available and
that the initial delivery date for purposes of the Contracts was January 1, 1989. Stockton III,
583 F.3d at 1351; Stockton I, 75 Fed. Cl. at 343. From 1989 through 1992, Stockton East
and Central did not request water from the New Melones Reservoir, as construction of the
NMCS had not been completed. See Stockton III, 583 F.3d at 1351; see also Tr. 95
(Kauffman) (stating NMCS was not completed until 1993). Reclamation did not deliver any
water to Stockton East or Central during the 1988-1992 time period. Stockton III, 583 F.3d
at 1351; Stockton I, 75 Fed. Cl. at 343.

       2. 1993

        In the spring of 1993, following the enactment of the CVPIA, 11/ Stockton East and
Central requested a meeting with representatives of Reclamation and the United States Fish
and Wildlife Service (“FWS”) to discuss how the CVPIA would affect the Contracts. Tr.
792 (Zolezzi). Jeanne M. Zolezzi, Stockton East’s General Counsel in 1993, testified that
the districts requested the meeting because FWS had made an initial prescription in March


        11/ In 1992 Congress enacted the CVPIA, which directed Reclamation to dedicate
annually 800,000 acre-feet of water from the CVP for fish, wildlife, and habitat restoration
needs. See Stockton III, 583 F.3d at 1351. For a more detailed discussion of the CVPIA, see
id. at 1354-56; Stockton I, 75 Fed. Cl. at 338-42.

                                              12
1993 that over 200,000 acre-feet of water from the New Melones Reservoir would be
allocated for environmental uses. See id. During a June 1993 meeting, representatives of
Reclamation and FWS confirmed that 250,000 acre-feet of New Melones water had been re-
allocated from CVP contractors to fish. Tr. 792-94 (Zolezzi); see also Tr. 1636 (Roberts).
Reclamation and FWS also told the districts that they had made a “back of an envelope”
determination that this same amount would be needed for fish in every year. Tr. 792
(Zolezzi). According to Ms. Zolezzi, Reclamation and FWS made clear that “this
prescription would continue and in only the wettest years might [the districts] see some
water.” Tr. 795 (Zolezzi); see also Tr. 1636 (Roberts) (“[A]t that meeting, Frank Dimmick,
I believe his name is and Wayne White, Dimmick was there representing the Bureau, Mr.
White was there representing Fish and Wildlife Service, spoke about what had transpired
over the past year and basically said there was not going to be any water to honor the
contracts it had to make. . . . [T]here was the passage of the CVPIA[.]”). Despite defendant’s
skepticism that Ms. Zolezzi’s recent testimony was so specific, the court found Ms. Zolezzi
credible on this point, as consistent with other testimony during the 1996 liability trial. 12/

       The testimony during the liability trial almost six years earlier of both Messrs. Steffani
and Roberts was substantially the same on this issue. Compare Liab. Trial Tr. 425-26
(Steffani) (“And we were told at that meeting [which he placed in spring 1993] that we
would be getting no water. And the people in attendance were about ready to throw the
people out from the Bureau [of] Fish and Wildlife, especially after we asked Fish and
Wildlife representatives if they could document the need for the 200,000 acre-feet for fish
flow: How did you determine that you need that much water for fish in the Stanislaus River
this year? We want to know all of the science behind this. And I believe it was Jim
McKevitt from the Fish and Wildlife Service said, ‘Well, we really don’t have anything much
except what we’ve written on the back of an envelope.’”), with Liab. Trial Tr. 170 (Roberts)
(“[T]he Reclamation official whose name was Frank Dimmick . . . indicated that no water
was going to be delivered to either district that year. That all the water was going to go to
meet the requirements of the CVPIA.”).

        In 1993 Stockton East submitted an oral request, on behalf of both Central and
Stockton East, for a total of 20,000 acre-feet of water, with 10,000 allocated between each
district. Stockton III, 583 F.3d at 1352; Stockton I, 75 Fed. Cl. at 343. Reclamation did not
deliver any water under the Contracts in 1993. Stockton III, 583 F.3d at 1352; Stockton I,
75 Fed. Cl. at 343.




       12/ Although Ms. Zolezzi’s testimony at the liability trial referenced the 1993
meeting with Reclamation and FWS, her testimony did not focus on that meeting. See Liab.
Trial Tr. 1024-26 (Zolezzi).

                                               13
       3. 1994-1995

        For 1994 Stockton East requested 75,000 acre-feet of water, and Central requested
25,000 acre-feet of water. Stockton III, 583 F.3d at 1352; Stockton I, 75 Fed. Cl. at 343-44.
In February of that year, Reclamation announced an initial forecast of “zero water supply”
for the districts based on “conditions caused by California’s fourth driest year in 85 years.”
Stockton III, 583 F.3d at 1352; Stockton I, 75 Fed. Cl. at 343-44. Reclamation later informed
the districts that no water could be delivered due to insufficient rain and snowfall conditions,
explicitly invoking the shortage provision of Article 9(a) of the Contracts. Stockton III, 583
F.3d at 1352, 1361-62; Stockton I, 75 Fed. Cl. at 343-44. Neither Stockton East nor Central
received any water under the Contracts in 1994. Stockton III, 583 F.3d at 1353; Stockton I,
75 Fed. Cl. at 344.

        For 1995 Stockton East initially requested 65,000 acre-feet of water, and Central
initially requested 50,000 acre-feet. Stockton III, 583 F.3d at 1353, 1364; Stockton I, 75 Fed.
Cl. at 344. Reclamation informed the districts that a total of 37,000 acre-feet would be made
available to the districts, citing the general drought and water level conditions in the New
Melones Reservoir. Stockton III, 583 F.3d at 1353; Stockton I, 75 Fed. Cl. at 344.
Following a dispute regarding the districts’ water conservation plans, their water requests for
the year were reduced. Stockton III, 583 F.3d at 1353, 1364; Stockton I, 75 Fed. Cl. at 344.
Reclamation was unable to meet the districts’ requests for water in 1995. Stockton III, 583
F.3d at 1353.

       The Federal Circuit affirmed this court’s ruling that Reclamation’s failure to provide
the minimum volumes of water in 1994 and 1995 was excused because the shortage
provision of Article 9(a) applied to those years. Stockton III, 583 F.3d at 1363-64.

       4. 1996

       For 1996 Stockton East initially requested 32,400 acre-feet, and Central requested
40,000 acre-feet. Stockton III, 583 F.3d at 1353; Stockton I, 75 Fed. Cl. at 345. Reclamation
announced an allocation of 49,000 acre-feet to the districts in 1996 and made available all
of the water that Stockton East initially requested for that year. Stockton I, 75 Fed. Cl. at
345. Stockton East later significantly reduced its requested amount to 4,000 acre-feet, citing
“the wet ’95-’96 winter, and because of the unusually large amount of storage in New Hogan
Reservoir, [Stockton East’s] primary source.” Id.; see also Stockton III, 583 F.3d at 1353.




                                              14
In 1996 Reclamation delivered 12,969 acre-feet to Stockton East, PX 434, 13/ and 17,508
acre-feet to Central, Stockton III, 583 F.3d at 1353; Stockton I, 75 Fed. Cl. at 345.

        5. 1997-1998

        In 1997 the parties completed and agreed to an Interim Plan of Operations (the
“IPO”), which allocated water to the districts based upon annual storage and inflow at the
New Melones Reservoir. Stockton III, 583 F.3d at 1353. Stockton East and Central agreed
to the IPO as a short-term modification to the Contracts for 1997 and 1998. Id. In each of
those years, the districts were allocated a combined total of 50,000 acre-feet, and
Reclamation’s water deliveries complied with the terms of the IPO. Id.

        6. 1999-2004

       Although the IPO was intended to be operational for 1997 and 1998, Reclamation
continued to use the IPO formulas to allocate water to the districts from 1999 through 2004.
Id. The following chart summarizes the volumes of water (in acre-feet) that the districts
requested and that Reclamation allocated to the districts from 1999 through 2004:


 Year     Amount Requested by            Amount Requested by            Amount Allocated
             Stockton East                    Central                       (Total)
 1999              23,000                          None                        60,000

 2000              24,000                          None                        90,000

 2001              24,000                          None                        34,000

 2002               3,500                          12,000                      15,500




       13/ The columns labeled “USBR M&I” and “USBR AGR” in PX 434 show the
amount of water that Reclamation delivered to Stockton East under the Contract for the years
1995 to 2011. Tr. 126 (Kauffman). The summary chart depicted in PX 434 is based upon
monthly reports that Stockton East and Central submitted to Reclamation depicting the daily
flows to both districts. See Tr. 121 (Kauffman). The amounts listed in PX 434 differ slightly
from the delivery quantities recited in this court’s liability opinion and the Federal Circuit’s
opinion. Compare PX 434, with Stockton III, 583 F.3d at 1352-53, and Stockton I, 75 Fed.
Cl. at 347. Because the discrepancies are immaterial and both parties cite PX 434 as
evidence of Reclamation’s deliveries to Stockton East, the court accepts PX 434 as an
accurate representation of the quantities of water that Reclamation delivered to Stockton
East.

                                              15
 2003            10,000                         10,000                        10,000
          (combined with Central)           (combined with
                                             Stockton East)

 2004                 None                        25,000             15,000 (Central only)

Id.; Stockton I, 75 Fed. Cl. at 347. 14/ Reclamation delivered the followings volumes of
water to Stockton East and Central under the 1983 Contracts from 1999 through 2004:


  Year       Amount Delivered to Stockton East             Amount Delivered to Central
                                                                  (Ag Water)
            M&I Water        Ag Water        Total

  1999         23,078          5,112        28,190                   33,786

  2000         2,939           4,254         7,193                   27,759

  2001         4,671           2,359         7,030                   25,750

  2002         2,066           1,422         3,488                   10,503

  2003         1,260           1,135         2,395                    9,845

  2004            0            1,486         1,486                   13,605




       14/ At closing argument defendant pointed to PX 551 as evidence that Stockton East
and Central failed to take large volumes of water that Reclamation allocated to the districts
in 1999 and 2000. Closing Arg. Tr. 153 (Harrington) (discussing PX 551); see also Tr. 91,
156 (Harrington). Figure 2-13 in PX 551, Stockton East’s Water Supply Plan dated
December 2008, presents a bar graph showing unused CVP allocations in two of the breach
years – 1999 and 2000. See PX 551, at 2-13. Although PX 551 shows an “East Side CVP
Allocation” of 90,000 acre-feet in 1999, this court previously found that Reclamation
allocated a total of 60,000 acre-feet to Central and Stockton East in 1999. Compare PX 551,
at 2-13, with Stockton I, 75 Fed. Cl. at 347; see also Stockton III, 583 F.3d at 1353.
Defendant has not adequately accounted for this material discrepancy and has not shown that
the unused “East Side CVP Allocation” illustrated in PX 551 was allocated only to Central
and Stockton East. See, e.g., Tr. 2124-25 (Kauffman). The court therefore finds that its
2007 liability opinion accurately reflects the amount of water allocated by Reclamation to
Central and Stockton East.

                                             16
See PX 434; Jt. Stipl. ¶ 6. 15/

       Reclamation’s failure to provide the minimum quantities of water listed in the Build-
Up Schedule violated the requirements of Article 3 of the Contracts. Stockton III, 583 F.3d
at 1364; Stockton II, 76 Fed. Cl. at 489. In contrast to the years 1994 and 1995,
Reclamation’s non-performance during the 1999-2004 time period was not excused by the
shortage provision of Article 9(a), and Reclamation therefore was liable for breaching the
Contracts in the years 1999 through 2004. Stockton III, 583 F.3d at 1364, 1369.

IV. Stockton East’s 1997 Transfer Agreement

        In 1993 Stockton East began pursuing a water transfer agreement with Oakdale
Irrigation District (“OID”) and South San Joaquin Irrigation District (“SSJID”). Tr. 1791-92
(Zolezzi). OID and SSJID are two of the largest water rights holders on the Stanislaus River
with rights to the first 600,000 acre-feet of annual inflow to the New Melones Reservoir. Tr.
891-93 (O’Laughlin); see also Tr. 791 (Zolezzi). The City of Stockton (the “City”),
California Water Service Company (“Cal Water”), the County of San Joaquin, and Central




        15/ As discussed supra note 13, the columns labeled “USBR M&I” and “USBR
AGR” in PX 434 show the volumes of water that Reclamation delivered to Stockton East.
See PX 434. Central and Reclamation stipulated to the amounts delivered to Central for the
years 2001 through 2004. Jt. Stipl. ¶ 6. For deliveries to Central in 1999 and 2000, the
amounts listed in the chart above reflect the findings of fact from this court’s liability opinion
and the Federal Circuit’s opinion. See Stockton III, 583 F.3d at 1353; Stockton I, 75 Fed.
Cl. at 347.

       Defendant relies on Central’s interrogatory responses for the amounts delivered to
Central in 1999 and 2000. See DX 1099 at 4. Central’s interrogatory response for 2000,
however, lists a delivery amount of 28,153 acre-feet – approximately 400 acre-feet greater
than the amount listed in the prior opinions. Mr. Roberts also testified at the damages trial
that 28,153 acre-feet was the correct amount of water that Central purchased from
Reclamation in 2000. See Tr. 1661-62, 1665-66 (Roberts). Raising a hearsay objection and
citing Fed. R. Evid. 403, counsel for Central objected to defense counsel’s questioning Mr.
Roberts about Central’s interrogatory responses. Tr. 1662-63 (Marzulla). Although this
objection is due to be overruled and Mr. Roberts agreed with defendant’s figures, this
discrepancy is immaterial in view of the court’s ultimate findings on Central’s expectancy
damages.

                                               17
joined Stockton East in negotiating directly with OID and SSJID for transfer water. 16/ Tr.
795 (Zolezzi).

       On April 1, 1997, Stockton East entered into a ten-year water transfer agreement with
OID and SSJID (the “1997 Transfer Agreement”). See PX 450. The City, Lincoln Village
Maintenance District, and Colonial Heights Maintenance District also signed the 1997
Transfer Agreement, which referred to those entities, in addition to Stockton East, as the
“Purchasers.” See PX 450, at 1. The term of the 1997 Transfer Agreement was for ten years,
beginning with the date on which water was first delivered. PX 450, at 3. Paragraph 5(a)
required OID and SSJID to deliver water under every year of the agreement. Id. For years
in which the forecast of inflow to the New Melones Reservoir equaled 500,000 acre-feet or
more, OID and SSJID were required to deliver 30,000 acre-feet. Id. In drier years the
delivery amount was reduced to 12,500 acre-feet and 8,000 acre-feet. Id.

       The 1997 Transfer Agreement was a “take or pay” contract requiring Stockton East
to purchase the water regardless of the amount used. Id.; Tr. 801-02 (Zolezzi). For years in
which the forecast of inflow to the New Melones Reservoir equaled 450,000 acre-feet or
more, the price of the water was $55 per acre-foot. PX 450, at 3. In drier years, when the
delivery amount was reduced to 8,000 acre-feet, the price of the water was $90 per acre-foot.
Id. The price of the water was to be adjusted annually based upon changes to the Consumer
Price Index. Id. at 3-4.

       In 1999 Stockton East began receiving water from OID and SSJID under the 1997
Transfer Agreement. Tr. 807 (Zolezzi). Because deliveries were based upon the “water
year” – October 1 through September 30 – Stockton East received deliveries from October
1999 through September 2009. PX 454, at 2-7; see also PX 450, at 3. Utilizing a summary
of Stockton East’s monthly accounting records prepared by Stockton East’s Finance Director,
Elpedio V. Jamosmos, see PX 454, at 2-7; Tr. at 1098 (Jamosmos), Stockton East’s damages
expert, Everett P. Harry, compiled the following summary of Stockton East’s purchases from
OID and SSJID under the Transfer Agreement:


        Year            Amount of Water Purchased                    Amount Paid
                               (acre-feet)
 1999 (Oct. - Dec.)                 4,115.20                          $226,355.50

        2000                       33,352.80                         $1,848,369.17

        2001                       25,479.00                         $1,456,975.67


      16/ The substance of these negotiations and Stockton East’s purposes in seeking an
agreement with OID and SSJID are included in the “Discussion” section of this opinion.

                                               18
        2002                         29,815.00                          $1,746,144.14

        2003                         30,000.00                          $1,786,440.35

        2004                         30,146.50                          $1,834,402.62

        2005                         30,120.01                          $1,884,236.23

        2006                         30,000.00                          $1,948,500.00

        2007                         30,000.00                          $2,017,550.00

        2008                         30,000.00                          $2,064,850.00

 2009 (Jan. - Sept.)                 25,000.00                          $1,791,750.00

PX 403A; Tr. 1269-70, 1272-73 (Harry). 17/ Stockton East used the NMCS to convey the
water it purchased from OID and SSJID. Tr. 130 (Kauffman).

                                PROCEDURAL HISTORY

        A trial court takes note when its appeals court encourages an expedited resolution on
remand. See Stockton E. Water Dist., 638 F.3d at 785. The facts are that this case sat for
over eleven years in federal district court; after transfer to the United States Court of Federal
Claims and the revival of proceedings in April 2004, it was bifurcated at the parties’ request
and thereafter litigated on liability until May 2007; and it was on appeal and rehearing until
April 2011 when it was returned for trial on damages. See generally Stockton IV, 101 Fed.
Cl. at 354-55 (setting forth chronological history to date).

       This case began in 1993, when plaintiffs filed a complaint in the United States District
Court for the Eastern District of California and enumerated five untitled claims for relief.
“As characterized by the district court, these claims were (1) impairment of ‘vested rights
under . . . water contracts[] in violation of the Fifth Amendment due process clause’; (2)
violation of the National Environmental Policy Act for failure to prepare an environmental
impact statement; (3) violation of the CVPIA, § 3410; (4) arbitrary and capricious action by
the Government; and (5) violation of the Fifth Amendment’s takings clause.” Stockton IV,




      17/ Mr. Harry testified to the calculations in PX 403. Stockton East later realized,
however, that PX 403 included transactions that were not part of the 1997 Transfer
Agreement with OID and SSJID. See Tr. 1311-13 (Harry). The parties stipulated to an
amended exhibit – PX 403A – that excluded purchases of water unrelated to the 1997
Transfer Agreement. See PX 403A; Tr. 1807 (Spaletta).

                                               19
101 Fed. Cl. at 354 (dismissing takings claim) (quoting Westlands Water Dist. v. United
States, No. CV-F-93-5327 (E.D. Cal. Feb. 11, 1994) (consolidated cases)).

       On January 29, 2004, the district court transferred the takings claim to the Court of
Federal Claims. Id. at 355 (citing Stockton E. Water Dist. v. United States, Nos. CV-F-93-
5896, CV-F-96-5738 (E.D. Cal. Jan. 30, 2004) (order transferring cases) (consolidated
cases)). This court received the transferred action on April 1, 2004, and plaintiffs filed their
Amended Complaint on April 20, 2004, seeking relief for a taking and breach of contract.
See Amended Compl. filed Apr. 20, 2004. Defendant filed a motion to dismiss on June 21,
2004, inter alia, seeking to dismiss the breach of contract claim, which this court denied by
order entered on September 3, 2004. See Stockton E. Water Dist. v. United States, 62 Fed.
Cl. 379 (2004).

        After the parties filed a Joint Status Report on October 22, 2004, requesting the court
to bifurcate the case, with liability being tried first, and damages being tried thereafter only
if liability was found, an order entered on October 27, 2004, bifurcated the liability and
damages phases of the case. In 2005 the parties filed cross-motions for summary judgment
regarding the breach of contract claim. The court granted in part defendant’s summary
judgment motion, denied plaintiffs’ partial summary judgment motion, and identified the
issues for trial. See Stockton E. Water Dist. v. United States, 70 Fed. Cl. 515, 536 (2006).

        Trial on liability was held October 23, 2006, through November 2, 2006. The court
awarded judgment for defendant on the breach of contract claims for 1993 through 2004 and
dismissed the takings claim. See Stockton I, 75 Fed. Cl. at 376 (determining liability and
entering judgment on the merits). The court subsequently granted in part and denied in part
plaintiffs’ motion to alter or amend the judgment, Stockton II, 76 Fed. Cl. at 482, and denied
plaintiffs’ motion for reconsideration, Stockton E. Water Dist. v. United States, 76 Fed. Cl.
497, 512 (2007). Plaintiffs appealed to the United States Court of Appeals for the Federal
Circuit, which affirmed this court’s judgment of non-liability as to plaintiffs’ breach of
contract claims for 1994 and 1995, reversed this court’s judgment of non-liability as to
plaintiffs’ breach of contract claims for 1999 through 2004, and vacated this court’s dismissal
of plaintiffs’ takings claim. Stockton III, 583 F.3d 1344, reh’g en banc granted in part, aff’d,
638 F.3d 781. Plaintiffs did not appeal this court’s judgment of non-liability as to the
breaches alleged in 1993, 1996, 1997, and 1998. See id. at 583 F.3d at 1354. This court was
tasked with deciding plaintiffs’ takings claim and determining damages for the breaches that
occurred from 1999 through 2004. Id. at 1369.

        Since April 11, 2011, this matter has been before the court on remand from the
Federal Circuit. On July 19, 2011, defendant moved to dismiss the complaint for lack of
jurisdiction, invoking the United States Supreme Court’s decision in United States v. Tohono
O’Odham Nation, 131 S. Ct. 1723 (2011). Tohono construed 28 U.S.C. § 1500 (2006), to


                                              20
foreclose the Court of Federal Claims from hearing any claim based on the same operative
facts underlying a claim encompassed in a pending, prior-filed action in federal district court.
See Tohono, 131 S. Ct. at 1731. Following briefing by the parties, plaintiffs filed a Motion
for Voluntary Dismissal of Their Claim for Taking Without Just Compensation. Defendant
responded to plaintiffs’ motion, arguing that jurisdiction—a threshold issue—must be
resolved before the court could entertain plaintiffs’ motion for voluntary dismissal. On
October 31, 2011, this court dismissed plaintiffs’ takings claim, but denied defendant’s
motion to dismiss as to plaintiffs’ breach of contract claim. Stockton IV, 101 Fed. Cl. at 362.

       On June 18, 2012, defendant moved for summary judgment with respect to the claims
of both Stockton East and Central. Plaintiffs filed cross-motions for summary judgment,
which the court denied because adjudication of the cross-motions did not comport with the
deadline for filing dispositive motions set by an earlier order. Order entered July 10, 2012,
¶ 2. However, all arguments made in support of plaintiffs’ cross-motions were considered
as complementing their respective briefs in opposition to summary judgment. Id. On July
19, 2012, the court granted defendant’s motion with respect to Central only insofar as Central
was seeking a “market value” measure of damages representing the measure of damages for
a takings claim. Order entered July 1, 2012 [260]. The court otherwise denied defendant’s
motions with respect to both plaintiffs without prejudice to any party raising issues that are
appropriate for ruling on motions in limine. Id.; Order entered July 1, 2012 [259].

        After the close of discovery, the parties submitted a total of twenty-three motions in
limine and other pre-trial motions. On August 24, 2012, the court held a pretrial conference
and entered a lengthy epistle discussing each of the motions. 18/ See Order entered Aug.
24, 2012 (the “pretrial order”). The pretrial order noted that the “appeals court affirmed this
court’s findings on the scope of the breach, i.e., failure to deliver a minimum quantity of
water for each of the breach years.” Id., ¶ 12. Accordingly, the court ruled that the “non-
breaching buyer’s recovery is limited by that minimum quantity and whatever damages can
be attributed to the failure to deliver up to that quantity.” Id., ¶ 5.




         18/ In its pretrial order, the court deferred ruling on some arguments raised in the
motions in limine. For example, in response to defendant’s motion in limine arguing that
Stockton East’s stranded costs claim was tantamount to a claim for interest, the court noted
that trial will “provide the appropriate context for ascertaining whether the incurred financing
costs are overhead or interest.” Order entered Aug. 24, 2012, at 18-19. The court explained,
however, that “Stockton East is aware that it can recover overhead in the form of fixed costs
and will present its claim as incurred costs that it could not recover due to the breach.” Id.
The rulings in the pretrial order therefore do not supersede this court’s rulings at trial or in
this opinion.

                                              21
        The damages trial was held in Sacramento, CA, from September 10, 2012, through
September 19, 2012. 19/ At the conclusion of Stockton East’s case-in-chief, defendant
moved for judgment on partial findings, pursuant to RCFC 52(c), with respect to Stockton
East’s damages claims for “groundwater recharge” and “stranded costs.” Tr. 1332-33
(Harrington). The court declined to grant the motion, noting that it was in the interest of
justice to have a full record, especially in light of the lengthy history of this litigation. Tr.
1377-79. Post-trial briefing was completed on December 21, 2012, and closing argument
were held on January 4, 2013.




        19/ Although the court has considered the testimony of every witness, discussion of
each is not necessary to render a comprehensive decision. Stockton East proceeded first at
trial and presented the following witnesses: (1) Kevin M. Kauffman, General Manager of
Stockton East; (2) Mark J. Madison, former Director of Utilities of the City of Stockton; (3)
Jeanne M. Zolezzi, former General Counsel of Stockton East; (4) Francis S. Ferraro, Vice-
President of California Water Service Company; (5) Timothy O’Laughlin, counsel for
Oakdale Irrigation District; (6) Clay J. Landry, Managing Director of WestWater Research
and an expert in western water markets; (7) Elpedio V. Jamosmos, Finance Director of
Stockton East; (8) Elaine Vastis Conti, Manager of Raftelis Financial Consultants and an
expert in identifying and allocating the costs of water conveyance facilities; and (9) Everett
P. Harry, Partner of Harry Torchiana LLP and an expert in the analysis and computation of
breach of contract damages.

       Central then presented the following witnesses: (1) Timothy J. Durbin, an expert in
the hydrology of the Eastern San Joaquin Groundwater Basin; (2) Reid W. Roberts, General
Counsel of Central; (3) Angela K. Slaughter, Chief of the Water Contracts and Policy Branch
of Reclamation’s Sacramento, CA office; (4) Grant O. Thompson, Chairman of Central’s
Board of Directors; and (5) Dr. Rodney T. Smith, President of Stratecon, Inc., and an expert
in California water markets.

       Defendant presented the following witnesses: (1) Steven P. Emrick, General Counsel
for South San Joaquin Irrigation District; (2) Mr. Kauffman; (3) Ali Shahroody, a water
research engineer for Stetson Engineers, Inc. and an expert in water resources and
agricultural engineering; and (4) Dr. David L. Sunding, Professor in the College of Natural
Resources at the University of California, Berkeley and an expert in natural resource
economics, economic damages, agricultural economics, and the economics of water
resources.

                                               22
                                       DISCUSSION

I. Expectancy damages

       1. Standard for awarding expectancy damages

       Plaintiff Stockton East seeks expectancy damages of $18,818,509.00 or, in the
alternative, $5,398,033.00. Pl. Stockton East’s Br. filed Nov. 9, 2012, at 30. The purpose
of expectancy damages is to make the non-breaching party whole by providing it with the
benefits it expected to receive from the contract had the breach not occurred. Fifth Third
Bank v. United States, 518 F.3d 1368, 1374 (Fed. Cir. 2008) (citing Glendale Fed. Bank,
FSB v. United States, 239 F.3d 1374, 1379 (Fed. Cir. 2001)). The Federal Circuit has
cautioned, however, that “‘[a] non-breaching party is [generally] not entitled, through the
award of damages, to achieve a position superior to the one it would reasonably have
occupied had the breach not occurred.’” Kan. Gas and Electric Co. v. United States, 685
F.3d 1361, 1366 (Fed. Cir. 2012) (quoting LaSalle Talman Bank, F.S.B. v. United States, 317
F.3d 1363, 1371 (Fed. Cir. 2003) (first alteration in original)); see also Old Stone Corp. v.
United States, 450 F.3d 1360, 1378 (Fed. Cir. 2006) (“[T]he non-breaching party should not
be placed in a better position through the award of damages than if there had been no
breach.” (citations and internal quotation marks omitted)). Although expectancy damages
can include lost profits, they are not limited to lost profits. Fifth Third Bank, 518 F.3d at
1374 (citing Glendale Fed. Bank, 239 F.3d at 1379).

       A party is entitled to expectancy damages if it can make three showings. Id. First,
the damages must have been reasonably foreseeable at the time the parties entered into the
contract. Id. (citing Cal. Fed. Bank v. United States, 395 F.3d 1263, 1267 (Fed. Cir. 2005))
Second, the damages must be caused by the breach. Id. (citing Cal. Fed. Bank, 395 F.3d at
1267). Third, the measure of damages must be reasonably certain. Id. (citing Cal. Fed.
Bank, 395 F.3d at 1267).

        Foreseeability, causation, and proof of damages to a reasonable certainty are all issues
of fact to be determined by the trial court. Id. at 1375 (citing Home Sav. of Am., FSB v.
United States, 399 F.3d 1341, 1347 (Fed. Cir. 2005)); Bluebonnet Sav. Bank, F.S.B. v.
United States, 266 F.3d 1348, 1355-57 (Fed. Cir. 2001) (“Bluebonnet III”) (explaining that
“[f]oreseeability is a question of fact reviewed for clear error[,]” “[c]ausation is also a
question of fact reviewed under the clear error standard[,]” and reviewing a finding of
reasonable certainty under the clear error standard). The burdens of proving causation,
foreseeability, and proof of damages lie with the claimant. See Anchor Sav. Bank, FSB v.
United States, 597 F.3d 1356, 1362 (Fed. Cir. 2010) (discussing burden in context of lost
profits claim); Precision Pine & Timber, Inc. v. United States, 596 F.3d 817, 833 (Fed. Cir.
2010) (“[T]he party seeking damages has the burden of proving them with ‘reasonable


                                              23
certainty.’”); Yankee Atomic Electric Co. v. United States, 536 F.3d 1268, 1273 (Fed. Cir.
2008) (discussing plaintiff’s burden to prove causation).

              1) Foreseeability

        As the Federal Circuit has held, the party seeking expectancy damages “must show
that the claimed damages were within the realm of reasonable foreseeability at the time the
contract was entered into[.]” Fifth Third Bank, 518 F.3d at 1374 (citing Cal. Fed. Bank, 395
F.3d at 1267). Actual foresight is not required, and the “specific loss in question” need not
be “within the contemplation of the parties at the time of contracting.” Anchor Sav. Bank,
597 F.3d at 1364. Reasonable foreseeability requires “‘merely that the injury actually
suffered must be one of a kind that the defendant had reason to foresee and of an amount that
is not beyond the bounds of reasonable prediction.’” Id. (quoting 11 Joseph M. Perillo,
Corbin on Contracts § 56.7, at 108 (rev. ed. 2005)). The breaching party will not be liable,
however, “‘for a particular type of loss that was so unusual as not to be foreseeable.’” Id.
(quoting E. Allen Farnsworth, Farnsworth on Contracts § 12.14, at 262 (3d ed. 2004)).

              2) Causation

        A plaintiff seeking expectancy damages also must establish that the breach caused the
damages. Fifth Third Bank, 518 F.3d at 1374. In Winstar cases and Spent Nuclear Fuel
(“SNF”) cases, the Court of Federal Claims has applied two different standards in
determining causation of damages: the “but-for” test and the “substantial factor” test. See
Citizens Fed. Bank v. United States, 474 F.3d 1314, 1318-20 (Fed. Cir. 2007). In the “but-
for” test, the plaintiff must establish that the damages would not have occurred “but-for” the
breach. Cal. Fed. Bank, 395 F.3d at 1267. However, the breach need not be “the sole factor
or sole cause” of the damages, and therefore “[t]he existence of other factors operating in
confluence with the breach will not necessarily preclude recovery based on the breach.” Id.
at 1267-68 (affirming trial court’s decision to apply “substantial factor” test) (citing E. Alan
Farnsworth, Farnsworth on Contracts § 12.1, at 150-51 (3d ed. 2004)). Under the
“substantial factor” standard, in contrast, the plaintiff must show that the breach is a
“substantial causal factor” in the damages. See Ind. Mich. Power Co. v. United States, 422
F.3d 1369, 1374 (Fed. Cir. 2005) (citing Energy Capital Corp. v. United States, 302 F.3d
1314, 1320 (Fed. Cir. 2002)).

       The Federal Circuit has explained that the “selection of an appropriate causation
standard depends upon the facts of the particular case and lies largely within the trial court’s
discretion.” Citizens Fed. Bank, 474 F.3d at 1318. Although the Federal Circuit has
affirmed trial court decisions applying the “substantial factor” test in Winstar and SNF cases,
the Federal Circuit has stated a preference for the “but-for” test. See Yankee Atomic, 536
F.3d at 1272 (explaining that the “but-for” test is the “traditional” and “preferred” standard


                                              24
for determining causation). Accordingly, this court will apply the “but-for” standard of
causation to Stockton East’s claim for damages.

        Regardless of the causation standard applied, the Federal Circuit has held that “‘it is
incumbent upon [a plaintiff seeking expectancy damages] to establish a plausible ‘but-for’
world.’” S. Nuclear Operating Co. v. United States, 637 F.3d 1297, 1304 (Fed. Cir. 2011)
(quoting Yankee Atomic, 536 F.3d at 1273); see also Kan. Gas and Electric, 685 F.3d at 1371
(citing Yankee Atomic, 536 F.3d at 1273; Bluebonnet Sav. Bank, FSB v. United States, 67
Fed. Cl. 231, 238 (2005) (“Bluebonnet VI”)); Energy Nw. v. United States, 641 F.3d 1300,
1308 (Fed. Cir. 2011) (“[T]he burden of proving the non-breach world . . . lie[s] with [the
plaintiff].”); Yankee Atomic, 536 F.3d at 1273 (quoting Bluebonnet VI, 67 Fed. Cl. at 238).
In other words, the plaintiff bears the burden of demonstrating “what might have been”
absent the breach. Glendale Fed. Bank, 239 F.3d at 1380.

        Plaintiffs have been denied expectancy damages where the Court of Federal Claims
“could not accurately assess [plaintiffs’] damages” because there was insufficient evidence
to “perform the necessary comparison between the breach and non-breach worlds[.]” Kan.
Gas and Electric, 685 F.3d at 1371; Yankee Atomic, 536 F.3d at 1273 (“Without record
evidence about [plaintiffs’] condition with full Government performance, the Court of
Federal Claims could not perform the necessary comparison between the breach and non-
breach worlds and thus could not accurately assess the [plaintiffs’] damages.” (citations
omitted)). In Kansas Gas and Electric, for example, an SNF plaintiff could not obtain
damages for a spent fuel storage study because the record showed that the plaintiff would
have been required to pursue a similar study regardless of the breach, and the plaintiff did
not provide record evidence comparing the costs of the studies in the breach and non-breach
worlds. 685 F.3d at 1371. In Bluebonnet Savings Bank, a Winstar case, the Federal Circuit
similarly rejected an expectancy damages claim based on a failed but-for model. Bluebonnet
III, 266 F.3d at 1358; see also Bluebonnet IV, 67 Fed. Cl. at 238 (explaining that “the Federal
Circuit recognized that plaintiffs were responsible for establishing the ‘but-for’ world”). The
plaintiffs in Bluebonnet Savings Bank had contended that, in the “but-for” world, they would
have obtained capital infusions through loans at a “speculative” interest rate and that they
would have repaid their debt promptly. Bluebonnet III, 266 F.3d at 1358. However, the
plaintiffs presented no evidence “that anyone would have loaned [plaintiffs] the funds[,]” and
the only witness who testified as to the interest rate predicated the availability of the rate on
contingencies for which no evidence was introduced. Id.

       A proper calculation of expectancy damages accounts for avoided costs – costs that
a plaintiff would have incurred in the non-breach world but has not incurred in the breach
world. See S. Nuclear Operating Co., 637 F.3d at 1303-04 (citations omitted); Yankee
Atomic, 536 F.3d at 1273 (discussing plaintiff’s failure to account for avoided costs);
Bluebonnet Sav. Bank, F.S.B. v. United States, 339 F.3d 1341, 1345 (Fed. Cir. 2003)


                                               25
(“Bluebonnet V”). The plaintiff’s recovery must be reduced by the amount of avoided costs,
“[i]n order to ensure that the [damages award] . . . does not represent an overstatement of the
loss fairly attributable to the breach.” Bluebonnet V, 339 F.3d at 1345; see also Carolina
Power & Light Co. v. United States, 573 F.3d 1271, 1277 (Fed. Cir. 2009) (affirming trial
court finding that plaintiff did not avoid certain costs). Although the plaintiff bears the
burden of persuasion with respect to avoided costs, the plaintiff’s burden to “incorporate
those saved costs into its formulation of a plausible but-for world” arises only when the
defendant first “move[s] forward by pointing out the costs it believes the plaintiff avoided
because of the breach.” S. Nuclear Operating Co., 637 F.3d at 1304 (remanding to the trial
court and instructing that “[s]hould the government fail to timely point out specific
shortcomings in the plaintiff’s causation proof on the issue of saved costs and, in appropriate
circumstances, produce supporting evidence, the court is entitled to treat the issue as
waived”).

              3) Proof of damages to a reasonable certainty

        A party seeking expectancy damages also must prove its damages to a reasonable
certainty. Fifth Third Bank, 518 F.3d at 1374; Cal. Fed. Bank, 395 F.3d at 1267. However,
“where responsibility for damage is clear, it not essential that the amount thereof be
ascertainable with absolute exactness or mathematical precision[.]” Bluebonnet III, 266 F.3d
at 1355; see also San Carlos Irrigation & Drainage Dist. v. United States, 111 F.3d 1557,
1563 (Fed. Cir. 1997) (citing Elec. & Missile Facilities, Inc. v. United States, 416 F.2d 1345,
1358 (Ct. Cl. 1969)). When damages are not proved with mathematical precision, “the
court’s duty is to ‘make a fair and reasonable approximation of the damages.’” Bluebonnet
III, 266 F.3d at 1356-57 (quoting Ace-Fed. Reporters, Inc. v. Barram, 226 F.3d 1329, 1333
(Fed. Cir. 2000)). “If ‘a reasonable probability of damage can be clearly established,
uncertainty as to the amount will not preclude recovery[.]’” Fifth Third Bank, 518 F.3d at
1374-75 (quoting Cal. Fed. Bank, 395 F.3d 1267). Recovery of speculative damages,
however, is precluded. Ind. Mich. Power Co., 422 F.3d at 1373 (citing San Carlos Irrigation
& Drainage Dist., 111 F.3d at 1563).

       2. The parties’ arguments

              1) Additional M&I and agricultural water use but-for the breach

        The evidence and the parties’ arguments focused largely on establishing the “but-for”
world, i.e., what would have happened absent Reclamation’s breach. A primary component
of that scenario is the amount of water that Stockton East would have taken in the breach
years if Reclamation had made full allocations available; if Stockton East would not have
taken water that was unavailable due to Reclamation’s breach, it follows that it suffered no
damages as a result of Reclamation’s breach.


                                              26
        To support its claim for expectancy damages, Stockton East offered evidence that it
would have purchased an additional 82,955 acre-feet of water under the 1983 Contract.
Stockton East’s estimate of additional water demand in the but-for world is based upon: (1)
the testimony of its General Manager Mr. Kauffman, including Mr. Kauffman’s opinions as
a lay witness within the scope of Fed. R. Evid. 701; 20/ (2) testimony from representatives
of its Urban Contractors – Mark J. Madison, former Director of Municipal Utilities for the
City, and Francis S. Ferraro, Vice-President of Cal Water; 21/ and (3) evidence of water
deliveries and infrastructure improvements that actually occurred in the years following the
1999-2004 breach period. See Pl. Stockton East’s Br. filed Nov. 9, 2012, at 23-24.

       Mr. Kauffman prepared a spreadsheet – PX 563 – showing that, if Reclamation had
not breached the Contract, Stockton East would have requested during the breach years an
additional 62,908 acre-feet of water for M&I purposes and an additional 20,047 acre-feet of
water for agricultural and groundwater recharge purposes. See PX 563; Tr. 358-59, 372-77
(Kauffman) (discussing PX 563). The spreadsheet indicates that Stockton East would have
requested the following additional acre-feet of water during the breach period:


      Year             M&I Water               Ag Water and               Total Water
                                               Groundwater                (M&I + Ag /
                                                Recharge                   Recharge)
      1999                 3,152                    5,122                     8,274

      2000                 3,139                    4,217                     7,356



        20/ Mr. Kauffman provided lay testimony and was not qualified as an expert witness
under Fed. R. Evid. 702. Prior to trial defendant filed a motion in limine to exclude or limit
the testimony of ten experts, including Mr. Kauffman. The court found that, although Mr.
Kauffman was a long-time, experienced employee, he did not have the background to qualify
as an expert witness. Order entered Aug. 24, 2012, at 16-17. Mr. Kauffman testified as a
fact witness and offered lay testimony pursuant to Fed. R. Evid. 701.

       21/ Cal Water and the City each have contracts with Stockton East (the “Second
Amended Contract”) to purchase M&I water from Stockton East. Tr. 175-76 (Madison); Tr.
862 (Ferraro); see DX 807 (the Second Amended Contract). The City and Cal Water are two
of Stockton East’s largest Urban Contractors, collectively providing roughly 98% of the
Stockton metropolitan area with M&I water. See Tr. 860-61 (Ferraro). The City and Cal
Water are each entitled to slightly less than half of the M&I water available from Stockton
East. See Tr. 212 (Madison). Stockton East’s other Urban Contractors are Lincoln Village
Maintenance District and Colonial Heights Maintenance District – two political divisions
governed by San Joaquin County. See DX 807, at 00429.

                                             27
      2001                12,760                    5,287                    18,047

      2002                11,492                     152                     11,644

      2003                16,746                    1,144                    17,890

      2004                15,619                    4,125                    19,744

     Total                62,908                    20,047                   82,955
  (1999-2004)

PX 563 (columns M, N, and O).

        Stockton East’s ability to take 62,908 acre-feet of M&I water in the but-for world was
contingent upon certain enhancements that Stockton East would have made to its Drinking
Water Treatment Plant (the “DWTP”) and the Peters Pipeline. See Tr. 363-71 (Kauffman)
(discussing columns H-K in PX 563). Mr. Kauffman prepared a demonstrative exhibit – PX
435 – comparing the actual implementation of the enhancements with the enhancements that
would have occurred had Reclamation not breached the Contract. Tr 231-32 (Kauffman);
see PX 435. According to Mr. Kauffman, if Reclamation had not breached the Contract,
Stockton East would have received requests from its Urban Contractors to accelerate several
planned infrastructure improvements to the DWTP and thus would have hastened its ability
to treat New Melones water at the DWTP for sale to the Urban Contractors. Tr. 238-43, 363-
71 (Kauffman) (discussing PX 563). The first group of enhancements – involving the
completion of a study required by the California Department of Public Health (“CDPH”) and
improvements to the DWTP low-lift pump station – would have been implemented in 1999
and therefore would have increased the rated capacity of the DWTP from 40 million gallons
per day (“mgd”) to 45 mgd beginning in 1999. 22/ Tr. 238-39, 363-64 (Kauffman). In
actuality, Stockton East completed the CDPH study in 2000 and the improvements to the
low-lift pump station in 2002. Tr. 233-35 (Kauffman).

       The second series of enhancements to the DWTP – labeled “Enhancement #3 and #4”
in column J of PX 563 – consisted of improvements to the DWTP’s high-service pump
station and sedimentation basin. Tr. 240-41, 367-68 (Kauffman); see also PX 563. Mr.
Kauffman testified that these enhancements and an additional CDPH study would have been
completed in 2000 and therefore would have increased the rated capacity of the DWTP from
45 mgd to 60 mgd beginning in 2000. Tr. 240-41, 367-68 (Kauffman); see also PX 435; PX


       22/ In order to operate the DWTP at a higher capacity, Stockton East often was
obligated to obtain approval from the CDPH by completing a study demonstrating that it
could meet drinking water standards while operating the DWTP at a higher capacity. Tr.
234-35 (Kauffman).

                                             28
563. In the real world, Stockton East did not complete the high-service pump station and
sedimentation basin improvements until 2007, nor did Stockton East obtain approval to
operate the DWTP at a capacity of 60 mgd until 2008, upon completion of additional CDPH
studies. Tr. 236-37 (Kauffman); see also PX 435. Mr. Kauffman’s analysis also shows that
an additional CDPH study would have been completed in 2002, thereby increasing the rated
capacity of the DWTP to 65 mgd in 2002. See PX 435; PX 563. This study actually was
completed in 2010 – the year that Stockton East began operating the DWTP at its current
capacity of 65 mgd. Tr. 237 (Kauffman). Due to the acceleration of these enhancements in
the but-for world, Mr. Kauffman estimated that Stockton East would have been able to treat
an additional 55,386 acre-feet of water from 1999-2004. 23/ Tr. 371 (Kauffman) (discussing
column K in PX 563).

        Mr. Kauffman’s estimate of Stockton East’s M&I water use in the but-for world also
depended on the acceleration of an additional infrastructure project – the extension to the
Peters Pipeline. Tr. 239-40, 366 (Kauffman). Upon reaching Stockton East’s boundary at
the Copperopolis Gates, New Melones water flows through the Lower Farmington Canal for
roughly a mile and a half before entering the Peters Pipeline. Tr. 464-65, 467-68
(Kauffman). The water then travels westerly and southwesterly through the Peters Pipeline
before reaching the DWTP. Tr. 465 (Kauffman). Prior to 2006, however, only a portion of
the Peters Pipeline had been constructed, and New Melones water therefore had to flow
through a different pipeline – the Belotta Pipeline – for six miles before reaching the DWTP.
Tr. 465-66, 569 (Kauffman). It was Mr. Kauffman’s opinion – as General Manager of
Stockton East – that if Reclamation had not breached the Contract, Stockton East would have
received requests from its Urban Contractors to accelerate the Peters Pipeline project, and
Stockton East therefore would have completed the six-mile Peters Pipeline extension in 2000
– six years prior to its actual completion. Tr. 239-40, 366-70 (Kauffman). With a completed
Peters Pipeline, Stockton East would have been able to deliver additional water to the DWTP
and thus could have treated water at a rate of 60 mgd in 2001 and 65 mgd from 2002-2004.
Tr. 240-41, 366-68 (Kauffman).

      Mr. Kauffman also estimated that Stockton East’s agricultural customers would have
used an additional 20,047 acre-feet of New Melones water during the breach period if




      23/ Mr. Kauffman explained that approximately 14% of the M&I water purchased
from Reclamation at the Goodwin Tunnel constituted “system losses” resulting from
evaporation and percolation in the NMCS and DWTP. Tr. 361-62, 371, 621-25 (Kauffman).
Accordingly, Mr. Kauffman estimated that Stockton East would have needed to request
62,908 acre-feet of water from Reclamation to treat 55,386 acre-feet of water for its Urban
Contractors. Tr. 621-22 (Kauffman) (discussing PX 563).

                                             29
Reclamation had not breached the Contract. 24/ Tr. 372-73 (Kauffman) (discussing column
N in PX 563); see also PX 563. Stockton East operates an “incentive program” that assists
farmers in financing the capital improvements necessary to convert from groundwater to
surface water use. Tr. 379 (Kauffman). As General Manager of Stockton East, Mr.
Kauffman works with agricultural customers who are interested in participating in the
program and converting to surface water. Tr. 378-79 (Kauffman). Mr. Kauffman testified
that during the six-year breach period farmers within Stockton East expressed little interest
in converting to surface water because Stockton East’s surface water was unreliable. Tr.
379-80 (Kauffman). However, when Stockton East began receiving a full allocation of New
Melones water under the Contract in 2005, agricultural customers began expressing more
interest in converting to surface water. Tr. 379-80 (Kauffman). Mr. Kauffman stated that,
based on a comparison of 2010 agricultural use and agricultural use during the breach years,
his staff and he estimated how many more agricultural properties may have hooked up to the
system during the breach years and therefore would have taken New Melones water but for
the breach. Tr. 372-73 (Kauffman). According to Mr. Kauffman, from 1999-2004 the
highest volume of agricultural use – 5,287 acre-feet – would have occurred in the year 2001.
Tr. 376-77 (Kauffman) (discussing column N in PX 563). In that year 40,000 acres of
farmland in Stockton East were irrigated with groundwater. Tr. 377 (Kauffman). To provide
agricultural users with 5,287 acre-feet of New Melones surface water in 2001, Stockton East
would have needed to convert 800 to 1,500 acres from groundwater to surface water use. Tr.
376-77 (Kauffman). Mr. Kauffman related that, since the breach period, Stockton East
actually exceeded that level of conversion. Tr. 377 (Kauffman).

         In addition to Mr. Kauffman’s testimony, Stockton East supported its claim for
expectancy damages with the testimony of representatives of two Urban Contractors.
Messrs. Madison and Ferraro – representatives of the City and Cal Water, respectively – each
testified that their respective entities utilized a conjunctive-use program to meet water needs,
meaning that both surface water and groundwater were used. Tr. 175 (Madison); Tr. 860-64
(Ferraro). During the breach years, both the City and Cal Water had a policy or practice of
maximizing surface water use and reducing groundwater pumping to improve the conditions
of the groundwater basin. Tr. 174-75, 216-17 (Madison); Tr. 863-65 (Ferraro). Given the
Urban Contractors’ preference for using surface water, Messrs. Madison and Ferraro testified
that, if Reclamation had made additional water available to Stockton East from 1999-2004,
the Urban Contractors would have used that surface water to meet their customers’ M&I
water needs. Tr. 176-77, 215 (Madison); Tr. 868-69 (Ferraro). Stockton East also relied
upon Messrs. Madison and Ferraro in an attempt to corroborate Mr. Kauffman’s testimony


       24/ Mr. Kauffman testified that his estimate of agricultural use in the but-for world
accounted for “system losses” ranging from 10 to 30% because agricultural system losses
“var[y] depending on how close the customer is to the conveyance system.” Tr. 375-76
(Kauffman).

                                              30
that Stockton East would have received requests from the Urban Contractors to accelerate
planned infrastructure improvements. Pl. Stockton East’s Br. filed Dec. 10, 2012, at 5-6.

        Stockton East argues that Mr. Kauffman’s analysis is supported by evidence of
infrastructure and water deliveries that actually occurred in the years following the 1999-
2004 breach period. See Pl. Stockton East’s Br. filed Nov. 9, 2012, at 23-24. According to
Mr. Kauffman, 2005 was the first year that Stockton East received a full allocation of water
under the 1983 Contract. Tr. 380 (Kauffman). Mr. Kauffman further explained that, “[o]nce
Reclamation starting making the water more reliable from this contract the urban contractors
became believers” in Stockton East’s planned infrastructure improvements, Tr. 239
(Kauffman), and Stockton East consequently completed the Peters Pipeline extension in 2006
and improvements to DWTP’s high-service pump station and sedimentation basin in 2007,
Tr. 235-36 (Kauffman); see also Pl. Stockton East’s Br. filed Nov. 9, 2012, at 10.

        Stockton East also relies on post-breach evidence to corroborate Mr. Kauffman’s
analysis of agricultural use in the but-for world. See id. at 10. Mr. Kauffman’s analysis
shows that from 1999-2004 the highest volume of agricultural use – 5,287 acre-feet – would
have occurred in the year 2001. See PX 563. To provide agricultural users with 5,287 acre-
feet of New Melones surface water in 2001, Stockton East would have needed to convert a
maximum of 1,500 acres from groundwater to surface water use. Tr. 376-77 (Kauffman).
Mr. Kauffman testified that from 2005 to 2010 the actual conversion of farmland within
Stockton East exceeded that amount. Tr. 377-78 (Kauffman). He further indicated that those
conversions were facilitated by the increased reliability of New Melones water immediately
following the breach period. Tr. 379-80 (Kauffman).

        Defendant responds that Stockton East’s claim for expectancy damages fails because
it is based on an implausible but-for model. Def.’s Br. filed Nov. 29, 2012 [362], at 31-37.
Defendant offers three principal criticisms of Stockton East’s analysis of the but-for world.
First, defendant charges that “[c]onceptually, Stockton East’s but-for model is an exercise
in hindsight untethered to any specific facts in the record.” Id. at 32. Defendant emphasizes
that Mr. Kauffman developed the timeline of accelerated infrastructure improvements, see
PX 435, without reviewing contemporaneous records from the breach period or consulting
with the Urban Contractors, see Def.’s Br. filed Nov. 29, 2012 [362], at 32 (citing Tr. 539-42
(Kauffman)). Citing Mr. Kauffman’s testimony regarding his methodology, defendant
argues that Mr. Kauffman simply “reasoned backward” to develop a scenario under which
Stockton East would have been able to take deliveries of the minimum quantities listed in the
Build-Up Schedule. Id. at 32-33.

        Second, defendant contends that Mr. Kauffman’s but-for model lacks factual support
and is contradicted by evidence of record. Id. at 33-34. Defendant points out, for example,
that the DWTP was already operating at the 45 mgd level in 1999 and 2000, as evidenced by


                                             31
data included in an August 2000 permit application that Stockton East submitted to CDPH.
See id. at 33 (citing PX 525). Defendant also emphasizes that Stockton East’s timeline of
accelerated infrastructure improvements fails to explain how Stockton East would have
rapidly obtained $7 million to construct the Peters Pipeline extension. Id. at 34. Defendant
additionally takes issue with Stockton East’s estimate of agricultural demand in the but-for
world, contending that Stockton East provided no probative evidence that farmers would
have converted to surface water beginning in 1999 if Reclamation began complying with the
Build-Up Schedule in that year. Id. at 35-36.

        Third, defendant argues that Stockton East’s model of the but-for world is
fundamentally flawed because it fails to account for avoided costs. Id. at 36-37. Citing
Stockton East’s financial statements, defendant shows that Stockton East incurs operating
expenses associated with the DWTP to transport, treat, and distribute the water. See id. at
37 (citing PX 500, at 32). Because Stockton East’s but-for model makes no reference to
these costs that Stockton East avoided due to Reclamation’s breach, defendant argues that
Stockton East’s but-for model cannot serve as the basis for an expectancy damages award.
Id.

              2) Stockton East’s calculation of expectancy damages

       Stockton East proposes two alternative methods for calculating its expectancy
damages related to the 82,955 acre-feet of water that it would have requested but for the
breach. Stockton East’s preferred approach, which the court will refer to as the “groundwater
recharge” method, aims to measure the value of the groundwater recharge that Stockton East
lost due to the breach. See Pl. Stockton East’s Br. filed Nov. 9, 2012, at 27-28. Part of
Stockton East’s mission is to address the overdraft of the Eastern San Joaquin Groundwater
Basin by engaging in activities that facilitate groundwater recharge. See Tr. 382-83
(Kauffman); PX 5, at 00004-5, 00009. There are two general ways for Stockton East to
accomplish groundwater recharge: in-lieu recharge and direct recharge. Tr. 383 (Kauffman).
In-lieu recharge occurs when users substitute groundwater for surface water. Id. For
example, in-lieu recharge takes place when a farmer converts to surface water or when an
Urban Contractor uses surface water instead of pumping groundwater. Id. In contrast, direct
recharge can occur through flooding a field, basin, or pond with surface water. Tr. 384
(Kauffman). The surface water then seeps into the ground and ultimately reaches the
groundwater basin. Tr. 638 (Kauffman).

       Mr. Kauffman testified that, if Stockton East had not breached the Contract, Stockton
East would have used the additional 82,955 acre-feet that it would have requested to
effectuate in-lieu recharge. Tr. 393 (Kauffman). Because it is now operating its facilities
at maximum capacity for in-lieu recharge, Tr. 399-400 (Kauffman), Stockton East advances
the argument that it lost the opportunity to attain the in-lieu recharge that it would have


                                             32
achieved during the 1999-2004 breach period. Tr. 444-45 (Spaletta). Stockton East therefore
proposes that the court measure the value of this lost opportunity based upon the cost of
achieving direct recharge over the next three years. See Pl. Stockton East’s Br. filed Nov.
9, 2012, at 28; Tr. 1286-91 (Harry).

       Stockton East relies on the testimony of Messrs. Kauffman and Harry to compute its
expectancy damages under the groundwater recharge method. Mr. Kauffman testified that
Stockton East is currently pursuing a direct recharge project (the “north site facility”), which
would be able to recharge 26,500 acre-feet of water annually. Tr. 400-01 (Kauffman).
Stockton East has estimated that it would cost over $8 million to construct the facility, in
addition to $5.1 million to purchase the 230 acres on which the facility would be located. Tr.
401-09 (Kauffman); see also PX 440; PX 442, at SEWD 123742-D. Based on Mr.
Kauffman’s testimony, Mr. Harry calculated that the cost of accomplishing direct recharge
of 69,919 acre-feet 25/ at the north site facility would be $272.64 per acre-foot. Tr. 1286
(Harry). This sum includes a cost of $236.42 to acquire each acre-foot of water over the next
three years, in addition to $36.22 per acre-foot representing the costs of constructing,
operating, and maintaining the north site facility. Tr. 1286-89 (Harry); see also PX 554, at
2. Accordingly, Mr. Harry calculates that Stockton East’s expectancy damages under the
groundwater recharge method are $18,818,509.00. Tr. 1294 (Harry); see also PX 554, at 1.

       In its post-trial brief, Stockton East offered an alternative method for calculating its
expectancy damages – the “proxy cost of cover” approach. 26/ See Pl. Stockton East’s Br.
filed Nov. 9, 2012, at 25-27. Under this method Stockton East computes its expectancy
damages for each breach year by (1) multiplying the amount of water that it would have
requested from Reclamation but for the breach by the spot-market price of water 27/ and then
(2) subtracting from that amount the price that it paid to Reclamation. See id., Ex. B. Based




       25/ Mr. Harry based his analysis on Mr. Kauffman’s estimate that Stockton East
would have requested an additional 82,955 acre-feet of water but for the breach. See Tr.
1292-93 (Harry); PX 554, at 5. Assuming that 15.72% of the water would have been system
losses, Mr. Harry concluded that 69,919 acre-feet of groundwater would not have been
pumped but for the breach. Tr. 1292-93 (Harry).

        26/ Both in the pretrial order, see Order entered Aug. 24, 2012, at 3, and during trial,
see Tr. 419-20, 1373-74, the court suggested that Stockton East’s counsel should explore the
cost of cover as an alternative method for potentially valuing the water that Stockton East
claims would have been requested but for the breach.

       27/ The spot-market price refers to the price of buying water on a short-term basis,
usually for a one-year term. See Tr. 936-37 (Landry); Tr. 1993-94 (Smith).

                                              33
on the “proxy cost of cover” method, Stockton East alternatively seeks expectancy damages
of $5,398,033.00. 28/ See id. at 30.

        Defendant responds that neither of Stockton East’s expectancy damages calculations
is founded upon recognized principles of contract law. Def.’s Br. filed Nov. 29, 2012 [362],
at 38. Defendant asserts that “Stockton East’s claim for $18.8 million in ‘damages’ for the
projected cost to construct a groundwater recharge facility eight years after the breach ended,
and to supply ‘market rate’ water to that facility for three years, is unprecedented and
unsound.” Id. at 41. Defendant mounts three challenges to Stockton East’s groundwater
recharge calculation. First, citing California property law, defendant points out that the
overlying property owners – not Stockton East – own the groundwater in the East San
Joaquin Groundwater Basin, with the result that Stockton East cannot recover the alleged
damages incurred by those overlying property owners. Id. at 41-42. Second, defendant
contends that Stockton East has not incurred any monetary loss of its own as a result of
groundwater pumping by farmers and the Urban Contractors during the breach period. Id.
at 42-43. Third, defendant emphasizes that Stockton East’s groundwater recharge calculation
is speculative and unsound because it is based upon the construction of a direct recharge
facility that has not been built and may never be built. Id. at 43-44.

        Regarding Stockton East’s “proxy cost of cover” method of calculating of damages,
defendant argues that the use of a spot-market price is inappropriate because Stockton East
sold water to its customers at a price far below the spot-market price. Id. at 46. Moreover,
defendant contends that Stockton East’s “proxy cost of cover” calculation cannot be based
upon the premise that Stockton East would have sold any New Melones water outside the
district but for the breach. Id. at 47-48. Defendant adds that Stockton East did not identify
any potential buyer for its water and notes that Article 10 of the Contract limited Stockton
East’s ability to sell water outside its service area. See id.


       28/ Three witnesses testified regarding the spot-market price of water from the
Stanislaus River and San Joaquin River Basin during the six-year breach period. Timothy
O’Laughlin – an attorney representing OID – testified that the average market price of water
from 1999-2004 was $100 per acre-foot. Tr. 899-900 (O’Laughlin). Mr. Landry – an expert
on water markets – testified that the spot market price of water in the San Joaquin River
Basin during the six-year breach period ranged from a low of $61.25 per acre-foot to a high
of $136.67 per acre-foot. Tr. 940-42 (Landry); PX 426, at 6. Dr. Rodney T. Smith – an
expert on California water markets – testified that the spot-market price of water in the San
Joaquin River Basin ranged from a low of $60 per acre-foot to a high of $135 per acre-foot.
Tr. 2010-18 (Smith); see PX 622, Att. 3. Plaintiff provided separate “proxy cost of cover”
computations based on the spot-market prices provided by each of these witnesses. See Pl.
Stockton East’s Br. filed Nov. 9, 2012, Ex. B. The average of the three computations is
$5,398,033.00. See id. at 25.

                                              34
       3. Analysis of Stockton East’s proof of expectancy damages

              1) Stockton East’s analysis of M&I water use in the “but-for” world

        Stockton East’s model of the but-for world rests primarily on Mr. Kauffman’s
testimony and the two key exhibits he developed: (1) a spreadsheet – PX 563 – showing M&I
and agricultural water use but for the breach, and (2) a timeline – PX 435 – depicting the
acceleration of planned infrastructure improvements but for the breach. During direct
examination Mr. Kauffman testified that he and his staff developed the but-for model by
comparing evidence of M&I and agricultural water use in 2010 and the six-year breach
period. 29/ Tr. 358, 372-73 (Kauffman). Mr. Kauffman explained that the 2010 data were
relevant because “it [sic] was the most current data we had at the time when we did the
analysis, and it included the expansion of the treatment plant and the fact that our urban, or
our agricultural customers were beginning to see the value of the water coming from the CVP
contract through the [NMCS].” Tr. 358-59 (Kauffman). In other words, Stockton East relied
upon evidence of post-breach water deliveries and infrastructure improvements as a proxy
of what would have occurred from 1999 to 2004 had Reclamation not breached the Contract.
This analysis ultimately failed to account for other factors that impeded Stockton East’s
ability to accelerate its planned infrastructure improvements during the breach period and
therefore take additional M&I water from 1999 to 2004. More fundamental were the
problems with PX 563 itself.

       Defendant’s objections to PX 563 were manifold. See Tr. 369-70, 380-81
(Harrington). The court admitted the exhibit as the product of Mr. Kauffman’s analysis, i.e.,
without it his testimony would have been unmoored and incomprehensible. Tr. 381-82. The
lengthy examinations of Mr. Kauffman concerning PX 563 by both Stockton East and
defendant attest to its importance to Stockton East’s case on expectancy damages. See, e.g.,
Tr. 359-82, 393, 527-29, 533-39, 580-81 (Kauffman). It strikes the court as odd were
Stockton East permitted to trumpet an exhibit as embodying an analysis tantamount to that
sponsored by an expert when the proponent witness did not qualify as an expert under Fed.
R. Evid. 702. PX 563 has no inherent evidentiary value apart from Mr. Kauffman’s


       29/ On cross-examination defense counsel impeached Mr. Kauffman with deposition
testimony in which Mr. Kauffman admitted that he created PX 435 without personally relying
on any documents and that the timeline was based upon his conversations with Jeanette
Thomas, Stockton East’s Assistant General Manager. Tr. 541-42 (Kauffman). Mr.
Kauffman explained, however, that Ms. Thomas was “leading the effort” to develop the but-
for analysis. Tr. 540 (Kauffman). The court therefore finds that Mr. Kauffman’s but-for
model was developed through conversations with Ms. Thomas, although Ms. Thomas and
Stockton East staff likely relied upon historical and 2010 water use data to perform the
analysis.

                                             35
testimony, and the court finds that testimony did not withstand defendant’s cross-examination
as to its calculated or derived elements, as will be discussed.

       Stockton East bases its estimate of M&I water use in the but-for world upon its ability
to accelerate its planned infrastructure improvements during the breach period. See PX 563
(columns H-K). The six-mile extension of the Peters Pipeline, in particular, is critical to Mr.
Kauffman’s analysis. Prior to the actual construction of the extension in 2006, New Melones
water needed to flow through the Belotta Pipeline before reaching the DWTP. Tr. 465-66,
569 (Kauffman). Mr. Kauffman admitted during cross-examination, however, that the
Belotta Pipeline had a delivery capacity of 48 mgd and therefore functioned as the
“bottleneck” in Stockton East’s water conveyance system. Tr. 568-69 (Kauffman). Without
the six-mile extension to the Peters Pipeline, Stockton East could not deliver more water
from the New Melones Reservoir to the DWTP. Tr. 198-99 (Madison); Tr. 569 (Kauffman).
The parties do not dispute this fact. See Pl. Stockton East’s Br. filed Dec. 10, 2012, at 15.

       Mr. Kauffman testified that, but for the breach, Stockton East would have completed
the Peters Pipeline extension in 2000 – six years earlier than its actual completion – and thus
would have been able to deliver additional water to the DWTP from 2000-2004. Tr. 239-41,
366 (Kauffman). Crucially, Mr. Kauffman’s testimony did not demonstrate that Stockton
East plausibly could have obtained the financing to construct the extension in 2000. The
Peters Pipeline extension cost over $7 million to construct, see Tr. 570 (Kauffman), and
Stockton East admittedly did not have enough money in 2000 to accelerate its planned
improvements to the DWTP and Peters Pipeline extension, Tr. 562-63 (Kauffman). Stockton
East submitted a grant proposal to the State of California in December 2001 – the first year
in which such a grant proposal could be submitted – seeking $3.5 million to fund the Peters
Pipeline extension. Tr. 570-71 (Kauffman). The State denied the grant application, and
Stockton East resubmitted the application in June 2003. Id. Ten months later – in April 2004
– the State notified Stockton East that its application for $3.5 million in funding had been
approved, but that the funding might not be available from the State in fiscal years 2004 and
2005 due to the State’s budgetary problems. Tr. 571-72 (Kauffman). Once the grant
application had been approved, Stockton East’s Urban Contractors agreed in July 2004 to
fund the remaining $3.5 million. Tr. 572 (Kauffman).

       Mr. Kauffman explained that Stockton East did not have the funding in 2000 for the
Peters Pipeline extension because the Urban Contractors “saw the New Melones supply as
unreliable and didn’t want to fund these [infrastructure] projects.” Tr. 563-64 (Kauffman).
Indeed, Mr. Madison testified that “[i]f additional water was made available [under the 1983
Contract] I believe that the [C]ity would have been much more inclined to work
cooperatively with Stockton East to advance the construction of the Peters pipeline.” Tr. 210
(Madison). Mr. Ferraro echoed that “Cal Water would have required more certainty
associated with the availability of water from [Reclamation], and because of the history of


                                              36
[Reclamation] not providing the water under the terms of the contractual agreement with
Stockton East, we didn’t have that certainty.” Tr. 875-76 (Ferraro). Mr. Ferraro added, “[I]f
we’re going to be paying for additional facilities, and [Reclamation] is not delivering the
water to utilize those facilities, then that’s a waste of money.” Tr. 871 (Ferraro).

        While this testimony suggests that the City and Cal Water may have agreed to finance
the Peters Pipeline extension at an earlier date if additional New Melones water had been
available, it does not plausibly demonstrate that $7 million in financing was forthcoming or
that the Peters Pipeline would have been built in 2000 absent the breach. As Mr. Madison
testified, the water supply from the 1983 Contract was just one factor affecting the City’s
ability to finance construction of the Peters Pipeline extension. When Stockton East first
proposed the Peters Pipeline project in 1999, the City was concerned about the cost of the
project and therefore considered a more economical option, which involved adding slip lining
to the Belotta Pipeline to improve its ability to transport water at high pressures. Tr. 182-83,
199 (Madison). In fact, the City responded to Stockton East’s Peters Pipeline proposal with
a letter stating that the City “ha[d] serious concerns regarding the proposed financing plan”
for the project. 30/ DX 929, at SEWD042688-D.

        During that time period, the City also had other priorities, including its plans for the
South Stockton Aqueduct – a buried pipeline that conveys treated surface water from the
DWTP to the south part of the City. Tr. 185, 201-02 (Madison). Before construction of the
South Stockton Aqueduct in 2006, the south part of the City was not served with any surface
water and had to rely solely on groundwater. Tr. 185 (Madison); DX 1000. Accordingly,
the City prioritized that project over enhancements to the DWTP. Tr. 203 (Madison); see
also DX 1000. Despite the long-standing importance of the South Stockton Aqueduct to the
City, the City’s monetary concerns prevented the aqueduct from being constructed until 2006.
Tr. 201-02 (Madison). The City was not able to begin construction of the aqueduct until
2004 when it obtained $6 million in federal funding for the $10 million project. Id. Given
the financial obstacles faced by the City in constructing the South Stockton Aqueduct – a
project that it prioritized over the DWTP – it is not plausible that the City would have agreed
to finance construction of the Peters Pipeline extension as early as 1999. 31/


       30/ Mr. Kauffman noted his understanding that this specific language referred to
Reclamation’s breach of the Contract. Tr. 575 (Kauffman). Nonetheless, Mr. Kauffman
admitted that the letter made no specific reference to Reclamation. Tr. 576 (Kauffman).

        31/ Defendant argues that the City withheld funding for the Peters Pipeline in 1999,
in part, because the City and Stockton East were embroiled in a lawsuit. See Def.’s Br. filed
Nov. 29, 2012 [362], at 11. Citing Mr. Kauffman’s trial testimony, defendant claims that the
City “later threatened to sue the district if it went forward with the project.” See id. (citing
Tr. 552 (Kauffman)). The cited testimony, however, does not state explicitly that any lawsuit

                                              37
       A lack of funding was not the only factor affecting construction of the Peters Pipeline.
Mr. Kauffman explained during cross-examination that construction of a new pipeline
involves acquisition of a right-of-way, compliance with regulatory and environmental
procedures, and consultation with Stockton East’s Urban Contractors. Tr. 544-45
(Kauffman). Indeed, the City’s November 1999 response to Stockton East’s Peters Pipeline
proposal identifies several “[p]otentially [s]ignificant” land use, planning, and environmental
concerns with the proposed project:

       According to the Project Description, this project will require the acquisition
       of 3,650 feet of thirty-foot wide easements by [Stockton East]. As major water
       transmission pipelines inherently impose impacts and restrictions on
       landowner’s usage of property (maintenance roads, inspection/access points,
       cathodic protection equipment, etc.), this project will have a potentially
       significant impact on those affected landowners and their property.
       Consequently, in accordance with CEQA requirements, an Environmental
       Impact Report must be prepared detailing these impacts and any proposed
       mitigation measures.

              ....

       The Initial Study [of the Peters Pipeline project] fails to identify and assess
       other project alternatives that may satisfy the stated project needs without
       resulting in the adverse environmental impacts as described . . . above.

DX 929, at SEWD042687 to 688-D. Noting that “[t]hese alternatives may be less costly
[and] less impacting to the environment,” the City’s November 1999 letter recommended that
the alternatives “should be fully evaluated, together with the input of all affected parties,



       31/ (Cont’d from page 37.)

between the City and Stockton East was related to the pipeline project. See Tr. 552
(Kauffman). Three witnesses – Messrs. Madison, Kauffman, and Ferraro – testified
regarding a lawsuit that the Urban Contractors filed against Stockton East in the 1998-2001
time period. All three witnesses merely testified that the lawsuit involved the way Stockton
East was spending the Urban Contractors’ money. See Tr. 199-200, 221 (Madison); Tr. 575-
76 (Kauffman); Tr. 871 (Ferraro). Moreover, Mr. Ferraro directly denied that the lawsuit
was connected with the Peters Pipeline. See Tr. 871 (Ferraro). The nature of the lawsuit was
not further developed through testimony or documentary evidence, so the court is not in a
position to make a finding on the impact of the lawsuit on Stockton East’s ability to finance
its planned infrastructure improvements.

                                              38
prior to the adoption of any environmental document for the project.” Id. at SEWD042688-
D.

        The record reflects that such regulatory, environmental, and other factors unrelated
to financing likely would have prevented Stockton East from constructing the Peters Pipeline
six years earlier. Despite obtaining $3.5 million in financing from the Urban Contractors in
July 2004, Stockton East did not award a contract to begin construction of the pipeline until
February 2005. Tr. 572 (Kauffman). Due to problems that occurred during construction,
work on the project still was continuing in December 2006 – almost two-and-one-half years
after Stockton East secured financing from the Urban Contractors. 32/ Tr. 572-73
(Kauffman). Even if Reclamation had not breached the Contract in 1999 and Stockton had
obtained full funding from the Urban Contractors later that year, Stockton East has not met
its burden of producing evidence that it plausibly would have completed the required
regulatory and environmental process and construction of the pipeline at a faster pace. In
fact, when cross-examined, Mr. Kauffman stated that Reclamation’s breach did not cause
Stockton East to defer its plans for the Peters Pipeline project:

       Q. Stockton East did not defer the Peters pipeline in 1999 at all, did it? It
       continued pushing forward with that project.

       A. We pushed hard for that project from whoever would provide the funding.
       That’s correct.

       Q. So Stockton East didn’t defer the Peters pipeline because of the breach at
       all. It continued pushing forward with the project.

A. Absolutely we pushed forward with that project. We pushed forward with all of the
projects.

Tr. 551-52 (Kauffman). Mr. Kauffman confirmed that, when Reclamation announced the
water allocation in the first part of 1999 and began breaching the Contract, Stockton East’s
Board of Directors took no action to delay or defer the planned infrastructure improvements
described in Mr. Kauffman’s but-for model. Tr. 549-51 (Kauffman).

      Stockton East argues that Mr. Kauffman’s analysis of accelerated infrastructure
improvements is plausible because it is “truth-tested against what actually happened at the


        32/ Mr. Kauffman testified earlier that it took “about one year” to actually construct
the Peters Pipeline. Tr. 240 (Kauffman). His testimony on cross-examination, however,
clarified that construction was ongoing almost two years after Stockton East awarded a
construction contract. Tr. 572-73 (Kauffman).

                                             39
district post-breach.” Pl. Stockton East’s Br. filed Dec. 10, 2012, at 14. In other words,
Stockton East contends that Mr. Kauffman’s but-for model is reasonable because it comports
with infrastructure improvements that actually occurred after the breach period when
Reclamation began making more water available. See Pl. Stockton East’s Br. filed Nov. 9,
2012, at 24; Tr. 239-40 (Kauffman). The evidence adduced at trial, however, does not
indicate that the Urban Contractors began supporting the infrastructure improvements due
to a perceived or actual increased reliability or availability of New Melones water.
According to Mr. Kauffman, 2005 was the first year that Stockton East received a full
allocation of water under the 1983 Contract. Tr. 380 (Kauffman). Yet, the Urban
Contractors agreed to finance the Peters Pipeline during the prior year – in July 2004 – when
Reclamation was still breaching the Contract. See Tr. 572 (Kauffman). This fact
undermines Stockton East’s attempt to draw a causal link between Reclamation’s
performance under the Contract and the Urban Contractors’ eventual decision to finance the
Peters Pipeline.

        In fact, Mr. Madison testified that the City’s eventual support of the Peters Pipeline
was not driven by the availability of New Melones water. According to Mr. Madison, the
City decided to support the Peters Pipeline primarily because it was concerned about the
reliability of the Belotta Pipeline:

       A. Later on our position about the Peters pipeline changed because we became
       concerned about reliability of the Belotta pipeline.
              There was a particular event involving a pickup driven by one of the
       employees of Stockton East that backed up or drifted into a canal, and the
       supply, the sole supply, was potentially contaminated and we were concerned
       about water supply to the entire Stockton metropolitan area. And so that was
       one of the catalyst issues that led us to become concerned about the reliability
       of having a single pipeline feeding Stockton East water treatment plant from
       the east.
              And I think that and more discussion in general led the city at least – I
       can’t speak on behalf of Cal Water, but certainly the city – to think well,
       maybe it is time to construct the Peters pipeline, and then shortly thereafter the
       Peters pipeline was designed and built.

       Q. Did the amount of water that [Reclamation] was allocating to Stockton
       East under the contract during that time period influence the city’s position on
       the Peters pipeline?

       A. Not really. I don’t believe so. Certainly as engineers and water purveyors
       we like to have more capacity if we can get it, but from memory I remember



                                              40
       that the predominant thinking of myself and I think others at the city was it
       was primarily intended to enhance reliability.

Tr. 183-84 (Madison). Although Mr. Madison later indicated in his answer that the
availability of New Melones water was a factor affecting the City’s support for the pipeline
project, the “catalyst” and “predominant” factor influencing the City’s eventual decision to
support the pipeline project was the reliability of the Belotta Pipeline. Id. The balance of
Mr. Madison’s testimony therefore belies Stockton East’s assertion that it would have
obtained financing from the Urban Contractors in 1999 but for the breach.

         Stockton East also contends that Mr. Kauffman’s analysis of accelerated infrastructure
improvements is reasonable because it is based upon a 1989 design report of the DWTP
indicating that the DWTP was designed to be expanded to the 60-mgd level. See Pl.
Stockton East’s Br. filed Dec. 10, 2012, at 14 (citing PX 531; Tr. 227-28 (Kauffman)).
However, the cited trial testimony does not state that the 1989 design report was the
foundation of Mr. Kauffman’s analysis, see Tr. 227-28 (Kauffman), and the design report is
of little relevance because it does not appear to indicate when Stockton East expected to
achieve a 60-mgd capacity at the DWTP. See PX 531. In fact, a contemporaneous 1989
report of the NMCS actually stated that the capacity of the DWTP was projected to increase
to 60 mgd in the year 2010 – eight years after Mr. Kauffman estimated that the DWTP would
have achieved a 60-mgd rated capacity but for the breach. PX 444, at SEWD123726-D
(“The sedimentation basin capacity will be doubled in the year 2010 to increase the overall
plant capacity to 60 MGD[.]”). 33/

        Stockton East has failed to meet its burden of establishing a plausible but-for world
regarding its M&I water use in the years 2001 to 2004. See, e.g., S. Nuclear Operating Co.,
637 F.3d at1304 (“‘Because plaintiffs . . . are seeking expectancy damages, it is incumbent
upon them to establish a plausible ‘but-for’ world’” (quoting Yankee Atomic, 536 F.3d at
1273)); Energy Nw., 641 F.3d at 1308 (“[T]he burden of proving the non-breach world . . .
lie[s] with [the plaintiff].”). Stockton East’s estimate of M&I water use from 2001-2004 is
predicated upon its ability to complete construction of the Peters Pipeline project by 2000.
See PX 563. The record reflects that numerous contingencies, in addition to the availability
of New Melones water, would have substantially affected the ability of Stockton East to
construct the Peters Pipeline by that time. The proposition that the grant money would have
been available six years prior lacks record support, and the City had financial concerns and


       33/ The court admitted PX 444, over defendant’s objection, to the extent it was cited
during trial. Tr. 1184-85. In restricting lengthy documents to the extent that they are the
subject of testimony, or, if not objected to, argument by counsel, the court reserved the right
to read other portions for context. This reference falls within that scope, although Stockton
East sought to admit PX 444, including the page cited above. Id.

                                              41
other priorities – namely, the South Stockton Aqueduct – at that time. Tr. 201-02 (Madison).
Completion of the project also required Stockton East to acquire easements, complete
environmental assessments, comply with other regulatory steps, and procure a contractor.
See DX 929. Even though Stockton East admittedly continued “pushing forward” with the
project despite the breach, see Tr. 551-52 (Kauffman), construction of the project still was
ongoing almost two-and-one-half years after Stockton East secured financing, Tr. 572-73
(Kauffman). Mr. Kauffman’s but-for model of infrastructure improvements, see PX 435; PX
563, which was based upon his “brainstorming session” with Stockton East staff, Tr. 238
(Kauffman), failed to account for the complexity and contingencies involved in constructing
this project. 34/ The court therefore finds it implausible that Stockton East would have
completed construction of the pipeline in 2000 and taken additional M&I water from 2001-
2004 if Reclamation had not breached the Contract beginning in 1999. 35/

       For the years 1999 and 2000, Stockton’s but-for analysis of its M&I water use was not
contingent upon the acceleration of the Peters Pipeline project. See PX 563 (column H); Tr.
363-64 (Kauffman) (describing “Enhancement #1” in PX 563). Mr. Kauffman projected that
Stockton East would have been able to take additional M&I water in 1999 and 2000 due to
the acceleration of other enhancements that would have increased the capacity of the DWTP
from 40 mgd to 45 mgd beginning in 1999. Tr. 238-39, 363-64 (Kauffman). However, the
evidence adduced at trial demonstrates that the DWTP already was operating at a capacity


       34/ See supra note 20.

        35/ To its credit, Stockton East showed that Cal Water and the City could have used
additional surface water during the breach years. The Urban Contractors submitted annual
reports to Stockton East during the breach years depicting how much surface water and
groundwater the Urban Contractors used for M&I purposes. See Tr. 140-41, 155-56
(Kauffman) (discussing PX 432). The court admitted PX 432 as a summary of those annual
reports. See PX 432, at SEWD122942-D to 43-D; Tr. 159. Those reports show that for each
year of the breach the total amount of groundwater pumped by the Urban Contractors was
greater than the amount of surface water that Stockton East purportedly would have run
through the DWTP but for the breach. Compare PX 432, at SEWD122942-D to 43-D
(columns labeled “wells”), with PX 563 (column K). Because the Urban Contractors had a
policy or practice of maximizing surface water use and reducing groundwater pumping, see
Tr. 174-75, 216-17 (Madison); Tr. 863-65 (Ferraro), the Urban Contractors would have
replaced most of their groundwater pumping with the additional surface water that would
have been available from Stockton East, Tr. 212-17 (Madison); Tr. 866-68 (Ferraro)
(discussing PX 432). However, the Urban Contractors’ demand for additional surface water
does not entitle Stockton East to expectancy damages, because Stockton East did not show
that it would have had the facilities in place to treat and deliver the additional water. See Tr.
223-24 (Madison).

                                               42
of 45 mgd in 1999 and 2000. As part of its application to the CDPH to increase the rated
capacity of the DWTP from 40 to 45 mgd, Stockton East placed particle counting equipment
on its filters to test the ability of the DWTP to properly treat water while operating at the 45-
mgd level. Tr. 233-35 (Kauffman). In 1999 the CDPH gave Stockton East approval to
operate the DWTP at the 45-mgd level for purposes of collecting data from the particle
counting equipment. Tr. 451 (Kauffman); see also PX 525. The CDPH’s approval of
Stockton East’s application contains a chart showing that Stockton East operated the DWTP
at the 45-mgd level during the majority of months in the May 1999 to August 2000 time
period. See Tr. 596 (Kauffman); PX 525, at SEWD 122436-D to 37-D. 36/ Moreover, on
September 26, 2000, the CDPH approved Stockton East’s application and granted Stockton
East a permit to operate the DWTP at a rated capacity of 45 mgd, meaning that the DWTP
was operating at a rated capacity of 45 mgd for at least the last three months of 2000. 37/ See
Tr. 598 (Kauffman); PX 525. Because the DWTP was already operating at a 45-mgd
capacity in 1999 and 2000 in the non-breach world, Stockton East has not shown that it
would have been able to treat additional water in those years but for the breach.

        Stockton East’s but-for model of M&I water use also fails to incorporate the costs that
it avoided due to Reclamation’s breach. A plaintiff’s expectancy damages recovery must be
reduced by the amount of avoided costs “in order to ensure that the [damages award] . . . does
not represent an overstatement of the loss fairly attributable to the breach.” Bluebonnet V,
339 F.3d at 1345; see also Carolina Power & Light, 573 F.3d at 1277. In Southern Nuclear
the Federal Circuit held that the breaching party bears the burden of production on avoided
costs and therefore must “identify the nature” of the costs that were avoided because of the
breach. 38/ See 637 F.3d at 1304. Defendant in this case identified the nature of the costs



        36/ Although these two pages were not admitted into the record, Mr. Kauffman
testified as to the former. See Tr. 596 (Kauffman). These pages therefore fall within the
scope of the court’s rule that, in restricting the admission of lengthy documents to the extent
that they are the subject of testimony, the court reserves the right to read other portions for
context. See supra note 33.

        37/ Stockton East argued in its post-trial reply brief, without citation to the record,
that the DWTP did not operate at 45 mgd “consistently” in 1999 and 2000. See Pl. Stockton
East’s Br. filed Dec. 10, 2012, at 15. However, Stockton East has not quantified this
inconsistency, and Mr. Kauffman’s analysis did not appear to take this contemporaneous
indication of the DWTP’s operating capacity into account. See Tr. 233-35 (Kauffman).

       38/ Although the Federal Circuit in that case noted the defendant’s “remarkable
silence about the nature and amount” of the avoided costs, the court remanded with
instructions that the defendant “must identify the nature of the avoided costs in question on
remand.” S. Nuclear Operating Co., 637 F.3d at 1304. The court reasoned that “[p]laintiffs

                                               43
that Stockton East would have avoided if it would have been able to take more M&I water
– the costs of transporting, treating, and distributing the water through the treatment plant.
See Def.’s Br. filed Nov. 29, 2012 [362], at 37 (citing PX 500, at 32). Defendant cites
Stockton East’s March 31, 2002 financial statement, which lists specific “Treatment Plant
Expenses” under several categories, including “Transmission & Distribution” and “Water
treatment.” PX 500, at 32; see Def.’s Br. filed Nov. 29, 2012 [362], at 37 (citing PX 500, at
32).

        Once the breaching party points out the nature of the avoided costs, the “burden
shift[s] to the plaintiff to incorporate those saved costs into its formulation of a plausible but-
for world.” S. Nuclear Operating Co., 637 F.3d at 1304. Neither Mr. Kauffman’s
formulation of M&I water use in the but-for world nor Mr. Harry’s calculation of Stockton
East’s damages, which was based upon Mr. Kauffman’s analysis, incorporated the water
treatment expenses that Stockton East avoided because of Reclamation’s breach. 39/ During
closing argument Stockton East’s counsel explained that avoided costs were a “nonissue” in
the case because “the vast majority of the cost that Stockton East incurs in its operation are
facilities costs, which are essentially fixed.” Closing Arg. Tr. 35-36 (Spaletta). However,
Mr. Ferraro testified that Stockton East incurs variable operating costs, which the Urban
Contractors then reimburse to Stockton East:

       [W]hat we pay Stockton East is a fixed amount based on their facilities, the
       cost of their facilities, and then an incremental amount based on the actual
       operating cost of those facilities, so . . . we would have been paying to
       Stockton East . . . those additional incremental operating costs[.]

Tr. 869 (Ferraro). Stockton East argues that these avoided costs would have been offset with
forgone revenue from the Urban Contractors and therefore should not be included in
Stockton East’s formulation of its expectancy damages. See Pl. Stockton East’s Br. filed
Dec. 10, 2012, at 17; see also Tr. 1329-30 (Harry). The court is perplexed why Stockton East
takes this position on expectancy damages, given its arguments in support of its mitigation


       38/ (Cont’d from page 43.)

cannot be expected to brainstorm every possible cost they would have saved in the non-
breach world. Hence, a defendant must move forward by pointing out the costs it believes
the plaintiff avoided because of its breach.” Id. (citing Mech-Con Corp. v. West, 61 F.3d
883, 886 (Fed. Cir. 1995)).

      39/ To the extent that Mr. Harry did address avoided costs, it was only to opine that
the amount that Stockton East would have paid to Reclamation in the but-for world would
have been offset by additional revenue to Stockton East. See Tr. 1329-30 (Harry).

                                                44
damages claim. Stockton East argues that it is entitled to mitigation damages even though
the Urban Contractors ultimately reimbursed Stockton East for its mitigation costs – the
amount paid to OID and SSJID for water purchased under the 1997 Transfer Agreement. 40/
See Pl. Stockton East’s Br. filed Nov. 22, 2012, at 22-23. Stockton East cites no legal
authority explaining why the court should treat avoided costs and mitigation costs differently
for purposes of assessing the impact of offsetting revenue from the Urban Contractors. See
id. The purpose of deducting avoided costs from an expectancy damages award is to “ensure
that the [damages award] . . . does not represent an overstatement of the loss fairly
attributable to the breach[.]” Bluebonnet V, 339 F.3d at 1345. Avoided costs therefore
should be deducted from a potential damages award, regardless of whether Stockton East
passed its cost savings on to its customers. Stockton East failed to meet its burden of
establishing a but-for scenario that incorporated the water treatment expenses avoided due
to the breach. See S. Nuclear Operating Co., 637 F.3d at 1304 (holding that plaintiff bears
the burden of persuasion with respect to avoided costs).

              2) Analysis of Stockton East’s projected agricultural water use
                    but for the breach

       Defendant’s damages expert, Ali Shahroody, noted that Mr. Kauffman’s analysis of
agricultural use but for the breach varied from a low of 152 acre-feet in one breach year to
a high of over 5,287 acre-feet in another breach year. Tr. 2188 (Shahroody); see also PX 563
(column N). Based on this observation, Mr. Shahroody concluded that Stockton East’s
projection of agricultural use in the but-for world was a “paper exercise[.]” Tr. 2188
(Shahroody). In other words, Stockton East’s estimate of agricultural use in the years 2000-
2004 was merely the delta between (1) the Build-Up Schedule (column Q in PX 563),
Stockton East’s actual total use of New Melones water (column G in PX 563), and (2)
Stockton East’s estimate of its M&I use but-for the breach (column M in PX 563). See Tr.
2188-89 (Shahroody).

        In its post-trial reply brief and at closing argument, Stockton East admitted that Mr.
Kauffman “artificially capped” his estimate of agricultural use but for the breach. Pl.
Stockton East’s Br. filed Dec. 10, 2012, at 14-15; Closing Arg. Tr. 21-22 (Spaletta).
Stockton East points out that Mr. Kauffman initially included greater amounts of agricultural
use in his but-for analysis, but revised those numbers downward to comply with the court’s
pretrial ruling that Stockton East could not seek damages exceeding the minimums listed in
the Contract’s Build-Up Schedule. Pl. Stockton East’s Br. filed Dec. 10, 2012, at 14-15;
Closing Arg. Tr. 21-22 (Spaletta). Because Reclamation’s breach in the years 1999-2004
was based on its failure to deliver the minimum volumes in the Build-Up Schedule, see


      40/ The court addresses these arguments in greater detail in Part III of the
“Discussion” section of this opinion.

                                             45
Stockton III, 583 F.3d at 1356-57, 1364-65, this court ruled that Stockton East could not
present evidence that it would have requested more than the Contract minimums for each
year of the breach. See Order entered Aug. 24, 2012, at 2-4

         Stockton East chose to present its model of the but-for world in a chart with
calculations that combined both its M&I and agricultural use. See PX 563. This court’s pre-
trial ruling did not require Stockton East to put on its case in this manner. See Order entered
Aug. 24, 2012, at 2-4. Stockton East’s estimates of M&I and agricultural use in the but-for
world rested on different premises: although its M&I use was contingent upon the Peters
Pipeline extension and the DWTP improvements, Stockton East did not need to use such
facilities to deliver water to some of its agricultural customers. Tr. 776-78 (Kauffman).
Given the different assumptions underlying its M&I and agricultural demand, Stockton East
could have presented an independent analysis of its agricultural use. Based on that
independent model, Stockton East could have argued in the alternative that, if the court
declined to award damages for M&I water, Stockton East had shown its expectancy damages
for agricultural water alone. The court instead is left with a projection of agricultural use that
represents the difference between the Build-Up Schedule and Stockton East’s M&I water
use. Thus, Stockton East’s calculation simply assumes that agricultural demand would equal
whatever supply of New Melones remained after Stockton East satisfied its M&I demand.

        Such an estimate cannot form the basis of a plausible but-for model because the
evidence shows that numerous factors, in addition to the breach, would have affected
agricultural demand for New Melones water. Mr. Kauffman indicated that the lack of
availability of New Melones water was not the only reason that it proved difficult for
Stockton East to convince farmers to convert from groundwater to surface water. Tr. 630-31
(Kauffman). To convert to surface water, a farmer must pay to install the necessary
infrastructure to connect to a pipeline or to divert the surface water from a natural stream
course. Id. For properties abutting the Peters Pipeline, which has some existing connections,
the cost for farmers would be at least $15,000.00 to $20,000.00. Tr. 630 (Kauffman). In
contrast, a diversion from a natural stream course could cost a farmer at least $50,000.00.
Tr. 631 (Kauffman). Mr. Kauffman also agreed that it was “difficult” to convert farmers to
surface water during the breach years because Stockton East charged farmers a higher rate
for surface water than for groundwater. Id.

       Stockton East insists that its estimate of additional agricultural use is plausible
because it reflects a conversion of 800 to 1,500 acres of farmland to surface water during the
breach years and Stockton East actually exceeded that level of conversion post-breach. See
Pl. Stockton East’s Br. filed Nov. 9, 2012, at 10. Although Mr. Kauffman stated that
Stockton East has converted more than 1,500 acres of farmland “since the breach period to
2010[,]” Tr. 377 (Kauffman), Stockton East did not present any evidence that such
conversions plausibly would have occurred during the 1999 to 2004 period if Reclamation


                                               46
began making the minimums available beginning in 1999. 41/ Under cross-examination Mr.
Kauffman revealed that his methodology for estimating additional agricultural use in the but-
for world involved only a simple comparison of agricultural use in 2010 and the 1999-2004
breach period:

       Q. How much of this agricultural water couldn’t have been delivered if the
       Peters pipeline had not been constructed at that period?

       A. I did not estimate that. As I explained before, once we saw the numbers,
       comparing 2010 numbers to 1999 and 2004 numbers, I did no further analysis,
       I just noted it was considerably more, so it wasn’t a concern of mine to split
       those numbers up.

Tr. 605 (Kauffman).

        On redirect Mr. Kauffman pointed to a large map of the Central Valley – PX 518 –
and explained that, without the six-mile extension to the Peters Pipeline, Stockton East would
have been able to serve the agricultural areas along Mormon Slough, Potter Creek, and the
portion of the Peters Pipeline extending from the constant head vault to the Mormon Slough.
Tr. 776-78 (Kauffman). Stockton East cites this testimony as evidence that these properties
“would easily hook-up and take the water.” See Pl. Stockton East’s Br. filed Dec. 10, 2012,
at 6 (citing Tr. 776-78 (Kauffman)). Contrary to Stockton East’s assertion, Mr. Kauffman
did not present any testimony regarding the approximate number of acres in these corridors
that had connections to the New Melones supply during the breach period. See Tr. 776-78
(Kauffman). To the extent this acreage did not have connections, Stockton East presented
no analysis showing how many acres converted to surface water post-breach and projecting
when those conversions would have occurred absent a breach. 42/ Given the dearth of


       41/ In fact, Stockton East’s records of actual agricultural use suggest that such
conversions may not have taken place until five or six years after the end of the breach
period. See PX 434 (column labeled “USBR AGR”) (showing a spike in the use of New
Melones water for agricultural purposes in the years 2010 and 2011).

        42/ One exhibit in the record – PX 437 – contains a chart entitled “Estimated Timing
of Potential Surface Water Users” and shows agricultural acres listed next to each breach
year. See PX 437, at SEWD122954-D. This exhibit was discussed only during Mr.
Kauffman’s cross-examination, and that discussion did not include a specific reference to the
chart in question. See Tr. 605-13, 2473-74 (Kauffman). Stockton East did not affirmatively
rely on PX 437 to prove its estimate of additional agricultural demand, and the court was
provided with little information regarding its significance. See id. That exhibit therefore
cannot form the basis of Stockton East’s expectancy damages award for agricultural use.

                                             47
evidence regarding Stockton East’s projected demand for agricultural water and Stockton
East’s own admission that other factors made it difficult to convert farmers to surface water,
Stockton East has not met its burden of establishing a plausible but-for model of its
agricultural use. 43/

              3) Analysis of Stockton East’s groundwater recharge and “proxy cost
                    of cover” methods for calculating expectancy damages

       A plaintiff seeking expectancy damages bears the burden of establishing a “plausible
but-for world.” See, e.g., S. Nuclear Operating Co., 637 F.3d at 1304 (citation omitted);
Kan. Gas and Electric, 685 F.3d at 1371 (citations omitted). As discussed above, Stockton
East has not met its burden of demonstrating that it plausibly would have had the ability to
take additional M&I and agricultural water during the breach years. Both the groundwater
recharge and “proxy cost of cover” methods for calculating damages rest upon Mr.
Kauffman’s flawed analysis that Stockton East would have had the ability to request an
additional 82,955 acre-feet of water during the breach years. See Tr. 1292-93 (Harry); PX
554, at 5; Pl. Stockton East’s Br. filed Nov. 9, 2012, Ex. B. Accordingly, the court rejects
Stockton East’s expectancy damages calculations because they are not based on a plausible
but-for model.

        Even assuming that Mr. Kauffman’s analysis plausibly established Stockton East’s
additional water use in the but-for world, the court is not in a position to award expectancy
damages based upon Stockton East’s groundwater recharge calculation because Stockton
East’s groundwater recharge approach to calculating its damages is speculative and
inherently unreliable. See, e.g., Ind. Mich. Power Co., 422 F.3d at 1373 (explaining that
recovery of speculative damages is precluded) (citing San Carlos Irrigation & Drainage
Dist., 111 F.3d at 1563). Although Stockton East has an option to purchase the property on
which the north site facility would be located, it has not exercised that option and does not
have another opportunity to exercise that option until October 15, 2013. See Tr. 639-40
(Kauffman). Furthermore, Stockton East has not completed the environmental work
associated with the north site facility, and its Board of Directors has not voted to approve
construction of the project. Tr. 640-41 (Kauffman). Stockton East also has not obtained the
considerable financing it needs to build the project. Id. Although Stockton East is in


        43/ Stockton East has not argued that it would have requested additional water but
for the breach for purposes of selling water outside its boundaries. Article 10 of the Contract
provides that “[w]ater furnished to the Contractor pursuant to this contract shall not be sold,
exchanged, or otherwise disposed of for use outside the Contractor’s service area without
prior written consent of the Contracting Officer.” PX 36, at 00368. Stockton East presented
no evidence regarding whether the contracting officer would have provided such written
consent in the but-for world.

                                              48
negotiations with the Urban Contractors to obtain financing, the Urban Contractors have not
agreed to finance the project. Id. Mr. Kauffman admitted on cross-examination that the
north site facility may never be built. Tr. 641-42 (Kauffman). Stockton East’s effort to
monetize its expectancy damages thus rests on a wholly speculative construct. Stockton East
may be tasked to recharge the groundwater basin, but it has never built this recharge facility.
No case decided by the Federal Circuit involving expectancy damages has endorsed an award
for an activity undertaken in the but-for world that has been pyramided exclusively on
assumptions regarding its hypothesized construction and operation in the future. Given the
numerous uncertainties associated with the north site recharge facility, Stockton East’s
groundwater recharge method is speculative and unreliable.

          Citing the Restatement (Second) of Contracts, Stockton East argues that its
groundwater recharge method for calculating damages is proper because expectancy damages
“‘take account of any special circumstances that are peculiar to the situation of the injured
party, including his . . . own needs and opportunities.’” Pl. Stockton East’s Br. filed Nov.
9, 2012, at 15 (quoting Restatement (Second) of Contracts § 344 cmt. a (1981)); see also
Closing Arg. Tr. 7-10 (Spaletta). The court is mindful of Stockton East’s mission to address
the overdraft of the groundwater basin and acknowledges that Stockton East as a non-profit
may have sold its Contract water at a loss to effectuate its public mission. Nonetheless, the
law of contracts does not provide for an award of damages based upon the construction of
a facility that was not contemplated by the Contract, was not foreseeable under the Contract,
has not been built, and may never be built. The Restatement commentary cited by Stockton
East illustrates no scenario under which a court should award such damages to take account
of the non-breaching party’s peculiar circumstances. In fact, the sentence immediately
following the “special circumstances” language states: “In practice, however, the injured
party is often held to a more objective valuation of his expectation interest because he may
be barred from recovering for loss resulting from such special circumstances on the ground
that it . . . cannot be shown with sufficient certainty.” See Restatement (Second) of Contracts
§ 344 cmt. b. In this case Stockton East’s groundwater recharge computation is speculative
and therefore cannot form the basis of its damages.

       Stockton East also characterizes its groundwater recharge calculation as a form of
“consequential damages[.]” See Pl. Stockton East’s Br. filed Dec. 10, 2012, at 18-19.
Stockton East cites two cases for the proposition that “[c]onsequential damages are based on
estimates of what would have been if the contract had been performed, rather than on actual
expenditures made.” See id. (citing Simeone v. First Bank Nat’l Ass’n, 73 F.3d 184 (8th Cir.
1996); Nyquist v. Randall, 819 F.2d 1014 (11th Cir. 1987)). Neither case, however, is
analogous to the damages claim in the case at bar. In Simeone the Eighth Circuit upheld an
award of consequential damages for defendant’s breach of a contract related to the sale of
a vintage automobiles and parts. 73 F.3d at 188-89. The consequential damages award was
based on the market value of the vehicles and parts at the time of the breach, in addition to


                                              49
their appreciated value two years after the breach. Id. at 189. Plaintiff’s damages award in
Simeone did not include specific performance or the costs of actually building the facilities
to construct or re-create the vehicles and auto parts. Id. Simeone therefore does not support
Stockton East’s claim that it is entitled to damages based upon the costs of constructing a
direct recharge facility to replenish the basin with the water it would have purchased but for
the breach. In Nyquist the Eleventh Circuit affirmed an award of consequential damages,
based upon lost profits, to a cattle buyer who lacked the financial capacity to purchase
substitute cattle. 819 F.2d at 1017-19. Nyquist also is distinguishable from the present case
because the buyer’s lost profits in Nyquist were established based upon a pre-existing lease
that the buyer had arranged with a third party at the time of the contract. Id. at 1015-17. In
contrast, Stockton East’s claim for groundwater recharge damages is speculative because it
is based upon the hypothetical cost of constructing a facility that was not contemplated at the
time of contracting and may never be built.

       To the extent Stockton East had established a plausible but-for model, its “proxy cost
of cover” method may have provided a legally cognizable basis for computing its expectancy
damages. 44/ See Restatement (Second) of Contracts § 344 cmt. b (explaining that when


        44/ Given this matter’s lengthy history and in an abundance of caution, a discussion
of the proper computation of Stockton East’s “proxy cost of cover” damages is appropriate.
Central presented the expert testimony of Dr. Smith, who was qualified as an expert on the
sport-market value of water with respect to Central during the breach. See Tr. 1992. Dr.
Smith examined twenty-one one-year water transactions involving water rights originating
on the San Joaquin River or its tributaries – the geographic market where both Central and
Stockton East are located. See Tr. 1997-2002 (Smith). Using those data, Dr. Smith opined
that the spot-market value of water was $60 per acre-foot in 1999, $80 in 2000, $90 in 2001,
$135 in 2002, $85 in 2003, and $120 in 2004. See Tr. 2009-18 (Smith). The evidence
offered by Central would be appropriate for consideration in determining an annual spot-
market price for Stockton East.

        The court also heard testimony as to the spot-market price of water from Messrs.
O’Laughlin and Landry. Neither witness’s testimony is entitled to as much weight as that
of Dr. Smith. Mr. O’Laughlin testified only as to the price OID wanted to charge for transfer
water during the breach period, which was $100 per acre-foot. See Tr. 899-900
(O’Laughlin). Such a limited data set is less reflective of the broader market examined by
Dr. Smith. Mr. Landry’s testimony is not as probative as Dr. Smith’s for a similar reason.
Although Mr. Landry examined short-term contracts within the San Joaquin Basin, as Dr.
Smith did, he examined only transactions in which Reclamation acquired water, excluding
other transactions to protect data gathered by his company that he considered proprietary.
See Tr. 956-57 (Landry). Mr. Landry testified that he found the Reclamation transactions
to be representative, but offered no further support for that statement. See Tr. 957 (Landry).

                                              50
non-breaching party with special circumstances “cannot recover for loss that he could have
avoided by arranging a substitute transaction on the market . . . his recovery is often limited
by the objective standard of market price.” (citation omitted)). However, Stockton East also
failed to meet its burden of establishing a but-for scenario that incorporated the water
treatment expenses that it avoided due to the breach. Accordingly, the court cannot award
expectancy damages in this case based upon the “proxy cost of cover” method.

II. Costs of unused overhead

       1. Standards for awarding damages for overhead costs

        Stockton East also seeks to recover the “stranded costs” associated with the portion
of the NMCS that went unused as a result of Reclamation’s breach. Pl. Stockton East’s Br.
filed Nov. 9, 2012, at 28-29. Damages for overhead costs are recoverable where the
Government’s breach caused the non-breaching party to incur the overhead costs. See
Energy Nw., 641 F.3d at 1309-10 (explaining that plaintiff must “present a sufficient basis
for making the trial court reasonably certain that the claimed damages [for overhead
expenses] were caused by the breach”); cf Precision Pine & Timber, 596 F.3d at 834
(declining to award damages for fixed costs associated with operating sawmill because costs
“were not directly related to the . . . contract [at issue] and not a direct result of the
[breach]”). In the SNF context, for example, the Government’s breach caused the plaintiffs
to mitigate by constructing and maintaining new facilities for SNF storage. See, e.g., S. Cal.
Edison Co. v. United States, 655 F.3d 1319, 1322 (Fed. Cir. 2011) (affirming an award for
overhead costs associated with building, staffing, and maintaining new facility for SNF
storage). Because the overhead costs associated with the facilities were incurred as a result
of the breach, the utilities were entitled to recover damages for the overhead expenses. See
id. (distinguishing an SNF plaintiff from the plaintiff in Precision Pine “[b]ecause the [SNF
storage] facilities had not existed prior to the Government’s breach, and indeed were
necessitated by the breach”); Energy Nw., 641 F.3d at 1308-10 (affirming recovery of
overhead expenses allocated to mitigation projects undertaken because of Government’s
breach).

      Courts also have awarded damages for overhead expenses when the Government
imposed a delay or suspension of the contract work and thereby interrupted or reduced the


       44/ (Cont’d from page 50.)

Thus, Mr. Landry’s analysis was less reliable than Dr. Smith’s, and the court gives his
testimony less weight than that of Dr. Smith. Accordingly, if Stockton East had proven its
expectation damages, the proper spot-market price to use in any damages calculation is that
advanced by Dr. Smith’s testimony.

                                              51
contractor’s stream of income. See, e.g., Interstate Gen. Gov’t Contractors, Inc. v. West, 12
F.3d 1053, 1057-58 (Fed. Cir. 1993). If the suspension or delay prevents the contractor from
taking additional work to absorb its overhead costs, the contractor may be entitled to recover
damages for those costs. See, e.g., Nicon, Inc. v. United States, 331 F.3d 878, 882-83 (Fed.
Cir. 2003); Melka Marine, Inc. v. United States, 187 F.3d 1370, 1374-75 (Fed. Cir. 1999).
In such cases the contractor’s overhead damages are calculated using the three-step Eichleay
formula. Capital Electric Co. v. United States, 729 F.2d 743, 747 (Fed. Cir. 1984) (restating
formula of Eichleay Corp., ASBCA No. 5183, 60-2 BCA ¶ 2688 (1960), aff’d on reconsid.,
61-1 BCA ¶ 2894); see also Nicon, 331 F.3d at 882-83.

       2. The parties’ arguments

        To support its damages claim for “stranded costs,” Stockton East primarily relies upon
the testimony of Mr. Kauffman and two experts – Elaine Vastis Conti and Mr. Harry. See
Pl. Stockton East’s Br. filed Nov. 9, 2012, at 13-14. Ms. Conti was qualified as an expert in
identifying and allocating the costs of water conveyance facilities, Tr. 1173-74, and
performed a calculation purporting to represent the costs that Stockton East incurred for the
portion of the NMCS that went unused as a result of Reclamation’s breach, Tr. 1161, 1202-
03 (Conti). Ms. Conti relied upon data from Stockton East’s audited financial statements and
documents from Stockton East depicting the costs of the NMCS. Tr. 1175-80 (Conti)
(discussing PX 490 and PX 497-503). Ms. Conti also based her analysis on Stockton East’s
water flow data in the breach world, PX 411, and Mr. Kauffman’s estimate of Stockton
East’s additional water use in the non-breach world, PX 563; see Tr. 1175, 1195-97 (Conti).

        Ms. Conti’s testimony regarding her methodology distills to the following level of
coherence. First, she calculated the annual depreciation expense of the NMCS by dividing
the actual construction cost of each component of the NMCS by the expected service life of
each component. Tr. 1187-91 (Conti); see, e.g., PX 556, at 1 (column c). Second, Ms. Conti
computed the rate of return for this annual depreciation expense by weighting Stockton
East’s costs of debt and equity in each breach year. Tr. 1191-92 (Conti); see, e.g, PX 556,
at 1 (column j). Using this rate of return, Ms. Conti calculated an annual return on
investment, see, e.g., PX 556, at 1 (column k), which represents a proxy for the interest that
Stockton East paid in each breach year to finance its debt service for the NMCS. Tr. 1192-93
(Conti). Ms. Conti then compared the water flows that would have occurred in the NMCS
in the but-for world, see PX 563, with the water flows that occurred in the actual world, see
PX 411; Tr. 1195-97 (Conti); PX 557, at 1. Based upon that comparison, Ms. Conti
determined a percentage of each component of the NMCS that went unused as a result of the
breach in each year from 1999 to 2004. Tr. 1197-99 (Conti); PX 557, at 2. Finally, Ms.
Conti multiplied those percentages by the sum of the annual depreciation and the annual
return on investment for each year. Tr. 1200 (Conti); see, e.g., PX 556, at 1 (column o).
That calculation represents her estimate of the cost of the unused portion of the NMCS in


                                             52
each breach year. Tr. 1203 (Conti); see PX 555. Based on Ms. Conti’s analysis, Stockton
East seeks recovery of “stranded costs” in the amount of $1,599,960.00. PX 555; Pl.
Stockton East’s Br. filed Nov. 9, 2012, at 29; see Tr. 1205 (Conti).

       Stockton East points out that its damages expert Mr. Harry reviewed Ms. Conti’s
analysis and concluded that it was part of a “lost profits” analysis. Pl. Stockton East’s Br.
filed Nov. 9, 2012, at 14 (citing Tr. 1278 (Harry)). Mr. Harry also confirmed the accuracy
of Ms. Conti’s computations and opined that her approach was conservative. Id. (citing Tr.
1280-81 (Harry)).

        Defendant challenges Stockton East’s “stranded costs” claim on three separate
grounds. 45/ First, defendant points out that Stockton East’s stranded costs model is not
based upon the assumption that Reclamation’s breach deprived Stockton East of revenues
that Stockton East would have used to absorb its fixed costs. Def.’s Br. filed Nov. 29, 2012
[362], at 38-39. In that respect Stockton East’s stranded costs claim is distinct from those
cases where overhead damages are awarded based on the Eichleay formula. Id. at 39.
Second, defendant argues that Stockton East would have incurred its overhead costs
regardless of the breach. Id. at 38-39. Stockton East’s stranded costs claim therefore is not
analogous to the overhead damages awarded to the SNF plaintiffs. Id. at 39-40. Third,
defendant contends that the “rate of return” component of Stockton East’s stranded costs
claim is nothing more than the addition of interest to Stockton East’s claim for depreciation
costs and therefore is unrecoverable under the no-interest rule set forth in 28 U.S.C. § 2516.
Id. at 40.

       3. Analysis of Stockton East’s “stranded costs” damages

        Ms. Conti’s calculation of “stranded costs” relied upon Mr. Kauffman’s estimate of
Stockton East’s additional water use but for the breach. See Tr. 1175, 1195-97 (Conti); PX
557, at 1. As discussed in Part I.3. supra, Mr. Kauffman’s analysis – summarized in PX 563
– did not demonstrate that Stockton East would have had the ability to take an additional
82,955 acre-feet of water from Reclamation during the breach years. Mr. Kauffman’s
estimate of Stockton East’s additional M&I and agricultural water use but for the breach
consequently was not established, even given the relaxed plausibility standard used in but-for
scenarios. Because Ms. Conti’s methodology was based upon that flawed analysis, Stockton
East’s “stranded costs” claim fails.




      45/ See supra note 18. The pretrial order allowed Stockton East to make its overhead
damages claim, but did not rule on whether Stockton East’s methodology for presenting it
had been recognized in the case law. See Order entered Aug. 24, 2012, at 18-19.

                                             53
        Even assuming that Mr. Kauffman’s analysis plausibly shows that Stockton East
would have taken an additional 82,955 acre-feet of New Melones water but for the breach,
Stockton East has not established that its “stranded costs” are a recoverable form of damages
in the case at bar. The court ruled at trial that Ms. Conti was not qualified to testify as to
whether her analysis was supported by reliable principles and methodologies with respect to
calculating damages in a breach of contract case involving unused capacity in a water
conveyance system. Tr. 1174. Stockton East’s counsel proffered that it did not call Ms.
Conti to opine on such matters and that Mr. Harry would vouch for the propriety of claiming
stranded costs as an item of damages in this case. Tr. 1157 (Spaletta).

       Mr. Harry testified on direct examination that Stockton East’s “stranded costs” claim
was a proper measure of damages because it was “one part of” a “lost profits” or “lost
contribution margin” approach to damages:

       Q. [T]urning to the second category of damages that you described relating to
       the costs of the New Melones conveyance system, first can you describe for
       me why you identified that as a proper measure of damages.

       A. Because it is one part of the normally accepted lost profits approach to
       calculating damages, and it’s a very focused, conservative portion of that. So
       if you were doing a full lost profits computation, you first would project all of
       the lost sales volume and attended [sic] revenue. But the total of those
       amounts would overstate damages because to have attained those lost
       revenues, you would have had to spend certain amount of monies that were not
       incurred or saved. They’re called saved expenses.
              So typically the damages are the difference between the lost revenue
       and all of the saved expenses, which is the net lost profits or the lost
       contribution margin towards coverage of all otherwise fixed costs.
              All that has been done in this claim is to target into that contribution
       marginal loss and only claim the portion of that that would have gone towards
       coverage of the already incurred fixed costs for the [NMCS].

Tr. 1277-78 (Harry). When cross-examined, Mr. Harry clarified that the standard practice
for calculating lost profits is to subtract the additional costs that a plaintiff would have
incurred if the breach had not occurred from plaintiff’s lost revenue. Tr. 1315-16 (Harry).

       As Mr. Harry testified, a lost profits analysis takes into account both revenues and
costs. Yet, Ms. Conti revealed under cross-examination that she had little knowledge of how
the Urban Contractors actually paid Stockton East for the New Melones water. Ms. Conti
did not know, for example, whether Reclamation’s breach caused any changes to the Urban
Contractors’ payments to Stockton East or whether the Urban Contractors paid a higher


                                              54
monthly payment when the NMCS was operating at a higher capacity. Tr. 1222-25 (Conti).
Ms. Conti also admitted that she did not know if Stockton East would have received an
additional $1.6 million in revenue – the approximate amount of Stockton East’s “stranded
costs” – absent the breach. Tr. 1224 (Conti).

        During voir dire Ms. Conti explained that she had experience calculating rates for
water and wastewater utilities, Tr. 1148 (Conti), and that her methodology was very similar
to her approach for calculating wholesale rates, Tr. 1154-55 (Conti). Under this approach
a water utility can determine the amount of its fixed costs that can be factored into the
wholesale rates that it charges each customer. Tr. 1160 (Conti). Although Ms. Conti’s
methodology may provide an acceptable means of discerning how a utility should set its rates
to recapture its costs, her methodology does not measure how Stockton East would have
generated revenues to absorb its costs. As discussed in Part III.3. infra, ¶¶ 4-5 of the Second
Amended Contract – not the rate-making approach described by Ms. Conti – govern the
calculation of the Urban Contractors’ base monthly payment to Stockton East. See DX 807,
at 14, 16-17. Because Ms. Conti’s analysis ignored how Stockton East generates revenues
from its customers, it is not the “lost profits” approach to damages defined by Mr. Harry.

       Mr. Harry explained on cross-examination that it was not necessary for Ms. Conti to
consider how much revenue Stockton East would have received but for the breach because
her model isolated only the fixed costs attributable to those portions of the NMCS that went
unused as a result of the breach. Tr. 1317 (Harry). He concluded that this “conservative”
approach therefore measured only the “unrecovered” or “unabsorbed” fixed costs. Id. Ms.
Conti’s model, however, did not account for how Stockton East would have been paid by its
Urban Contractors under the Second Amended Contract and consequently cannot measure
how much of its fixed costs Stockton East would have absorbed if Reclamation had not
breached. 46/

       Although Mr. Harry considered Stockton East’s “stranded costs” claim to be a “lost
profits” analysis, his testimony indicates that the claim is more akin to a claim for unabsorbed




        46/ Defendant justifiably moved to strike Ms. Conti’s testimony. Tr. 1167-70
(Snyder). After defendant renewed its motion to strike following re-direct, Tr. 1238-45
(Snyder), the court deferred ruling on the motion, Tr. 1255-56. Ms. Conti’s testimony
stretched her expertise; her professional experience involved calculating rates for water
utilities, and she had never calculated damages or stranded costs in any context. Tr. 1153-55
(Conti). For the reasons discussed above, the court denies defendant’s motion to strike, but
affords no weight to Ms. Conti’s testimony.

                                              55
overhead damages based upon the Eichleay formula. 47/ In those cases overhead damages
are awarded when the Government imposes a delay or suspension of contract work and
thereby interrupts or reduces the contractor’s stream of income. See, e.g., Interstate Gen.
Gov’t Contractors, 12 F.3d at 1057-58. As discussed above, if the contractor can show that
the suspension or delay prevented it from taking on other work to absorb its fixed overhead
costs, the contractor may be entitled to recover damages for those unabsorbed overhead costs.
See, e.g., Nicon, 331 F.3d at 882-83; Melka Marine, 187 F.3d at 1375. In the instant case,
neither Ms. Conti nor Mr. Harry correlated Ms. Conti’s methodology for calculating
wholesale utility rates to the actual rate structure employed by Stockton East. Because Ms.
Conti’s calculation ignored how Stockton East’s customers would have reimbursed Stockton
East for the undelivered New Melones water, Stockton East has not shown that it would have
absorbed its fixed costs in the but-for world.

        Stockton East also appears to analogize its “stranded costs” claim to the overhead
damages in the SNF cases. See Pl. Stockton East’s Br. filed Nov. 9, 2012, at 29 (citing
Kansas Gas & Electric, 95 Fed. Cl. at 303). In those cases the Government’s breach caused
the utilities to mitigate by constructing and maintaining new facilities for SNF storage. See,
e.g., S. Cal. Edison, 655 F.3d at 1321 (affirming award for overhead costs associated with
building, staffing, and maintaining new facility for SNF storage). Because the overhead
expenses associated with the facilities were incurred due to the breach, those plaintiffs were
entitled to recover damages for the overhead costs. See Energy Nw., 641 F.3d at 1308-10
(affirming recovery of overhead expenses allocated to mitigation projects undertaken because
of Government’s breach); Kansas Gas & Electric, 95 Fed. Cl. at 303 (collecting cases), aff’d
in part, rev’d in part, 685 F.3d 1361. Unlike the SNF plaintiffs, however, Stockton East has
not shown that it incurred its overhead costs as a result of the breach. See Tr. 1224 (Conti)
(“Q. In fact, it is not your opinion that Stockton incurred an additional $1.6 million in costs
as a result of the breach. Isn’t that right? A. That’s correct.”); Tr. 1246 (Spaletta) (“There
really is no dispute that the actual costs of the [NMCS] during the breach period did not
change as a result of the breach as far as the total cost.”). Although the Contract required
Stockton East to construct the NMCS, see Tr. 95 (Kauffman); PX 36, at 13 (¶ 7(b)),
Stockton East admits that it would have incurred the costs of the NMCS regardless of the


       47/ On cross-examination Mr. Harry also testified, as follows:

       Q. Your understanding of what the term “stranded costs” means as it is being
       used in this litigation is that the term refers to the investment in the [NMCS]
       that was left there unrecovered because of the breach. Is that right?

       A. Yes.

Tr. 1316 (Harry).

                                              56
breach, see Tr. 1246 (Spaletta). Stockton East’s reliance on the SNF cases is misplaced, and
therefore the court cannot award overhead damages on that basis.

III. Cost of cover

       1. Standard for awarding damages for cost of cover

       Stockton East also seeks $6,740,890.78 in damages to recover its mitigation costs
associated with the 1997 Transfer Agreement. See Pl. Stockton East’s Br. filed Nov. 9,
2012, at 17-23. “A non-breaching party may generally recover its mitigation costs incurred
in a reasonable effort to avoid loss caused by a breach, even if its efforts prove
unsuccessful.” Old Stone Corp., 450 F.3d at 1368 (citing Restatement (Second) of Contracts
§§ 350 cmt. h, 347 cmt. c (1981)). Mitigation damages “are intended to reimburse a non-
breaching party to a contract for the expenses it incurred in attempting to rectify the injury
the breach caused it.” Citizens Fed. Bank, 474 F.3d at 1320.

        A non-breaching party has a duty to mitigate its damages. Ind. Mich. Power Co., 422
F.3d at 1375; Robinson v. United States, 305 F.3d 1330, 1336 (Fed. Cir. 2002) (“‘As a
general rule, a party cannot recover damages for loss that he could have avoided by
reasonable efforts.’” (quoting Restatement (Second) of Contracts § 350, cmt. b (1981))). The
obligation to mitigate damages arises “‘[o]nce a party has reason to know that performance
by the other party will not be forthcoming[.]’” Ind. Mich. Power Co., 422 F.3d at 1375
(quoting Restatement (Second) of Contracts § 350, cmt. b). A non-breaching party therefore
may recover its costs of mitigation even if it incurred those costs prior to the breach. Id.
When mitigating damages from a breach, the non-breaching party must “make only ‘those
efforts that are fair and reasonable under the circumstances.’” First Heights Bank, FSB v.
United States, 422 F.3d 1311, 1316 (2005) (quoting Home Sav. of Am., 399 F.3d at 1353.

        One way for a buyer to reasonably mitigate a seller’s breach is to “cover” or, in other
words, to enter into a transaction to obtain substitute goods from another seller. See Hughes
Commcn’s Galaxy, Inc. v. United States, 271 F.3d 1060, 1066 (Fed. Cir. 2001) (explaining
that the Uniform Commercial Code “provides useful guidance in applying general contract
principles”); LaSalle Talman Bank, 317 F.3d at 1373 (“[R]eduction of loss through a
substitute transaction is generally a direct mitigation of damages.”); see also Restatement
(Second) of Contracts § 350 cmt. e (discussing meaning of “substitute”). To constitute
reasonable cover, the substitute goods need not be identical to those involved in the contract,
as long as they are “‘commercially usable as reasonable substitutes under the
circumstances.’” Hughes Commcn’s, 271 F.3d at 1066 (quoting U.C.C. § 2-712 cmt. 2); see
also Restatement (Second) of Contracts § 350 cmt. e (“Whether an available alternative
transaction is a suitable substitute depends on all the circumstances, including the similarity
of the performance and the times and places that they would be rendered.”). When a buyer


                                              57
covers, the buyer’s remedy for the seller’s breach equals the difference between the cover
price and the contract price plus any other losses, such as consequential or incidental
damages. See Hughes Commcn’s, 271 F.3d at 1066 (citing U.C.C. § 2-712; Farnsworth on
Contracts, § 12.11 (2d ed. 1988).

       2. The parties’ arguments

       Stockton East contends that it “covered” for Reclamation’s failure to deliver water
under the Contract by purchasing more expensive New Melones water from OID and SSJID
pursuant to the ten-year, 1997 Transfer Agreement. See Pl. Stockton East’s Br. filed Nov.
9, 2012, at 17-18. Stockton East therefore seeks mitigation damages of $6,740,890.78, which
represent the difference between the cover price of the water that Stockton East purchased
from OID and SSJID from October 1999 through September 2009 and the Contract price of
that same amount of water. See id.; PX 403A.

        Citing the purposes of the Contract and Stockton East’s investment in the NMCS,
Stockton East argues that the 1997 Transfer Agreement was foreseeable mitigation. Pl.
Stockton East’s Br. filed Nov. 9, 2012, at 19-20. Stockton East also contends that it would
not have entered the 1997 Transfer Agreement but for Reclamation’s failure to perform
under the Contract. Id. at 18. Although the 1997 Transfer Agreement was negotiated and
signed prior to the 1999-2004 breach period, see Tr. 791-96 (Zolezzi), Stockton East points
out that it began pursuing a substitute water supply in response to its June 1993 meeting with
Reclamation and FWS, when the Government indicated that it would not honor the Contract
due to its obligations under the CVPIA, Pl. Stockton East’s Br. filed Nov. 9, 2012, at 19; see
Tr. 791-96 (Zolezzi). Stockton East therefore analogizes its pre-breach mitigation efforts to
those of the SNF plaintiffs who, in response to the Government’s 1994 announcement that
it would not meet its contractual obligations in the future, began taking mitigatory steps prior
to the breach. See Pl. Stockton East’s Br. filed Nov. 9, 2012, at 19-20 (citing Kan. Gas &
Electric, 95 Fed. Cl. at 275; Ind. Mich. Power Co., 422 F.3d at 1375).

        Stockton East also emphasizes that the terms of the 1997 Transfer Agreement –
including its duration, price, and “take or pay” provisions – were reasonable in light of the
prevailing market conditions at the time Stockton East negotiated the 1997 Transfer
Agreement. See id. at 20-21 (“In short, this was the best deal that Stockton East could make
under the circumstances.”). To prove that its mitigation options were limited, Stockton East
relies on the testimony of Ms. Zolezzi and Mr. O’Laughlin regarding their negotiation of the
1997 Transfer Agreement. Id.

        Defendant responds that Stockton East is not entitled to mitigation damages because
Stockton East had no duty to mitigate when it entered the 1997 Transfer Agreement. Def.’s
Br. filed Nov. 29, 2012 [362], at 18-21. Relying on Indiana Michigan, defendant argues that


                                              58
the duty to mitigate prior to the time for performance arises only when the breaching party
expressly repudiates its obligation to perform and “unequivocally announce[s]” that it will
be unable to meet its contractual obligations. See id. at 18 (quoting Ind. Mich. Power Co.,
422 F.3d at 1375). Defendant minimizes the impact of Stockton East’s 1993 meeting with
Reclamation and FWS, charging that “an off-the-cuff remark by an official who is unfamiliar
with the contract in question is hardly an authoritative statement regarding the likelihood of
the Government’s future performance.” Id. at 20-21. Any uncertainty regarding
Reclamation’s future performance, defendant postulates, resulted from uncertainty that was
inherent in the Contract itself – not the breach. Id. at 18-19. Defendant observes, for
example, that Reclamation’s non-performance in 1994 and 1995 was excused under the
shortage provision of Article 9, and the parties understood at the time of contracting that little
or no water might be available to Stockton East under the Contract due to drought conditions.
See id. at 19-20.

       For similar reasons defendant also contends that Stockton East’s decision to enter into
the 1997 Transfer Agreement was not caused by Reclamation’s impending breach, but
instead resulted from Stockton East’s desire to obtain a “continual” and guaranteed water
supply that would not vanish in dry years. See id. at 21-22 (citing Tr. 799-800 (Zolezzi)).
Because the Contract’s shortage provision did not guarantee such a guaranteed supply to
Stockton East, defendant urges that Stockton East entered into the 1997 Transfer Agreement
for “sound business reasons” that “had nothing to do with any future breach by
Reclamation.” Id. at 22-23.

        Defendant also argues that the 1997 Transfer Agreement did not constitute reasonable
or foreseeable mitigation. Id. at 23-28. Defendant reasons that a transaction functioning as
a “true substitute” for Reclamation’s performance (1) would not require water deliveries in
critically dry years, (2) would allow for the purchase of varying amounts of water each year,
and (3) would have a short term. Id. at 24. Because the 1997 Transfer Agreement was a
“take or pay” contract, defendant concludes that it was not a true substitute and therefore was
not a reasonable approach to mitigation. Id. at 24-26. Given the terms of the 1997 Transfer
Agreement, defendant also charges that it was not a foreseeable form of mitigation. Id. at
27-28.

       Even if the court were to find that the 1997 Transfer Agreement constituted
foreseeable and reasonable mitigation, defendant argues, Stockton East is precluded by law
from recovering $4,472,698.36 in mitigation costs for the cover water that it purchased in the
years following the 1999-2004 breach period. Id. at 28-29. Because no court has
determined that Reclamation has breached the Contract in any year from 2005 to 2009,
recovery for those years is not legally permissible. Id. Relying on SNF cases, defendant
argues that, because Stockton East is claiming a partial breach, Stockton East may recover
as damages only “those costs incurred prior to the date of its suit,” which in this case is the


                                               59
date of the amended complaint – April 20, 2004. Id. at 29 (quoting Ind. Mich. Power Co.,
422 F.3d at 1377).

       Defendant finally contends that Stockton East is not entitled to an award of mitigation
damages because Stockton East actually did not bear any costs associated with the purchase
of water under the 1997 Transfer Agreement. See id. at 29-31. Defendant emphasizes that
the Urban Contractors were the ultimate end users of the purchased water, see Tr. 879
(Ferraro), and the 1997 Transfer Agreement actually referred to the Urban Contractors as the
“Purchasers,” PX 450, at 1; see Def.’s Br. filed Nov. 29, 2012 [362], at 9, 29. In fact,
Stockton East and the Urban Contractors contemporaneously entered into a second
agreement, which required the Urban Contractors to pay Stockton East for the payments
Stockton East made to OID and SSJID under the 1997 Transfer Agreement. See DX 873,
at SJ04504; Def.’s Br. filed Nov. 29, 2012 [362], at 9; Tr. 475-76 (Kauffman). Because the
Urban Contractors were required to pay Stockton East for the costs of the transferred water,
defendant maintains that an award of mitigation damages to Stockton East would violate the
fundamental rule that “the non-breaching party should not be placed in a better position
through the award of damages than if there had been no breach.” Def.’s Br. filed Nov. 29,
2012 [362], at 29 (quoting Bluebonnet V, 339 F.3d at 1344-45).

         Stockton East rejoins that the Urban Contractors’ reimbursement for the transfer water
is irrelevant under the precedent of the Court of Federal Claims and the Federal Circuit. See
Pl. Stockton East’s Br. filed Nov. 9, 2012, at 22-23; Pl. Stockton East’s Br. filed Dec. 10,
2012, at 13-14. Stockton East primarily relies on Hughes Communications, arguing that the
Court of Federal Claims ruled that the Government may not assert a defense that contract
damages recovery should be reduced because the plaintiff recovered from its customers the
costs caused by the Government’s breach. See Pl. Stockton East’s Br. filed Nov. 9, 2012,
at 22 (citing Hughes Commc’ns Galaxy, Inc. v. United States, 38 Fed. Cl. 578, 581-82
(1997), aff’d, 271 F.3d 1060). Stockton East notes that the court in Hughes Communications
rejected defendant’s “pass-through” or indemnification defense based on the following
rationale:

       The breaching party is the wrongdoer and should not be able to take advantage
       of such arrangements by shifting those costs to third parties. Whether the
       contracting party who suffers the breach is getting paid twice for its costs is a
       question best worked out between it and its customers. The court should not
       be in the position of assessing whether the prices to the customers reflect the
       risk of such pass-through, or whether there is an obligation to repay any
       recovery from the government to those customers.

Id. at 22-23 (quoting Hughes Commc’ns, 538 Fed. Cl. at 581-82). Arguing that the same
rationale should apply to the case at bar, Stockton East asks the court similarly to reject


                                              60
defendant’s claim that Stockton East is not entitled to cost of cover damages due to the
payments it received from the Urban Contractors. Id.; Pl. Stockton East’s Br. filed Dec. 10,
2012, at 13-14.

       Stockton East also counters that defendant misconstrues Stockton East’s claim for cost
of cover damages incurred from 2005 to 2009. Pl. Stockton East’s Br. filed Dec. 10, 2012,
at 12-13. Stockton East argues that its damages claim for the years 2005 to 2009 is not based
on the Reclamation’s anticipated future non-performance in those years, but, rather, is “part
and parcel of Stockton East’s mitigation of the breach from 1999-2004.” See id. at 13.

       3. Analysis of costs of cover damages

              1) Recovery of mitigation damages prior to the 1999-2004 breach period

       Stockton East negotiated and signed the 1997 Transfer Agreement prior to the 1999-
2004 breach period. See Tr. 791-96 (Zolezzi). Relying on Indiana Michigan, defendant
argues that Stockton East had no duty to mitigate because such a duty arises only when one
party expressly repudiates by “unequivocally announc[ing]” that it will be unable to meet its
contractual obligations. See Def.’s Br. filed Nov. 29, 2012 [362], at 18-21. In Indiana
Michigan the Federal Circuit held that pre-breach mitigation damages could be recoverable,
noting that “[i]t is beyond debate that because the government unequivocally announced in
1994 that it would not meet its contractual obligations beginning in 1998, the utilities were
in fact obligated to take mitigatory steps.” Ind. Mich. Power Co., 422 F.3d at 1375.
However, the Federal Circuit clarified in a subsequent case that, in the SNF context, the duty
to mitigate could have attached before the Government made its “unequivocal” 1994
announcement:

       [T]he Government seeks to minimize its exposure by clinging to individual
       words and phrases in the Indiana Michigan opinion. In particular, the
       Government urges this court to enforce the statement: “It is beyond debate that
       because the government unequivocally announced in 1994 that it would not
       meet its contractual obligations beginning in 1998, the utilities were in fact
       obligated to take mitigatory steps.” [Ind. Mich. Power Co., 422 F.3d at 1375.]
       This statement, however, does not set 1994 as the earliest possible date for any
       duty to mitigate. Rather, this passage reveals that this court in Indiana
       Michigan viewed 1994 as the latest possible date for the utilities’ duty to
       mitigate, not the earliest. The full context of the statement shows this
       meaning. In the introductory clause (“It is beyond debate”), this court
       recognizes that no one could reasonably dispute that a duty to mitigate existed
       in 1994. This statement, however, is not a ruling that the duty to mitigate did



                                             61
       not arise until 1994, but instead suggests that the duty could have arisen
       earlier.

Yankee Atomic, 536 F.3d at 1275.

        Defendant in the case at bar likewise cannot rely on Indiana Michigan to argue that
Stockton East’s duty to mitigate did not arise until Reclamation unequivocally announced in
any given year that it would not meet the Build-Up Schedule. As the Federal Circuit
explained in Indiana Michigan, “[m]itigation is appropriate where a reasonable person, in
light of the known facts and circumstances, would have taken steps to avoid damage.” 422
F.3d at 1375 (citing Robinson, 305 F.3d at 1334). The appropriateness of a plaintiff’s pre-
breach mitigation is a fact-specific inquiry. See Yankee Atomic, 536 F.3d at 1275-77
(contrasting factual records in Indiana Michigan and Yankee Atomic).

       Stockton East first contacted OID and SSJID regarding substitute water supplies in
1993 because of a meeting with Reclamation and FWS that occurred earlier that year. Tr.
790-95 (Zolezzi). Ms. Zolezzi testified that, during a June 1993 meeting, representatives of
Reclamation and FWS confirmed to Stockton East that 250,000 acre-feet of New Melones
water had been re-allocated from CVP contractors to fish. Tr. 792 (Zolezzi). Reclamation
and FWS also told the districts that they had made a “back of an envelope” determination that
this same amount would be needed for fish in every year as a result of the CVPIA. Id.
According to Ms. Zolezzi, Reclamation and FWS made clear that “this prescription would
continue and in only the wettest years might [the districts] see some water.” 48/ Tr. 795
(Zolezzi). In response to the representations made at the 1993 meeting, Stockton East soon
began negotiating with OID and SSJID to obtain substitute surface water supplies that it
could deliver through its newly-constructed NMCS. Tr. 792 (Zolezzi). Given the
representations made by Reclamation and FWS at the June 1993 meeting, Stockton East had
reason to know that Reclamation would not perform in the future. Therefore, it was
appropriate and reasonable for Stockton East to begin taking mitigatory steps as early as
1993.

       The court disagrees with defendant’s assertion that, by the time Stockton East signed
the 1997 Transfer Agreement, “Stockton East had ample reason to believe that Reclamation
would perform under the [Contract].” See Def.’s Br. filed Nov. 29, 2012 [362], at 18. In


       48/ Defendant blithely dismisses the importance of the June 1993 meeting. See
Def.’s Br. filed Nov. 29, 2012 [362], at 20-21. As discussed in the “Facts” section of this
opinion, the court finds Ms. Zolezzi’s testimony on point credible. Her testimony regarding
the June 1993 meeting echoed Mr. Roberts’s testimony at the damages trial, see Tr. 1636
(Roberts), and the testimony during the liability trial almost six years earlier of Messrs.
Steffani and Roberts, see Liab. Trial Tr. 170 (Roberts); Liab. Trial Tr. 425-26 (Steffani).

                                             62
1994 and 1995, Reclamation failed to provide the minimum volumes of water listed in the
Build-Up Schedule. Stockton III, 583 F.3d at 1352-53. After more than a decade of
litigation in federal district court and transfer of the case to the Court of Federal Claims in
2004, the parties received a ruling by this court in 2007, later affirmed by the Federal Circuit,
that Reclamation’s non-performance in 1994 and 1995 was excused because the shortage
provision of Article 9 applied to those years. See id. at 1363-64. The operation of the IPO
in 1997 and 1998 also did not give Stockton East reason to believe that Reclamation would
perform in the future. The districts agreed to the IPO in early 1997 as a short-term
modification of their water allocations under the Contracts for 1997 and 1998. Stockton III,
583 F.3d at 1353; Stockton I, 75 Fed. Cl. at 346. Stockton East understood at the time that
the IPO was an “interim stopgap measure” that would give time to the parties to “negotiate
a more equitable long-term operations agreement.” Stockton I, 75 Fed. Cl. at 356 (citations
and internal quotation marks omitted). Contrary to defendant’s assertion, Stockton East
therefore did not have ample reason to believe that Reclamation’s full performance would
be forthcoming after the two-year period in which the IPO was intended to operate.

       Due to the Government’s representations at the June 1993 meeting, in addition to the
events that transpired in the following years, it was reasonable for Stockton East to begin
taking steps to mitigate Reclamation’s breach. Furthermore, a multi-year water transfer
involves compliance with CEQA’s substantial environmental requirements, and accordingly
can be difficult and time-consuming to implement. See Tr. 811-14 (Zolezzi); Tr. 918
(O’Laughlin). Given the lengthy process involved in obtaining water under such an
agreement, Stockton East’s decision to begin pursuing mitigation shortly after the June 1993
meeting was reasonable under the circumstances.

        Defendant urges this court to avoid “expanding the holding” of Indiana Michigan
beyond the SNF context, where “‘an action for . . . total breach . . . [was] foreclosed by
statute[.]’” Def.’s Br. filed Dec. 21, 2012 [365], at 5-6 (quoting Ind. Mich. Power Co., 422
F.3d at 1374). The Federal Circuit in Indiana Michigan disagreed with the trial court in that
case that pre-breach mitigation damages are per se unrecoverable in cases of a partial breach.
Ind. Mich. Power Co., 422 F.3d at 1374. The court’s reasoning was not limited to the SNF
context:

       Holding pre-breach damages unrecoverable, or that pre-breach damages are
       recoverable only for anticipatory repudiation leading to a total breach, would,
       however, compromise a party’s obligation to mitigate damages. The general
       rule must be reconciled with a party’s obligation to mitigate damages which
       befall it during the periods both antedating and postdating the breach. . . . Our
       breach-of-contract cases have dealt only with the duty to mitigate damages
       incurred after a total breach. But we see no reason why efforts to avoid
       damages in contemplation of a partial breach should not also be recoverable.


                                               63
       . . . Hence, mitigation damages are available for pre-breach costs should the
       obligee elect to treat the obligor’s breach as partial[.]

Id. at 1375 (internal citations omitted). As the SNF plaintiffs did, Stockton East received
notice of defendant’s future non-performance and began taking mitigatory steps shortly
thereafter. 49/ The fact that Stockton East began pursuing a cover transaction before the
breach should not foreclose recovery of damages for its cost of cover during the breach years.

              2) Causation

       A party seeking mitigation damages must prove causation. See, e.g., Yankee Atomic,
536 F.3d at 1275-77. At the damages trial, Ms. Zolezzi repeatedly stated that Stockton East
pursued a water supply from OID and SSJID in response to the June 1993 meeting. Tr. 792-
95, 821, 851-52 (Zolezzi). The representations made by Reclamation and FWS at the June
1993 meeting caused Stockton East to be concerned that its newly-built, expensive
conveyance facility would go unused. Tr. 851-52 (Zolezzi). Shortly thereafter Stockton East
began seeking a substitute surface water supply from the New Melones Reservoir, Tr. 852
(Zolezzi), and naturally looked to obtain that substitute supply from OID and SSJID, two of
the largest water-rights holders on the Stanislaus River, Tr. 792-93 (Zolezzi). Mr.
O’Laughlin – the OID representative involved in negotiating the 1997 Transfer Agreement
– similarly testified as to his understanding that Stockton East was seeking transfer water as
an “alternative supply of water to help meet [its] needs.” Tr. 889 (O’Laughlin).

        Defendant ignores the impact of the 1993 meeting and urges this court to find that
Stockton East entered into the 1997 Transfer Agreement for an entirely different reason – to
secure a dry-year water supply. Def.’s Br. filed Nov. 29, 2012 [362], at 7-9. To support this
argument, defendant relies upon Ms. Zolezzi’s trial testimony that Stockton East wanted to
obtain a “reliable” and “continual” water supply from OID and SSJID. See id. at 7, 22-23
(citing Tr. 799-800 (Zolezzi)). Contrary to defendant’s repeated assertions, Ms. Zolezzi’s
references to a “reliable” and “continual” water supply do not support the notion that
Stockton East entered the 1997 Transfer Agreement for the sole purpose of obtaining a dry-
year water supply. See Tr. 799-800 (Zolezzi). Furthermore, the 1997 Transfer Agreement
actually did not guarantee Stockton East a continuous water supply that persisted through
critically dry years. OID and SSJID were required to deliver only 12,500 acre-feet in years
for which the forecast of inflow to the New Melones Reservoir was between 450,000 and



       49/ The court also observes that, unlike the SNF plaintiffs, Stockton East is not
seeking damages for mitigation costs incurred in the years prior to the breach. See, e.g., Ind.
Mich. Power Co., 422 F.3d at 1372. Stockton East seeks mitigation damages for the six
breach years – 1999 to 2004 – and the five years following the breach period. See PX 403A.

                                              64
499,000 acre-feet; in years for which the forecast was less than 450,000 acre-feet, OID and
SSJID were required to deliver only 8,000 acre-feet. See PX 450, at 3.

        Defendant reasons that, because the 1983 Contract did not guarantee a reliable and
continuous water supply, Reclamation did not enter the 1997 Transfer Agreement to avoid
losses that would result from Reclamation’s breach. See Def.’s Br. filed Nov. 29, 2012
[362], at 2; Def.’s Br. filed Dec. 21, 2012 [365], at 4. Defendant appears to exaggerate the
uncertainties inherent in the 1983 Contract, as it mistakenly claims that “Reclamation was
not required to offer the Build-Up allocations, or any allocations at all, to Stockton East in
years in which the agency reasonably determined that a water shortage existed.” Def.’s Br.
filed Dec. 21, 2012 [365], at 4 (citing Stockton III, 583 F.3d at 1363-64; Stockton I, 75 Fed.
Cl. at 364). The Federal Circuit did not hold that the water shortage provision could be
invoked upon Reclamation’s reasonable determination that a water shortage existed. See
Stockton III, 583 F.3d at 1363-64, 1369. Rather, the Federal Circuit explained that Article
9 is a force majeure provision that applies to causes “beyond the control of the United
States,” such as a drought, earthquakes, an internal failure of the dam, or other such causes.
Id. at 1361-62. The 1983 Contract required Reclamation to make available the minimum
quantities listed in the Build-Up Schedule, but provided that Reclamation would not be liable
in any year where the force majeure provision properly applied. See id. Stockton East’s
search for a “reliable” surface water supply from OID and SSJID therefore constituted an
effort to mitigate losses that would result from Reclamation’s impending breach of the 1983
Contract.

        The record reflects that Stockton East also had other reasons – in addition to
mitigation – for negotiating and signing the 1997 Transfer Agreement. When cross-
examined, Ms. Zolezzi agreed that Stockton East was concerned about receiving as much
water as possible from OID and SSJID during dry years. Tr. 841 (Zolezzi). Mr. O’Laughlin
testified that a “myriad of factors” – including drought and hydrology – factored into the
unreliability of the New Melones water supply and thus motivated Stockton East’s search for
transfer water. Tr. 889-90 (O’Laughlin); see also Tr. 903, 909-11 (O’Laughlin). Although
Stockton East also was influenced by its desire to obtain a surface water supply in drought
years, its primary goal – in light of the statements made at the June 1993 meeting – was to
obtain a replacement supply of New Melones water. Tr. 835-36, 855-56 (Zolezzi). Stockton
East is not precluded from obtaining its cost of cover damages because it had multiple
reasons for entering into the 1997 Transfer Agreement. See Cal. Fed. Bank, 395 F.3d at
1268 (explaining that breach need not be “the sole factor or sole cause” of the damages, and
therefore “[t]he existence of other factors operating in confluence with the breach will not
necessarily preclude recovery based on the breach” (citing Farnsworth on Contracts § 12.1,
at 150-51)); cf. Ind. Mich. Power Co., 422 F.3d at 1376 (affirming denial of mitigation
damages because plaintiff’s purported mitigation “was purely a business judgment which it
would have had to pursue irrespective of [defendant’s] breach” (emphasis added)).


                                             65
              3) Reasonableness

        A party seeking mitigation damages also must demonstrate that its mitigation efforts
are “fair and reasonable under the circumstances.” See First Heights Bank,, 422 F.3d at 1316
(quoting Home Sav. of Am., 399 F.3d at 1353). Stockton East reasonably mitigated in the
years 1999-2004 by obtaining surface water supplies from the same water source – the New
Melones Reservoir – at a price below the spot-market price in the years Reclamation
breached the Contract. See Restatement (Second) of Contracts § 350 cmt. e (“Whether an
available alternative transaction is a suitable substitute depends on all the circumstances,
including the similarity of the performance and the times and places that they would be
rendered.”).

        In arguing that Stockton East’s mitigation was not reasonable, defendant emphasizes
the differences between the 1983 Contract and the 1997 Transfer Agreement. See Def.’s Br.
filed Nov. 29, 2012 [362], at 24. Defendant specifically notes that the 1997 Transfer
Agreement guaranteed water deliveries in dry and critically dry years, whereas the 1983
Contract did not. Id. As discussed above, defendant misunderstands the nature of the
Contract’s shortage provision; Article 9 is a force majeure provision that applies only to
causes “beyond the control of the United States[.]” Stockton III, 583 F.3d at 1361-62. To
the extent the 1983 Contract and 1997 Transfer Agreement contained different requirements
regarding deliveries in critically dry years, those discrepancies do not render the 1997
Transfer Agreement unreasonable. See Hughes Commcn’s, 271 F.3d at 1066 (explaining
that, to constitute reasonable cover, the substitute goods need not be identical to those
involved in the contract, as long as they are “‘commercially usable as reasonable substitutes
under the circumstances’” (quoting U.C.C. § 2-712 cmt. 2)).

        Defendant also contends that the 1997 Transfer Agreement was an unreasonable form
of mitigation because it contained a “take or pay” provision requiring Stockton East to take
a certain quantity of transfer water in every breach year, regardless of the amount allocated
by Reclamation under the Contract. Def.’s Br. filed Nov. 29, 2012 [362], at 25. Two
participants involved in negotiating the 1997 Transfer Agreement – Ms. Zolezzi and Mr.
O’Laughlin – testified at the damages trial. According to Ms. Zolezzi, Stockton East did not
want the “take or pay” provision in the 1997 Transfer Agreement, but OID and SSJID
“insisted” on including that provision in the agreement. Tr. 802 (Zolezzi). Ms. Zolezzi
explained that the take-or-pay provision was necessary for OID and SSJID because “their
goal of entering into a water transfer agreement was to obtain consistent income . . . and
[OID and SSJID] needed to be able to know each year how much they were going to have
to fund their system improvements and that they would have it over the term of the contract.”
Tr. 802 (Zolezzi). Mr. O’Laughlin – the lead negotiator for OID and SSJID – echoed Ms.
Zolezzi’s testimony, explaining that OID and SSJID “would know that X amount of dollars
would be coming in every year, and then based on those dollars coming in, [OID and SSJID]


                                             66
could then have a revenue stream that they could price projects, do conservation measures
and things that they wanted to do.” Tr. 895-96 (O’Laughlin). Both Ms. Zolezzi and Mr.
O’Laughlin indicated that this consistent stream of income, made possible by the “take or pay
provision,” eventually enabled OID and SSJID to undertake a variety of infrastructure
improvements and conservation programs. 50/ Tr. 801 (Zolezzi); Tr. 916 (O’Laughlin).

        Given the tenor of the negotiations, it was reasonable for Stockton East to accept the
demands of OID and SSJID regarding the “take or pay” provision. Negotiations were
contentious and broke down several times. Tr. 795-97 (Zolezzi). The market conditions also
influenced the negotiating leverage of the parties. Following the June 1993 meeting,
Stockton East looked to obtain a substitute surface water supply from the New Melones
Reservoir because New Melones water easily could be conveyed through the NMCS. Tr. 793
(Zolezzi). OID and SSJID are two of the largest water rights holders on the Stanislaus
River, Tr. 791 (Zolezzi); Tr. 891-93 (O’Laughlin), and few other water rights holders on the
Stanislaus were looking to sell water at that time, Tr. 805-06 (Zolezzi). Ms. Zolezzi also
testified that other entities, including Reclamation and FWS, were looking to buy water from
OID and SSJID. Tr. 806 (Zolezzi). Because the market conditions dictated that OID and
SSJID had negotiating leverage over Stockton East, it was reasonable for Stockton East to
agree to their demands to include the “take or pay” provision in the 1997 Transfer
Agreement.

        Defendant points to the year 2000 as a “paradigmatic example” of how the “take or
pay” provision rendered Stockton East’s mitigation unreasonable. See Def.’s Br. filed Nov.
29 [362], 2012, at 25. In that year Reclamation allocated a total of 90,000 acre-feet to both
Stockton East and Central. Stockton III, 583 F.3d at 1353; Stockton I, 75 Fed. Cl. at 347.
However, in 2000 Stockton East purchased only 7,193 acre-feet from Reclamation under the
Contract, see PX 434, and 33,352 acre-feet from OID and SSJID pursuant to the 1997
Transfer Agreement, see PX 403A. According to Mr. Kauffman, Stockton East took
deliveries under the 1997 Transfer Agreement – rather than the 1983 Contract – due to the
“take or pay” nature of the 1997 Transfer Agreement. Tr. 760-61 (Kauffman). However,
because it was reasonable for Stockton East to agree to include the “take or pay” provision
in the 1997 Transfer Agreement, the court finds that Stockton East’s award for cost of cover



        50/ While pointing to the testimony described above, defendant asserts – without
citation to other record evidence – that Stockton East’s desire for a dry-year water supply
influenced its decision to agree to the “take or pay” provision. See Def.’s Br. filed Nov. 29,
2012 [362], at 8. However, Mr. O’Laughlin testified that, to obtain the dry-year water
supply, Stockton East agreed to take a reduced amount of water in dry years in exchange for
a higher price. Tr. 903 (O’Laughlin); see also PX 450, at 3-4. The court is satisfied with this
explanation.

                                              67
damages should not be reduced due to its failure to exhaust the allocations made by
Reclamation in the year 2000. 51/

       Defendant also contends that the mitigation was unreasonable because Stockton East
could have purchased water on the spot market through a series of one-year transactions.
Def.’s Br. filed Nov. 29, 2012 [362], at 26. Such transactions were possible, in defendant’s
view, because Central made three one-year agreements with SSJID from 2002-2004, and
Stockton East itself purchased water on a short-term basis from OID and/or SSJID from
2007-2009. Id. Although the evidence suggests that Stockton East could have covered by
purchasing water on the spot market, it would not have been able to obtain the price that it
desired by entering into one-year agreements. Stockton East wanted to obtain a substitute
supply of water at a price similar to the price that it would have paid Reclamation, Tr. 804
(Zolezzi), and ultimately obtained a cover price roughly $10 per acre-foot greater than the
Contract price for M&I water, Compare PX 450, at 3, with Jt. Stipl. ¶ 5. According to the
three witnesses who provided testimony regarding the spot-market price of water during the
six-year breach period, the spot-market price generally far exceeded the price Stockton East
paid under the 1997 Transfer Agreement. 52/ See Tr. 899-900 (O’Laughlin); Tr. 940-42
(Landry); Tr. 2010-18 (Smith); PX 426, at 6; see PX 622, Att. 3. Stockton East therefore
acted reasonably by forgoing the spot market to obtain a substitute supply at a lower
price through a multi-year transaction. 53/

              4) Foreseeability

       Defendant disputes the characterization of the 1997 Transfer Agreement as
foreseeable mitigation because it contained a “take or pay” provision. See Def.’s Br. filed



        51/ For similar reasons defendant also contends that Stockton East’s damages award
should not include its costs of cover for the year 1999. See Def.’s Br. filed Nov. 29, 2012
[362], at 26-27. Defendant points to the graph in PX 551 indicating an unused “East Side
CVP Allocation” of roughly 30,000 acre-feet of the 90,000 acre-feet allocated in 1999. See
id.; see PX551, at 2-13. As discussed supra note 14, the court finds that Reclamation
allocated only 60,000 acre-feet to the districts in 1999, as reflected in this court’s 2007
liability opinion.

        52/ Defendant does not assert, and the record does not show, that Stockton East
would have been able to obtain the $15 per acre-foot price that Central received from SSJID
for its spot purchases from 2002-2004.

      53/ However, as discussed in the court’s discussion of Stockton East’s mitigation
damages for the years 2005 to 2009, Stockton East did not show that the price of its transfer
water was contingent upon agreeing to a ten-year term.

                                             68
Nov. 29, 2012 [362], at 28 (“Reclamation could not have foreseen that its failure to comply
with the Build-Up Schedule in some years would cause Stockton East to commit itself to
purchases of water in every year, without regard to Reclamation’s actual performance in that
year.”). Although the Federal Circuit has applied a foreseeability analysis to mitigation
damages, see Vt. Yankee Nuclear Power Corp. v. United States, 683 F.3d 1330, 1344-45
(Fed. Cir. 2012); Yankee Atomic, 536 F.3d at 1275 (noting Indiana Michigan’s
acknowledgment of “the propriety of pre-breach mitigation damages for plaintiffs who can
prove foreseeability, causation, and reasonableness”), defendant misunderstands the
foreseeability requirement. Reasonable foreseeability requires “‘merely that the injury
actually suffered must be one of a kind that the defendant had reason to foresee and of an
amount that is not beyond the bounds of reasonable prediction.’” Anchor Sav. Bank, 597
F.3d at 1364 (quoting 11 Joseph M. Perillo, Corbin on Contracts § 56.7, at 108).

         Reclamation had reason to foresee that Stockton East would seek to mitigate by
obtaining substitute surface water supplies from water-rights holders on the Stanislaus River
from 1999 to 2004. The 1983 Contract recites that Reclamation was furnishing the water for
“irrigation, municipal, industrial, domestic, and other beneficial uses” and that
“[I]nvestigations by [Reclamation] indicate that [each district] has a present and potential
need for an irrigation and a municipal and industrial water supply[.]” PX 36, at 00352-53.
Moreover, the Contract expressly required Stockton East to construct conveyance facilities
to transport water from the New Melones reservoir to Stockton East’s boundaries. PX 36,
at 00364. Given the location of the required conveyance facilities, Reclamation should have
been aware that Stockton East’s options for obtaining a substitute supply in the event of a
breach would be limited to the Stanislaus River. OID and SSJID are two of the largest water
rights holders on the Stanislaus River (followed by Reclamation), Tr. 791 (Zolezzi); Tr. 891-
93 (O’Laughlin), and few other water rights holders on the Stanislaus were looking to sell
water at that time, Tr. 805-06 (Zolezzi). As discussed above, Stockton East therefore had
little leverage in negotiating the 1997 Transfer Agreement, and the “take or pay” provision
was reasonable, given the negotiating positions of OID and SSJID. The court accordingly
finds that Reclamation had reason to foresee that Stockton East would cover by purchasing
the substitute supplies from OID and SSJID from 1999 to 2004.

              5) Recovery for the years 2005 to 2009

        Although Stockton East seeks over $6 million in cost of cover damages, more than
$4 million of that amount represents the difference between the cover price and the Contract
price for water purchased in the years 2005 to 2009. See PX 403A. As defendant correctly
observes, no court has determined that Reclamation breached the Contract in any year from
2005 to 2009. See Def.’s Br. filed Nov. 29, 2012 [362], at 28; Def.’s Br. filed Dec. 21, 2012
[365], at 8. Because no ruling issued on liability as to those years, recovery for those years
is precluded to the extent that Stockton East seeks damages based upon Reclamation’s non-


                                             69
performance from 2005 to 2009. The Federal Circuit confronted this result in Indiana
Michigan, where the SNF plaintiff sought damages for its forecasted future investment in the
construction of a private storage facility for housing SNF. 422 F.3d at 1372-73. The court
concluded that, because the plaintiff’s claim was premised upon a partial breach – in contrast
to a total breach – “damages were limited to those costs incurred prior to the date of its suit.”
Id. at 1377-78. In the present case, Stockton East treated Reclamation’s breach as a partial
breach of the Contract, and it therefore may not recover damages based upon Reclamation’s
non-performance in the years following the breach period. See id.; Scott Timber Co. v.
United States, 692 F.3d 1365, 1379 (Fed. Cir. 2012) (quoting Yankee Atomic, 536 F.3d at
1280).

        In its post-trial reply brief, Stockton East postured that the holding in Indiana
Michigan regarding future damages is inapplicable to this case because Stockton East does
not allege that its mitigation costs incurred from 2005-2009 “are based on [Reclamation’s]
future non-performance.” See Pl. Stockton East’s Br. filed Dec. 10, 2012, at 13. Stockton
East instead characterizes these costs as “part and parcel of Stockton East’s mitigation of the
breach from 1999-2004.” Id. Although Stockton East provided the court with little
additional guidance on how to conceptualize its 2005-2009 costs, Stockton East’s damages
claim for those years falls under the category of incidental damages. 54/

       When a buyer covers, the buyer’s remedy equals the difference between the cost of
cover and the contract price, in addition to any incidental losses. Hughes Commc’ns, 271
F.3d at 1066 (citing U.C.C. § 2-712; Farnsworth on Contracts § 12.11). Incidental losses
include “costs incurred in a reasonable effort, whether successful or not, to avoid loss[.]”
Restatement (Second) of Contracts § 347 cmt. c, § 350 cmt. h (“Under the rule stated in §
347, costs incurred in a reasonable but unsuccessful effort to avoid loss are recoverable as
incidental losses.”); Am. Fed. Bank, FSB v. United States, 72 Fed. Cl. 586, 597 (2006)
(quoting Restatement (Second) of Contracts § 347 cmt. c)). The U.C.C. clarifies that
incidental damages resulting from a seller’s breach must be “reasonable” or “reasonably




       54/ In response to the court’s suggestion at closing argument that the 2005-2009 costs
represented incidental damages, Stockton East’s counsel replied:

       I suppose you could characterize them as incidental damages . . . but, frankly,
       they’re part of the cost of cover because when Stockton East mitigated by
       purchasing the transfer water it was obligated to pay for 30,000 acre-feet of
       water for 10 years. That was the price tag for the mitigation.

Closing Arg. Tr. 32-33 (Spaletta).

                                               70
incurred[.]” 55/ U.C.C. § 2-715; see also U.C.C. § 2-712 (instructing that a buyer’s damages
for cost of cover includes incidental damages as defined by U.C.C. § 2-715).

        The evidence adduced at trial did not show that the costs incurred by Stockton East
under the 1997 Transfer Agreement for the years 2005 to 2009 were reasonable mitigation.
Citing Ms. Zolezzi’s trial testimony, Stockton East posits that “the 10-year term secured the
reliable supply [Stockton East] needed at an affordable price.” Pl. Stockton East’s Br. filed
Dec. 10, 2012, at 13 (citing Tr. 800, 804, 806). The evidence demonstrates that Stockton
East would not have been able to obtain the price that it desired by entering into a one-year
transfer agreement, but the evidence does not show that the price was contingent upon
Stockton East’s agreeing to a ten-year term. In contrast to the “take or pay” provision, the
ten-year term was not a contractual provision that OID and SSJID insisted upon including
in the 1997 Transfer Agreement. Compare Tr. 802 (Zolezzi), with Tr. 804 (Zolezzi). In fact,
Ms. Zolezzi explained that Stockton East pushed for a longer-term of “15 to 20 years” but
that the “term ended up at 10 because . . . [OID and SSJID] were stretching themselves” in
terms of projecting their long-term water supplies and demands. Tr. 805-06 (Zolezzi). Ms.
Zolezzi also added that the parties “didn’t know if they could get along well enough to have
a long-term agreement” and therefore negotiated an “out in the contract” that would enable
the agreement to be terminated prior to its expiration. 56/ Tr. 806-07 (Zolezzi). The record
does not support Stockton East’s position that purchasing 30,000 acre-feet of water each year
from 2005-2009 was the “price tag” of Stockton East’s mitigation during the breach years.
See Closing Arg. Tr. 33 (Spaletta). Stockton East consequently has not shown that its
purchases for the years 2005-2009 were a reasonable expense that it incurred to mitigate
Reclamation’s breaches in the years 1999 to 2004. 57/



       55/ Although the Uniform Commercial Code is a model code, Linear Tech. Corp. v.
Micrel, Inc., 275 F.3d 1040, 1048 (Fed. Cir. 2001), the Federal Circuit has explained that the
“Uniform Commercial Code provides useful guidance in applying general contract
principles[,]” Hughes Commncn’s, 271 F.3d at 1066.

       56/ The “out” clause referenced by Ms. Zolezzi appears to be included in ¶ 3 of the
1997 Transfer Agreement: “Once all approvals are obtained and water is delivered to
Purchasers under this Agreement, Purchasers may terminate this Agreement upon two years
prior notice after the first five years.” PX 450, at 3.

       57/ Under Stockton East’s theory of mitigation, its incidental losses far exceed its
actual cost of cover for the six breach years. See PX 403A. If Stockton East had succeeded
in obtaining the twenty-year term it desired, see Tr. 805 (Zolezzi), its “incidental” losses
would extend to the year 2019 and likely would be several times greater than the differential
between the cover price and the Contract price for the six breach years. Such an absurd
result further undercuts the notion that Stockton East reasonably incurred the costs of
purchasing water in the five years following the six-year breach period.

                                             71
        Relying on Yankee Atomic, Stockton East’s fallback position is that it is entitled to
recover its mitigation costs for 2005-2009 even though the transfer water may have been
“unnecessary” during those years. Pl. Stockton East’s Br. filed Dec. 10, 2012, at 13 (citing
Yankee Atomic, 536 F.3d at 1276). In Yankee Atomic some of the plaintiff’s mitigation
costs ultimately proved unnecessary because the plaintiff shut down some of its facilities
more than a decade earlier than it had initially planned. Yankee Atomic Electric Co. v.
United States, 73 Fed. Cl. 249, 278-79 (2006); see also Yankee Atomic, 536 F.3d at 1276.
Nonetheless, the plaintiff’s mitigation expenses were recoverable because the court found
that the mitigation was reasonable, foreseeable, and caused by the Government’s breach.
Yankee Atomic, 536 F.3d at 1276-77. In contrast, Stockton East has not shown that its
expenses for the years 2005 to 2009 were reasonable costs incurred in mitigating
Reclamation’s breach for the years 1999 to 2004.

              6) Reimbursement by the Urban Contractors

        Once again, the parties have left the court with the task of fleshing out the interstices
of the contracts involved in this dispute. Although the 1997 Transfer Agreement refers to
both the Urban Contractors and Stockton East as the “Purchasers,” PX 450, at 1, that contract
does not appear to contain a provision requiring the Urban Contractors to reimburse Stockton
East for the transfer water. At the damages trial, two witnesses – Messrs. Ferraro and
Kauffman – briefly testified regarding how Stockton East received payments from the Urban
Contractors for water purchased under the 1997 Transfer Agreement. Mr. Ferraro explained
that the costs of the transfer water “were passed on into the base monthly payment to both
Cal Water and the other urban contractors.” Tr. 879 (Ferraro). On cross-examination Mr.
Kauffman agreed that, under a contemporaneous agreement between Stockton East and the
Urban Contractors, the Urban Contractors had to pay Stockton East the amount of money that
Stockton East paid to OID and SSJID. Tr. 476 (Kauffman). Paragraph 2(b) of that
contemporaneous agreement concerned such payments, Tr. 475 (Kauffman), and stated:
“Water and costs shall be apportioned among the Urban Contractors in the manner set forth
in Paragraph 4 H of the Second Amended Agreement.” DX 873, at SJ04504. Paragraph 4H
of the Second Amended Contract establishes a formula by which Stockton East calculates
the annual percentages of water “produced” by each Urban Contractor. See DX 807, at 14.
Those percentages are applicable to ¶ 5 of the Second Amended Contract, see id., which
deals with the Urban Contractors’ payments to Stockton East, see id. at 16. However, ¶ 5
contains numerous sub-paragraphs affecting the amount of the base monthly payment made
by the Urban Contractors. See, e.g., id. at 17 (¶ 5A(4)). These multiple provisions and
complex mechanisms governing the Urban Contractors’ base monthly payment to Stockton
East were not developed adequately at trial. Further explication of the Second Amended
Contract therefore is necessary to understand the extent to which Stockton East received
reimbursement from the Urban Contractors through the base monthly payment.


                                               72
        To understand how Stockton East “passed through” its mitigation costs to the Urban
Contractors, this court must piece together the provisions of three different contracts – the
1997 Transfer Agreement, the companion agreement between Stockton East and the Urban
Contractors, and the Second Amended Contract. This case therefore demonstrates precisely
why the Federal Circuit has noted that “a standard for pass-through reductions [in breach of
contract actions] would entail extremely difficult burdens for the trial court.” Hughes
Commc’ns, 271 F.3d at 1072. As the Federal Circuit explained in Hughes Communications,
“‘The answer is not difficult. The general tendency of the law, in regard to damages at least,
is not to go beyond the first step. As it does not attribute remote consequences to a defendant
so it holds him liable if proximately the plaintiff has suffered a loss.’” Id. (quoting S. Pac.
Co. v. Darnell-Taenzer Lumber Co., 245 U.S. 531, 533-34 (1918)).

       In the case at bar, it is not necessary for the court to go beyond the first step.
Reclamation breached its Contract with Stockton East, and Stockton East mitigated by
entering into a substitute transaction with OID and SSJID. The terms of that substitute
transaction – the 1997 Transfer Agreement – provided that Stockton East was the obligor for
payment. The “take or pay” provision, for example, required Stockton East to pay OID and
SSJID regardless of whether the “Purchasers” – Stockton East or the Urban Contractors –
wanted the water. PX 450, at 3. In the event that a balance remained unpaid thirty days after
the due date, Stockton East was required to pay OID and SSJID annual interest of 10% on
that balance. Id. at 4. These provisions establish that Stockton East was the obligor under
the 1997 Transfer Agreement and consequently did not function merely as the conduit for
the Urban Contractors.

       Stockton East has established that it reasonably incurred its mitigation damages for
the years 1999 to 2004. It therefore is entitled to recover its cost of cover in the amount of
$2,268,192.42, which is the difference between the amount that Stockton East paid for the
water it purchased from OID and SSJID in the years 1999 to 2004 and the amount it would
have paid to Reclamation for that water under the 1983 Contract. 58/ See PX 403A.


        58/ The parties do not address the role of Stockton East’s water treatment costs in
their discussion of Stockton East’s cost of cover damages. As discussed in Part I.3.1) supra,
Stockton East incurs some incremental costs to treat the New Melones water that it purchases
from Reclamation. The water that Stockton East purchased from OID and SSJID also came
from the New Melones Reservoir and was conveyed through the NMCS and treated at the
DWTP for use by the Urban Contractors. See Tr. 636 (Kauffman) (“Q. And Stockton East
used the New Melones conveyance system to convey the water purchased under the 1997
transfer agreement to the district’s water treatment plant during [the 1999 to 2004] period.
A. Yes, we did.”). This evidence supports an inference, and the court so finds, that any
water treatment costs that Stockton East avoided by Reclamation’s breach are equal to any


                                              73
                                      CONCLUSION

       Based on the foregoing, Stockton East is entitled to an award of $2,268,192.42 as
damages for cost of cover and to no award of expectancy damages or damages for overhead.
By separate order entered this date in No. 04-541L, the Clerk of the Court has been instructed
to enter judgment for Central. The Clerk of the Court shall enter judgment for plaintiff
Stockton East in the amount of $2,268,192.42.

       IT IS SO ORDERED.

       No costs.




                                                 /s/ Christine O.C. Miller
                                           ________________________________
                                                 Christine Odell Cook Miller
                                                 Judge




       58/ (Cont’d from page 73.)

water treatment costs incurred in connection with Stockton East’s purchase of water from
OID and SSJID. Stockton East’s water treatment costs therefore do not enter into the
calculation of Stockton East’s cost of cover damages.

                                             74
