               ARMED SERVICES BOARD OF CONTRACT APPEALS

Appeal of --                           )
                                       )
Abdul Ahad Khadim Construction Company )           ASBCA No. 59206
                                       )
Under Contract No. W91B4L-12-C-0214    )

APPEARANCE FOR THE APPELLANT:                      Mr. Abdul Ahad Khadim
                                                    Director

APPEARANCES FOR THE GOVERNMENT:                    Raymond M. Saunders, Esq.
                                                    Army Chief Trial Attorney
                                                   L TC Brian J. Chapuran, JA
                                                    Trial Attorney

        DECISION BY ADMINISTRATIVE JUDGE LOPES ON THE
    GOVERNMENT'S MOTION TO DISMISS FOR LACK OF JURISDICTION

      Pursuant to Board Rule 7, the Department of the Army (Army or government)
moves to dismiss Abdul Ahad Khadim Construction Company's (appellant) appeal for
the Board's lack of jurisdiction due to appellant's failure to certify its claim. The
motion to dismiss is granted. This appeal is dismissed without prejudice.

       STATEMENT OF FACTS (SOF) FOR PURPOSES OF THE MOTION

       1. On 19 July 2012, the government awarded firm fixed-price Contract
No. W91B4L-12-C-0214 (contract) to appellant for the construction of a road and
entry control point at Kandahar Airfield, Afghanistan (R4, tabs 1-3). The estimated
value of the contract was $201,232 (R4, tab 1 at 3-5).

        2. The contract incorporated by reference the FAR 52.233-1, DISPUTES (JUL
2002) clause (R4, tab 1 at 28). The contract included the full text of the FAR 52.211-12,
LIQUIDATED DAMAGES -- CONSTRUCTION (SEP 2000) clause and notified appellant that if
it failed to complete the work within the time specified in the contract it would be
required to "pay liquidated damages to the Government in the amount of $667.36 for the
first day and $573.44 for each calendar day of delay thereafter until the [contract]
work [was] completed or accepted" (R4, tab 1 at 7-8).

       3. The government issued a notice to proceed on 1 September 2012, with a
contract start date of 1 September 2012. The contract completion date was 30 October
2012. (R4, tab 5)
      4. On 17 October 2012, the contracting officer sent a letter to appellant
expressing concern over appellant's lack of progress on the contract work (R4, tab 5).

       5. On 22 October 2012, the government issued contract Modification
No. P00002 that extended the contract completion date to 10 November 2012 due to
delays caused by appellant (R4, tab 9 at 1, 3). The modification stated that liquidated
damages would be assessed effective 31 October 2012, until the project had been
accepted by the government (id. at 1).

       6. On 13 January 2013, the government issued contract Modification
No. P00003 that extended the contract completion date to 1 February 2013 due to
delays (R4, tab 18 at 2, 3). The modification stated that liquidated damages would
continue to be assessed (id. at 3).

       7. On 7 March 2013, the government issued contract Modification No. P00004
that extended the contract completion date to 2 April 2013 due to delays caused by
appellant (R4, tab 32).

       8. On 3 April 2013, the government issued contract Modification No. P00005
that extended the contract completion date to 22 April 2013 (R4, tab 37). The
modification stated that the government had decided not to assess liquidated damages
for delays caused by appellant (id. at 2).

      9. On 1 October 2013, the government issued contract Modification
No. P00006 that assessed $27,045.60 in liquidated damages due to delays of 47 days
between 19 May 2013 and 4 July 2013 caused by appellant (R4, tab 43).

        10. On 2 February 2014, appellant filed a claim for AFN 16,508,044.80 (R4,
tab 44). Using the currency conversion rate in the contract, the claim was for
$339,513.82 (R4, tab 1 at 10). The claim for currency exchange losses, lost labor,
administration costs, and liquidated damage costs was not certified pursuant to the
Contract Disputes Act by appellant.

        11. On 1 March 2014, the contracting officer issued a contracting officer's
final decision granting appellant's claim for liquidated damages cost ($27,045.60) (see
SOF if 9) but denying the remainder of the claim (R4, tab 45).

       12. On 10 March 2014, appellant timely filed this appeal.




                                           2
                                       DECISION

       The Contract Disputes Act (CDA), 41 U.S.C. §§ 7101-7109, requires each
claim by a contractor against the Federal Government relating to a contract shall be in
writing. 41 U.S.C. § 7103(a)(2).

              For claims of more than $100,000 made by a contractor,
              the contractor shall certify that -
                   (A) the claim is made in good faith;
                   (B) the supporting data are accurate and complete to
              the best of the contractor's knowledge and belief;
                   (C) the amount requested accurately reflects the
              contract adjustment for which the contractor believes the
              Federal Government is liable; and
                   (D) the certifier is authorized to certify the claim on
              behalf of the contractor.

41 U.S.C. § 7103(b)(I). Certification may be executed by an individual authorized to
bind the contractor with respect to the claim. 41 U.S.C. § 7103(b)(2).

        "[T]he certification requirement is a jurisdictional prerequisite that must be
satisfied by the contractor before it may appeal the contracting officer's claim denial."
Tefirom lnsaat Enerji Sanayi ve Ticaret A.S., ASBCA No. 56667, 11-1 BCA ii 34,628
at 170,630 (citing United States v. Grumman Aerospace Corp., 927 F.2d 575, 579
(Fed. Cir. 1991); WM Schlosser Co. v. United States, 705 F.2d 1336, 1338 ("Unless
the claim was certified when it was submitted to the contracting officer, the Board
should have neither heard nor ruled on the appeal.")). The complete absence of any
certification is not a defect which may be corrected under the CDA for the Board to
retain jurisdiction. Eurostyle, Inc., ASBCA No. 45934, 94-1BCAii26,458
at 131,654. Moreover, the fact that a contracting officer purported to issue a final
decision does not serve to remedy the absence of certification. CDM International,
Inc., ASBCA No. 52123, 99-2 BCA if 30,467 at 150,514 (citing WM Schlosser,
705 F.2d 1336).

        The record establishes that appellant's monetary claim is for more than
$100,000 (SOF if 10). There is no evidence on record that appellant has certified its
claim as required by the CDA. The Board determines that appellant has failed to
certify its monetary claim in accordance with the CDA, and therefore the Board has no
jurisdiction over the claim.




                                            3
                                    CONCLUSION

        Because appellant's monetary claim is for more than $100,000 and was not
certified in accordance with the CDA, the Board has no jurisdiction over the appeal.
The government's motion to dismiss is granted without prejudice. Appellant retains
its right to submit a properly certified claim to the contracting officer for decision.

       Dated: 7 August 2014



                                                  CRANE L. LOPES
                                                  Administrative Judge
                                                  Armed Services Board
                                                  of Contract Appeals

I concur                                          I concur



~~L-IAM~'-S~~~~~~ ~$
Administrative Judge                              Administrative Judge
Chairman                                          Vice Chairman
Armed Services Board                              Armed Services Board
of Contract Appeals                               of Contract Appeals

       I certify that the foregoing is a true copy of the Opinion and Decision of the
Armed Services Board of Contract Appeals in ASBCA No. 59206, Appeal of Abdul
Abad Khadim Construction Company, rendered in conformance with the Board's
Charter.

      Dated:



                                                 JEFFREY D. GARDIN
                                                 Recorder, Armed Services
                                                 Board of Contract Appeals




                                            4
