AFFIRM as MODIFIED, and REVERSE and REMAND; Opinion Filed December 21,
2018.




                                          S    In The
                                Court of Appeals
                         Fifth District of Texas at Dallas
                                        No. 05-17-00583-CV

                           CITY OF LANCASTER, Appellant
                                       V.
                       WHITE ROCK COMMERCIAL, LLC, Appellee

                       On Appeal from the 191st Judicial District Court
                                    Dallas County, Texas
                            Trial Court Cause No. DC-14-06471

                MEMORANDUM OPINION ON REHEARING
                          Before Justices Bridges, Brown, and Boatright
                                  Opinion by Justice Boatright
       Our memorandum opinion in this case issued on August 20, 2018. We deny the motion for

rehearing, withdraw our opinion issued August 20, 2018, and vacate the judgment of that date.

This is now the opinion of the court.

       The City of Lancaster appeals a $4.7 million judgment rendered against it for breach of an

economic development contract with appellee White Rock Commercial, LLC. The City contends

that White Rock’s claim is barred by immunity. It also urges that the district court erred in granting

White Rock’s motion for partial summary judgment on the issue of liability, and it raises several

grounds for reversal related to the court’s damages award. We conclude that White Rock’s claims

are not barred by immunity and that the court did not err in granting White Rock’s motion for
partial summary judgment. However, we conclude that the court’s damages award is erroneous in

certain respects. We affirm, as modified, in part and reverse and remand, in part.




                                               –2–
                                                         BACKGROUND

          The Texas Constitution authorizes the Legislature to “provide for the creation of programs

and the making of loans and grants of public money” for “public purposes” that include the

“development and diversification of the economy of the state.” TEX. CONST. art. III, § 52-a (West

Supp. 2017). To this end, the Local Government Code empowers a municipality to “establish and

provide . . . programs for making loans and grants of public money . . . to promote state or local

economic development and to stimulate business and commercial activity in the municipality.”

TEX. LOC. GOV’T CODE ANN. § 380.001(a) (West 2005). White Rock’s claim is premised on the

City’s breach of a contract entered under the authority of this statute.

          White Rock is a real estate developer. In 2007, it found out about an 83-acre site in

Lancaster that the City wished to develop. The City was willing to provide economic incentives to

promote the development. On August 13, 2007, White Rock entered two contracts that would

provide funds to help develop the property: (i) an “Incentive Agreement” with the Lancaster

Economic Development Corporation (the EDC),1 and (ii) an “Economic Agreement” with the City.

We will refer to the Economic Agreement as the 380 Agreement because it cites section 380.001

as the basis for the City’s authority to enter the Agreement.

          In both contracts, White Rock agreed to design and construct infrastructural improvements

for a 1.4 million square-foot industrial park on the site. Such improvements were to be constructed

according to the City’s plans and specifications and were to include a new public regional storm

drainage and detention system, a wastewater or sanitary sewer system, a water delivery system,

off-site utility trunk connections, and streets. Both contracts made White Rock responsible for




      1
        The Lancaster EDC administers funds and projects using the $0.25 sales tax receipts dedicated to economic development pursuant to the
Development Corporation Act of 1979. The EDC has a board, separate from the City, composed of five members. The EDC is a separate taxable
entity from the City with its own budget and guidelines for expending funds.

                                                                   –3–
funding the “Project Costs”—the actual costs incurred by White Rock to construct the

infrastructural improvements, plus a specified rate of interest—subject to reimbursement.

       Each contract provided a different method of reimbursement. The Incentive Agreement

authorized four $450,000 payments from the EDC to White Rock, totaling $1.8 million, with the

first payment to be made ten days after commencement of the project. To trigger the remaining

payments, this agreement required White Rock to construct a “Qualified Building”—a building or

buildings on the project totaling at least 440,000 square feet—within thirty months of the City’s

final acceptance of the infrastructural improvements. White Rock would receive the remaining

three payments according to a schedule, with the final payment on August 1, 2009.

       In contrast, the 380 Agreement was implemented through an “annual economic

development grant,” apportioned into twenty scheduled payments by the City. The payments were

to begin on October 1 following the first year that any office or industrial building constructed on

the property was issued a certificate of occupancy, and they were to continue for an additional

nineteen years. The grant was paid annually according to a formula based on the product of the

fair market value of the improvements multiplied by the City’s annual tax rate.

       The parties disagree as to why there were two contracts. The City claims that the EDC had

insufficient funds to fully reimburse the projected costs budgeted for the project, which totaled in

excess of $3 million. In the City’s view, the 380 Agreement’s purpose was to reimburse White

Rock’s expected costs that were in excess of the $1.8 million to be paid under the Incentive

Agreement. White Rock counters that the contracts created different obligations and that the

Incentive Agreement provided additional incentives above the amounts to be paid under the 380

Agreement.

       White Rock acquired the site in a private sale and completed the infrastructural

improvements on June 22, 2009. The City accepted these improvements nearly two months later.

                                                –4–
White Rock also constructed a 442,000 square-foot distribution center. This was the Qualified

Building referenced in the Incentive Agreement. The EDC paid White Rock the four $450,000

installment payments required by the Incentive Agreement. The City issued a temporary certificate

of occupancy for this building on June 1, 2012, but it did not make any annual economic grant

payments under the 380 Agreement. White Rock sold the building at a loss, and its lender took the

undeveloped remainder of the property through a deed in lieu of a foreclosure transaction. This

remainder was thereafter developed by another developer.

       White Rock sued the City in June 2014, alleging that it breached the 380 Agreement. White

Rock also filed a motion for partial summary judgment, urging that that the evidence established

the City’s liability for breach of contract and negated the City’s affirmative defenses. On January

28, 2015, the district court signed an order granting White Rock’s motion on all elements of its

breach of contract claim except for the amount of the damages, if any, to be determined at a later

date. The order also ruled that each of the City’s affirmative defenses failed as a matter of law.

       The City subsequently filed a plea to the jurisdiction, claiming that it was immune from

White Rock’s breach of contract suit and that the 380 Agreement created a debt prohibited by the

Texas Constitution. The district court held a hearing on the City’s plea, and on June 30, 2016, the

court signed an order denying the plea. The court conducted a bench trial on White Rock’s

damages in November 2016. White Rock presented evidence that it had incurred Project Costs of

$ 2,677,288.79 and that its damages, after also adding the interest applicable under the 380

Agreement, totaled $4,726,217.53. On March 8, 2017, the court rendered judgment awarding

White Rock (i) actual damages consistent with the foregoing amounts, (ii) prejudgment interest of

$413,252.69, (iii) court costs, and (iv) postjudgment interest at the rate of 3.75%, compounded

annually. The City filed a motion for new trial and to set aside the court’s partial summary-

judgment order, which the court denied following a hearing. The City then appealed the judgment.

                                                –5–
                                             ANALYSIS

        The City raises six issues that challenge the judgment, including the district court’s

interlocutory orders that merged into the judgment.

                                                  I.
                                       Plea to the Jurisdiction

        The City urges that it is immune from White Rock’s suit. An assertion of governmental

immunity implicates a court’s subject matter jurisdiction, and such immunity is properly asserted

in a plea to the jurisdiction. Harris Cty. v. Annab, 547 S.W.3d 609, 612 (Tex. 2018). A movant

bears the burden in its plea to establish that it is entitled to immunity, and if it meets this burden,

the burden then shifts to the non-movant to establish, or at least raise a fact issue on, a waiver of

immunity. Lubbock Cty. Water Control and Improvement Dist. v. Church & Akin, L.L.C., 442

S.W.3d 297, 305 (Tex. 2014). Subject matter jurisdiction is a question of law that we review de

novo. Annab, 547 S.W.3d at 612. In the posture of this appeal from a final judgment following a

trial, we review the entire record, including the evidence admitted at trial, to the extent it bears on

the City’s jurisdictional argument. ATI Enters., Inc. v. Din, 413 S.W.3d 247, 250–51 (Tex. App.—

Dallas 2013, no pet.). With these standards in mind, we must determine whether immunity applies

and, if it does, we must defer to the Legislature’s decision to waive, or not to waive, such immunity.

Wasson Interests, Ltd. v. City of Jacksonville (“Wasson I”), 489 S.W.3d 427, 435 (Tex. 2016).

A.      Applicability of Immunity

        In its first issue, the City contends that it is immune from suit under the common law

doctrine of sovereign immunity. The City explains that political subdivisions of the State are

immune from suit unless the Legislature unambiguously waives immunity, and it contends that the

Legislature did not do so. And in its reply brief, the City asserts that its actions in entering into the

380 Agreement were governmental rather than proprietary. The distinction between governmental

and proprietary functions applies to breach of contract claims. Id. at 439. The City notes that
                                                  –6–
economic development corporations have sovereign immunity under chapters 504 and 505 of the

Local Government Code. It concludes that, because the City “acted in the same capacity as the

EDC” in entering into the 380 Agreement, “it was clearly and unequivocally carrying out a

governmental function consistent with case law.” However, the City provides no legal authority in

support of that conclusion. Chapters 504 and 505 apply to economic development corporations,

not municipalities, and we are aware of no judicial decision concluding that a municipality can

either act in the capacity of an economic development corporation, or carry out a governmental

function in that capacity.

       White Rock contends that the City was never entitled to immunity because it engaged in a

proprietary rather than a governmental function. White Rock quotes the Texas Supreme Court in

Wasson I for the proposition that a proprietary function is one undertaken “for the private

advantage and benefit of the locality and its inhabitants.” Id. at 433. White Rock notes that the 380

Agreement expressly provided that it “will further the objectives of the City, will benefit the City

and the City’s inhabitants and will promote local economic development and stimulate business

and commercial activity in the City.” White Rock contends that this shows that the City sought a

private advantage and benefit of the City and its inhabitants, that the City was engaging in a

proprietary rather than a governmental function, and that the City was therefore not entitled to

immunity under Wasson I.

       That case, however, addressed section 101.0215 of the Civil Practice and Remedies Code,

which expressly identifies “street construction and design,” “sanitary and storm sewers,” and

“water and sewer service” as governmental functions and not proprietary functions. TEX. CIV.

PRAC. & REM. CODE § 101.0215(a)(3), (9), (32) (West Supp. 2017). Each of those functions was

expressly covered by the 380 Agreement. If section 101.0215 had not identified those functions as

either governmental or proprietary functions, we would apply a four-part test to determine whether

                                                –7–
they were governmental, as the Texas Supreme Court did in an opinion issued after submission of

our case. Wasson Interests, Ltd. v. City of Jacksonville (“Wasson II”), 559 S.W.3d 142, 150 (Tex.

2018). However, because the functions expressly covered by the 380 Agreement are expressly

identified in section 101.0215 as governmental functions, we do not apply the Wasson II test. We

are instead guided by section 101.0215’s treatment of those functions. Wasson I, 489 S.W.3d at

439. We conclude that these functions are what the Legislature has told us they are: governmental

functions. Therefore, the City is immune from suit absent a waiver by the Legislature. We sustain

the City’s first issue.

B.      Waiver of Immunity

        In its second issue, the City contends that its immunity was not waived under Chapter 271

of the Local Government Code. A waiver of governmental immunity must be clear and

unambiguous. Oncor Elec. Delivery Co. LLC v. Dallas Area Rapid Transit, 369 S.W.3d 845, 849

(Tex. 2012). Under Chapter 271, “[a] local government entity that . . . enters into a contract subject

to this subchapter waives sovereign immunity to suit for the purpose of adjudicating a claim for

breach of the contract,” subject to certain terms and conditions not at issue here. TEX. LOC. GOV’T

CODE ANN. § 271.152 (West 2016). A “contract subject to this subchapter” includes “a written

contract stating the essential terms of the agreement for providing goods or services to the local

governmental entity that is properly executed on behalf of the local governmental entity.” TEX.

LOC. GOV’T CODE ANN. § 271.151(2)(A) (West 2016). We must look beyond the title of a written

contract to determine whether it satisfies Chapter 271’s waiver requirements. Church & Akin, 442

S.W.3d at 301.

        The City argues that the 380 Agreement was not a “contract subject to this subchapter”

because it (i) lacked an essential term—the time of performance, City of Houston v. Williams, 353

S.W.3d 128, 138–39 (Tex. 2011)—and (ii) did not relate to the provision of goods or services.

                                                 –8–
       1.      Time of Performance

       The City contends that its obligation to pay is “contingent on the completion of

performance by White Rock in an undetermined period of time,” citing section 5.3 of the

Agreement. The City relies on a decision from a sister court that held a contract to build a home

lacked several essential terms, including the size of the house contemplated, the price of the house

on a per-square-foot or other basis, or the time for completing construction. DKH Homes, LP v.

Kilgo, No. 03-10-00656-CV, 2011 WL 1811435, at *3 (Tex. App.—Austin May 11, 2011, no pet.)

(memo. op.). In response, White Rock points to section 7.1 of the Agreement, which authorizes

the City to terminate if White Rock does not take adequate steps to cure a default within thirty

days (or in the instance of a non-monetary default, within ninety days) after receiving notice from

the City, such default including a failure to commence or to complete construction of the project.

White Rock urges that this provision obligated it to perform within a reasonable time, citing case

law that a contract is not “too indefinite to be enforced . . . so long as the language used fixes an

ascertainable fact or event by which the term of the duration of the contract can be determined.”

Brittian v. Gen. Tel. Co. of Sw., 533 S.W.2d 886, 891 (Tex. Civ. App.—Fort Worth 1976, writ

dism’d). It alternatively contends that the law will imply a reasonable time where no time for

performance is stated in the contract, citing Moore v. Dilworth, 179 S.W.2d 940, 942 (Tex. 1944).

       Whether a contract has all the essential terms to be an enforceable agreement is a question

of law. Ferachi v. Cady, No. 2-07-355-CV, 2009 WL 1506899, at *4 (Tex. App.—Fort Worth

May 28, 2009, pet. denied) (mem. op). The material terms are determined on a case-by-case basis,

and each contract should be considered separately to determine its material terms. Fischer v. CTMI,

L.L.C., 479 S.W.3d 231, 237 (Tex. 2016). In this case, we conclude that the law implied a

reasonable time for White Rock to complete performance of its contractual obligations. Absent

such an interpretation, section 7.1’s provision regarding the cure of a default, and the termination

                                                –9–
following a failure to cure, would never apply. This interpretation would render section 7.1

meaningless, in contravention of the principle that courts attempt to avoid such a construction.

Vest v. Gulf Ins. Co., 809 S.W.2d 531, 533 (Tex. App.—Dallas 1991, writ denied). For this reason,

we conclude that the Agreement stated its essential terms.

       2.      Goods or Services

       We next consider whether the 380 Agreement was for the provision of “services,” a term

not defined in Chapter 271. The Texas Supreme Court has held that the term “is broad enough to

encompass a wide array of activities,” and “includes generally any act performed for the benefit

of another.” Kirby Lake Dev., Ltd. v. Clear Lake City Water Auth., 320 S.W.3d 829, 839 (Tex.

2010) (citation and internal quotation marks omitted). The services provided “need not be the

primary purpose of the agreement.” Id. However, section 271 does not extend to “‘contracts in

which the benefit that the local governmental entity would receive is an indirect, attenuated one.’”

Id. (quoting Berkman v. City of Keene, 311 S.W.3d 523, 527 (Tex. App.—Waco 2009, pet. denied)

(brackets omitted)); cf. Church & Akin, 442 S.W.3d at 303 (“When a party has no right under a

contract to receive services, the mere fact that it may receive services as a result of the contract is

insufficient to invoke chapter 271’s waiver of immunity.”).

       The City urges that White Rock, as the owner of the property, was required by the City’s

subdivision ordinance to construct the infrastructural improvements at issue. The City claims that

its ordinance required this infrastructure, once built, to be turned over to the City to maintain in

perpetuity. In the City’s view, it merely financed White Rock’s construction of the infrastructural

improvements that White Rock was already required by law to install. The City’s plea attached an

affidavit of the City Manager/Chief Budget Officer, who averred that the City did not receive a

direct benefit from the project. The City also urges that it was White Rock who benefitted from

the infrastructure in the form of an increase in its property’s value.

                                                –10–
        In support of its position, the City relies on cases holding that contracts were not for the

provision of services because their benefit to the municipality was attenuated. Berkman involved

child welfare services that were at most a benefit to the state given that the city in that case had no

independent obligation to provide for the welfare of children who were wards of the state. 311

S.W.3d at 527. In East Houston Estate Apartments, L.L.C. v. City of Houston, a city loaned federal

and private funds to a property owner to rehabilitate an apartment complex within the city. 294

S.W.3d 723, 726, 736–37 (Tex. App.—Houston [1st Dist.] 2009, no pet.). While the city might

benefit in a general way from refurbished apartments and low-income housing, our sister court

concluded that nothing in the contract obligated the property owner to provide any municipal

service directly to the city. Id. at 736. Rather, the city was simply a conduit of federal funds and a

facilitator of the project. Id.

        In City of Canton v. Zanbaka, USA, LLC, a city economic development corporation

contracted with the owner of “Duke’s Travel Plaza” to fund a sewer line and lift station to its travel

plaza located along Interstate 20. No. 12-12-0006-CV, 2013 WL 3377436, at *1 (Tex. App.—

Tyler July 3, 2013, pet. denied) (mem. op. on reh’g). Despite the contract’s stated purpose of

providing new economic opportunities for the city, our sister court concluded that the contract’s

“tangible objective” was to provide funding for a sewer line and lift station to Duke’s real property.

Id. at *3. Any benefits to the EDC that would flow from this objective were indirect. Id.

        In response to the City, White Rock relies on Kirby Lake, in which the supreme court held

that section 271.152 waived a water control and improvement district’s immunity. 320 S.W.3d at

838–40. In that case, residential developers contracted with the district to build water and sewer

facilities—i.e., water and sewer lines—according to the district’s specifications. Id. at 832. The

contracts required the developers to lease the constructed facilities to the district free of charge

until the district purchased them. Id. The district agreed to reimburse the developers for 70% of

                                                –11–
their construction costs once it received voter-approved bond funds. Id. at 832–33. However, under

applicable state regulations, the developers assumed the risk that the voters would never authorize

public funds for acquiring the facilities. Id. at 832, 836. Based on the developers’ obligation to

“construct, develop, lease, and bear all risk of loss or damage to the facilities,” the supreme court

held that the contracts entailed services provided directly to the district. Id. at 839.

        White Rock also cites Dallas Area Rapid Transit v. Monroe Shop Partners, Ltd., 293

S.W.3d 839 (Tex. App.—Dallas 2009, pet denied), disapproved on other grounds by Zachry

Constr. Corp. v. Port of Houston Auth. of Harris Cty., 449 S.W.3d 98, 110 n.54 (Tex. 2014). In

that case, we concluded that a contract that called for DART to sell, and for Monroe to purchase

and develop, a historically significant property was a contract to provide services. Id. at 840–41.

The contract required Monroe to accept a separate assignment of DART’s responsibility of

complying with the state’s restrictions flowing from the historic nature of the property. Id. at 841.

These facts, coupled with the contract’s provisions that required various approvals from DART,

brought the contract within the scope of section 271.152. Id.

        In this case, the 380 Agreement expressly stated that it would benefit the City by growing

its economy. Nevertheless, under the reasoning of Berkman, East Houston Estate, and Zanbaka,

this benefit to the City is too attenuated for the section 271.152 waiver to apply. Cf. Church &

Aiken, 442 S.W.3d at 306–07 (indirect benefits to water district from lessee’s increased profits

could not, alone, convert lessee’s efforts to promote its own business into services to water district).

However, the circumstances of this case demonstrate that White Rock’s agreement to construct

the infrastructural improvements was itself a direct benefit to the City, as were the facilities

constructed in Kirby Lake. 320 S.W.3d at 838–40. Although the City contends that its subdivision

ordinance independently required White Rock to construct the facilities at issue, the record

evidences that White Rock would not have done so but for the City’s solicitations. Specifically,

                                                 –12–
Hopkins testified that White Rock initially refused to develop the property but changed its mind

after the City offered the incentives set forth in both the 380 Agreement and the Incentive

Agreement. The City’s agreement to pay White Rock for such construction is further evidence of

a contract for services. See Church & Aiken, 442 S.W.2d at 304 (“[T[he waiver will typically apply

only to contracts in which the governmental entity agrees to pay the claimant for the goods or

services that the claimant agrees to provide to the governmental entity.”).

       In sum, the 380 Agreement entailed services provided directly to the City, thereby waiving

its immunity under section 271.152. Accordingly, we need not decide whether the Agreement was

also a contract for providing goods. We overrule the City’s second issue.

C.     Enforceability of Debt

        The City’s third issue contends that the 380 Agreement created a void debt that the district

court lacked jurisdiction to enforce. The City cites two constitutional provisions that prohibit it

from incurring a debt unless at the same time (i) a provision is made for annually assessing and

collecting a sufficient sum to pay the debt’s interest, and (ii) a sinking fund is created of at least

two percent of the debt. TEX. CONST. art. XI, §§ 5, 7 (West Supp. 2017); see McNeill v. City of

Waco, 33 S.W. 322, 324 (Tex. 1895) (concluding that “debt,” as used in article 11, means any

pecuniary obligation imposed by contract except for obligations to be satisfied out of current

revenues or out of some fund within the municipality’s immediate control). We are not persuaded

by the City’s argument. The constitutional provision authorizing Local Government Code section

380.001 provides that a “grant made as provided by this section”—that, as in this case, is not

secured by a pledge of ad valorem taxes or financed by the issuance of bonds payable from such

taxes—“does not constitute or create a debt for the purpose of any provision of this constitution.”

TEX. CONST. art. III, § 52-a. Thus, the grant made under the 380 Agreement was not a debt for

purposes of the foregoing constitutional provisions.

                                                –13–
       The City alternatively relies on section 3.3 of the Agreement, in which it agreed “to use

available funds . . . to reimburse DEVELOPER for Project Costs.” The City interprets this

provision to mean that its obligation was contingent on its appropriation of funds in its annual

budget to pay the grant. Related to this point, the City Manager/Chief Budget Officer averred in

an affidavit, attached to the City’s plea, that the City did not appropriate any funds for fiscal years

2012 through 2016 to pay the grant.

       The interpretation of an unambiguous contract, including whether a contractual provision

creates a condition precedent to performance, is a question of law for the court. Lambrecht &

Assocs., Inc. v. State Farm Lloyds, 119 S.W.3d 16, 26 (Tex. App.—Tyler 2003, no pet.). “[T]o

make performance specifically conditional, a term such as ‘if’, ‘provided that’, ‘on condition that’,

or some similar phrase of conditional language must normally be included.” Solar Applications

Eng’g, Inc. v. T.A. Operating Corp., 327 S.W.3d 104, 109 (Tex. 2010) (citation and internal

quotation marks omitted). Though such phrases are not required, their absence is probative of the

parties’ intent to make a covenant—i.e., to agree to act or refrain from acting in a certain way—

rather than to impose a condition precedent. Id. at 108–09. In the absence of conditional language,

and to the extent another reasonable interpretation of the contract is possible, we will construe the

terms as a covenant in order to prevent a forfeiture. Id. at 109. In this case, the 380 Agreement

contains no such condition, nor does it contain other language that suggests the parties intended to

condition the City’s performance under the Agreement on its appropriation of funds to pay the

grant. We therefore disagree with the City’s interpretation of section 3.3.

        The City also cites section 2.2 of the Agreement, which provides that “DEVELOPER’s

performance . . . shall not result in the creation of any claim against CITY for money or

performance, any lien, charge, encumbrance or security interest upon any asset of CITY.” White

Rock responds that the Agreement, when read in its entirety, makes clear that the City was

                                                –14–
obligated to reimburse White Rock’s costs and that section 2.2 cannot reasonably be construed

otherwise. We agree with White Rock’s interpretation. Section 2.2 addresses only White Rock’s

performance under the Agreement, as opposed to the City’s nonperformance if its own obligations.

Moreover, sections 1.13 and 3.3 of the Agreement expressly obligate the City to reimburse White

Rock’s costs, though these sections differ whether such reimbursement is to be in full. Upon

reviewing the Agreement in its entirety, we conclude that section 2.2 did not bar White Rock’s

claim against the City. We overrule the City’s third issue.

                                               II.
                                       Breach of Contract

       The City’s fourth issue challenges the sufficiency of the evidence to support White Rock’s

breach of contract claim. The City refers to both legal and factual sufficiency, but the crux of its

complaint is that the district court erred in granting White Rock’s motion for partial summary

judgment. Cf. City of Keller v. Wilson, 168 S.W.3d 802, 823 (Tex. 2005) (“[T]he test for legal

sufficiency should be the same for summary judgments, directed verdicts, judgments

notwithstanding the verdict, and appellate no-evidence review.”). White Rock, the movant, bears

the burden of proving that no material fact issue exists on the elements of its claim and that it is

entitled to judgment as a matter of law. TEX. R. CIV. P. 166a(c). We review a challenge to a

traditional summary judgment de novo. Provident Life & Accident Ins. Co. v. Knott, 128 S.W.3d

211, 215 (Tex. 2003). We view the evidence in the light most favorable to the City, the non-

movant, indulging every reasonable inference in the City’s favor, and resolving any doubts against

the motion. Lightning Oil Co. v. Anadarko E&P Onshore, LLC, 520 S.W.3d 39, 45 (Tex. 2017).

A.     Conditions Precedent

       The City asserts that White Rock’s summary-judgment motion did not establish the

occurrence of what it labels as four conditions precedent to the City’s obligation to pay the

economic development grant. The performance of a condition precedent is an essential element of
                                               –15–
a plaintiff’s breach of contract claim. Lidawi v. Progressive Cty. Mut. Ins. Co., 112 S.W.3d 725,

734 (Tex. App.—Houston [14th Dist.] 2003, no pet.).

           1.         Completion of Infrastructure

           The City contends that White Rock failed to give notice that it completed the infrastructural

improvements. While the 380 Agreement obligated White Rock to complete the improvements,

the contract’s terms did not require White Rock to give notice of such completion. White Rock’s

summary-judgment motion attached an affidavit by Hopkins, along with supporting

documentation, to show that (i) White Rock completed the improvements on June 22, 2009, and

(ii) the City delivered a letter of acceptance on August 13 of the same year.2 The City’s opposing

summary-judgment evidence did not contradict these facts.

           2.         Certificate of Occupancy

           The City also complains that White Rock failed to show that a “final” certificate of

occupancy was issued for a building on the project site. As described previously, section 5.3 of the

Agreement required the City, following the issuance of a certificate of occupancy on any

“Improvement[ ]”—defined elsewhere in the contract as an office or industrial building—to

commence economic development grant payments. The Hopkins affidavit attached a “temporary”

certificate of occupancy issued by the City on June 1, 2012, for the “Mobis” building constructed

on the property. The “temporary” designation on the certificate has no significance given that the

380 Agreement does not require a “final” certificate. White Rock’s summary-evidence thus

demonstrates that the certificate-of-occupancy requirement was met. The City’s summary-

judgment evidence did not contradict this fact.




      2
        The City objected to White Rock’s summary-judgment evidence. However, the district court did not rule on these objections, and they are
not asserted in the City’s appeal brief as a basis for reversal.

                                                                   –16–
       3.      Project Costs

       The City complains that White Rock did not submit a written report itemizing all Project

Costs within ninety days following the end of the fiscal year in which the infrastructural

improvements were completed, as was required by section 4.6 of the Agreement. The City

contends that it did not receive such a report until December 2015, when White Rock produced a

report in response to the City’s discovery requests. The City also points to Hopkins’s trial

testimony that he did not know whether White Rock submitted a report reflecting and itemizing

its Project Costs. In the City’s view, its obligation to pay White Rock never arose because White

Rock failed to provide the cost report required by section 4.6. White Rock disputes the City’s

claims and urges that the City’s brief omits Hopkins’s trial testimony that he believed White Rock

had in fact submitted a cost report “with some level of itemization.”

       We begin by considering the City’s assertion that section 4.6 gave rise to a condition

precedent. This provision contains no language that would suggest such a condition. Solar

Applications, 327 S.W.3d at 109. However, section 7.2 of the Agreement provides that, “in the

event” White Rock fails to furnish the City any required documentation within thirty business days

following a written request from the City, “then” White Rock shall be in default. Section 7.3, in

turn, suspends the City’s obligation to pay any installment while White Rock is in default.

Moreover, section 7.1 permits the City to terminate the Agreement “if” White Rock does not take

adequate steps to cure its default within a specified period of time after receiving notice of the

default. In the event of a termination, section 7.3 provides that White Rock shall forfeit any

remaining payments under the Agreement. Taken together, the foregoing provisions establish a

condition subsequent—“a condition referring to a future event, upon the happening of which the

obligation becomes no longer binding upon the other party, if he chooses to avail himself of the

condition.” Cmty. Health Sys. Prof. Servs. v. Hansen, 525 S.W.3d 671, 682 (Tex. 2017) (citation

                                              –17–
and internal quotation marks omitted). A condition subsequent excuses an already binding

agreement, id. at 683, and unlike a condition precedent, it is an affirmative defense on which the

defendant bears the burden of proof, see Commercial Union Ins. Co. of Am. v. Stanmike Inv. Co.,

475 S.W.2d 295, 297 (Tex. Civ. App.—Waco 1971, writ ref’d n.r.e.) (concluding that burden was

on insurer to plead, prove, and establish occurrence of condition subsequent in order to avoid

liability); Knoff v. U.S. Fid. & Guar. Co., 447 S.W.2d 497, 500–01 (Tex. Civ. App.—Houston [1st

Dist.] 1969, no writ) (concluding same); Blue Bonnet Life Ins. Co. v. Reynolds, 150 S.W.2d 372,

374 (Tex. Civ. App.—Eastland 1941, writ ref’d) (concluding same).

       The City’s answer did not plead White Rock’s non-compliance with section 4.6, though it

pled that White Rock did not comply with all applicable provisions of the contract. In addition, the

City’s summary-judgment opposition made no attempt to establish (i) such noncompliance, or

(ii) that the City availed itself of the condition subsequent set forth above. Since the City failed to

raise a fact question regarding this affirmative defense, section 4.6 did not foreclose the rendition

of a partial summary judgment in White Rock’s favor.

       4.      Value of Improvements

       Under section 5.3 of the Agreement, the formula for determining each economic

development grant payment is based in part on “the fair market value of the industrial distribution

and office improvements (as determined by the Dallas County Appraisal District).” The City urges

in its appeal brief, as it did in the litigation below, that White Rock’s notice of such value was a

condition precedent to the City’s contractual obligations. Related to this argument, the City’s

Economic Development Director averred in a supporting affidavit that White Rock did not notify

the City of the value of the building for which the certificate of occupancy was issued. We disagree

with the City’s contention that section 5.3 gave rise to a condition precedent. This section does not

require White Rock to provide notice of the improvements’ value, nor does it condition the City’s

                                                –18–
obligation to pay on its receipt of such notice. Solar Applications, 327 S.W.3d at 109. Accordingly,

White Rock’s purported noncompliance with this provision did not preclude the rendition of a

partial summary judgment in its favor.

B.           Affirmative Defenses

             The City also asserts that fact issues regarding its affirmative defenses foreclosed the

rendition of summary judgment against it, though it provides no additional briefing on this point.

We have already addressed most of the City’s defenses asserted in its summary-judgment

opposition—specifically, governmental immunity, whether the 380 Agreement creates an

unconstitutional debt, and conditions precedent. The sole remaining defense that we have not

addressed is the City’s assertion that the 380 Agreement was an illegal tax abatement because it

required payments in excess of ten years on property not located in a “reinvestment zone,” in

contravention of section 312.204 of the Tax Code. TEX. TAX CODE ANN. § 312.204(a) (West

2015).3 This section applies only to agreements to exempt property from taxation. Id. The 380

Agreement was not such an agreement; it instead obligated the City to make grant payments

directly to White Rock. Accordingly, section 312.204 does not apply here.

             In conclusion, upon viewing the summary-judgment evidence in the light most favorable

to the City, we conclude that the district court did not err in granting White Rock’s motion for

partial summary judgment. We overrule the City’s fourth issue.

                                                                     III.
                                                                   Damages

A.           Credit for Sums Paid Under Incentive Agreement

             The City’s fifth issue contends that the district court erred in refusing to credit the Lancaster

EDC’s $1.8 million payment against any balance owed by the City under the 380 Agreement.



     3
         The City also pled failure of consideration, but it did not assert this defense in its opposition to White Rock’s summary-judgment motion.

                                                                       –19–
During its cross examination of Hopkins, the City attempted to establish that it was entitled to this

credit plus an additional credit for impact fees that it had waived. White Rock objected to this line

of questioning on the basis that the City had not pled the affirmative defense of offset. See SAS &

Assocs., Inc. v. Home Mktg. Servicing, Inc., 168 S.W.3d 296, 301 (Tex. App.—Dallas 2005, pet.

denied) (noting that offset is an affirmative defense). The district court sustained White Rock’s

objection, thereby foreclosing any trial by consent regarding this defense.

          The City contends that the court’s ruling was erroneous because the defense of offset does

not apply here. This defense, also referred to as setoff, has its roots in English bankruptcy law,

which permitted a defendant to raise a debt that the plaintiff owed the defendant as a defense or

counterclaim. Bandy v. First State Bank, Overton, Tex., 835 S.W.2d 609, 618 (Tex. 1992). The

right of setoff allows parties that owe each other money from different transactions, referred to as

“mutual debts,” to apply their debts to each other. Sommers v. Concepcion, 20 S.W.3d 27, 35 (Tex.

App.—Houston [14th Dist.] 2000, pet. denied). In the City’s view, this defense does not apply to

sums paid by a third-party, in this case, the Lancaster EDC, as opposed to sums paid by the debtor

itself.

          White Rock agrees that its specific objection at trial regarding the City’s failure to plead

offset was not a proper objection. It instead contends for the first time on appeal that the affirmative

defense of payment, also not pled by the City, applies here. TEX. R. CIV. P. 94–95. It argues that

we should uphold the district court’s ruling on any valid ground, i.e., the City’s failure to plead

payment, even though the court’s ruling was based on the City’s failure to plead offset. See State

Bar of Tex. v. Evans, 774 S.W.2d 656. 658 n.5 (Tex. 1989) (“[E[ven where the trial court errs in

sustaining a specific untenable objection, an appellate court should uphold the ruling if there is

any other ground for doing so, even though not urged below.”). In response, the City’s motion for

rehearing points to a decision by one of our sister courts that declined to apply Rule 95 to a

                                                 –20–
defendant’s pleading of payments paid by a third party. Imperial Lofts, Ltd. v. Imperial

Woodworks, Inc., 245 S.W.3d 1, 4–5 (Tex. App.—Waco 2007, pet. denied). We agree, and we

therefore conclude that the City was not barred in this case from presenting evidence of the $1.8

million paid by the Lancaster EDC.

       Turning to the merits of the City’s argument, it contends that the 380 Agreement and the

Incentive Agreement are unambiguous. Both contracts provide for the “reimbursement” of White

Rock’s actual costs incurred in the design and construction of infrastructural improvements. In the

City’s view, “[r]eimbursement is . . . a repayment for money one has already spent,” not a bonus.

White Rock counters that both contracts were ambiguous as to the amounts owed to it. It notes that

the contracts referred to a “Financing Plan” that contemplated less than full reimbursement of all

Project Costs, while at the same time they provided for “reimbursement in full.” While Rock urges

that parol evidence was admissible to resolve this purported ambiguity, and it points to Hopkins’s

testimony that the parties intended White Rock to receive payments under the 380 Agreement in

addition to any payments made under the Incentive Agreement. In White Rock’s view, the court

must have determined that it was entitled to “reimbursement in full” under the 380 Agreement,

plus four liquidated incentive payments under the Incentive Agreement. Pertinent to this argument,

Hopkins testified, over the City’s objection, that the contract provision limiting the City’s

reimbursement costs was inadvertently transposed from the Incentive Agreement to the 380

Agreement as the result of a cut-and-paste error.

       When interpreting a contract, our primary concern is to ascertain the true intentions of the

parties as expressed in the instrument. J.M. Davidson, Inc. v. Webster, 128 S.W.3d 223, 229 (Tex.

2003). A contract is unambiguous if it can be given a definite or certain legal meaning. Id. On the

other hand, a contract is ambiguous if it is “subject to two or more reasonable interpretations after

applying the pertinent rules of construction,” which require us to “examine and consider the entire

                                               –21–
writing in an effort to harmonize and give effect to all the provisions of the contract so that none

will be rendered meaningless.” Id. Whether ambiguity exists is a question of law for the court.

First Bank v. Brumitt, 519 S.W.3d 95, 105 (Tex. 2017). We may consider the context in which a

contract is made in determining whether it is ambiguous, but we may not rely on extrinsic evidence

to create an ambiguity or to give the contract a different meaning than what its language imports.

Id. at 109–10.

       Upon reviewing the 380 Agreement and the Incentive Agreement, we conclude that neither

contract is ambiguous on the question of whether payments made to White Rock under the

Incentive Agreement should be credited against the balance owed to it under the 380 Agreement.

Both contracts provide for “reimbursement” of White Rock’s Project Costs. We must give a

contract term its “plain, ordinary, and generally accepted meaning.” Heritage Res., Inc. v.

NationsBank, 939 S.W.2d 118, 121 (Tex. 1996). The term “reimburse” means “to pay back (an

equivalent for something taken, lost, or expended) to someone.” Webster’s Third New Int’l

Dictionary of the English Language 1914 (1981). While the 380 Agreement and the Incentive

Agreement each contain differing terms whether the reimbursement at issue was to be “in full,”

neither of the agreements provide for an incentive payment to White Rock above and beyond its

reimbursement. We conclude that Hopkins’s testimony regarding the parties’ intent with respect

to the foregoing contracts cannot alter the contracts’ plain meaning. Accordingly, the court erred

in refusing to credit the EDC’s $1.8 million payment against the balance owed by the City under

the 380 Agreement. We sustain the City’s fifth issue.

B.     Evidentiary Issues

       In its sixth issue, the City asserts that several of the district court’s evidentiary rulings were

erroneous. The admission or exclusion of evidence is committed to the trial court’s sound

discretion. Interstate Northborough P’ship v. State, 66 S.W.3d 213, 220 (Tex. 2001). The City

                                                 –22–
urges that the court erred by admitting into evidence a file (Plaintiff’s Exhibit 9) containing vendor

invoices and other documentation relating to Project Costs incurred by White Rock. The City

contends that the invoices lacked a proper foundation and were inadmissible hearsay. We disagree.

Exhibit 9 was accompanied by an affidavit, signed by Hopkins, which averred that White Rock

(i) incorporated each of the invoices into its business records, and (ii) regularly relied on the

accuracy of the invoices. Hopkins also averred that White Rock confirmed the accuracy of the

invoices prior to incorporating them into its own records, thereby establishing the invoices’

trustworthiness. Hopkins provided additional testimony at trial that supported the statements made

in his affidavit. Based on the foregoing evidence, we conclude that White Rock laid a proper

predicate for the admission of Exhibit 9 under the hearsay exception for records of regularly

conducted activity. Morris v. Branch Banking and Trust Co., No. 05-15-01249-CV, 2017 WL

3634334, at *8 (Tex. App.—Dallas Aug. 24, 2017, pet. denied) (mem. op.). The court did not err

in overruling the City’s objection to the admission of this exhibit.

       The City also claims that the court erred by admitting a chart into evidence (Plaintiff’s

Exhibit 8) that tallied the invoice amounts from Exhibit 9 and identified the Project Costs category

to which each invoice related. Exhibit 8 reflected that the costs incurred by White Rock totaled

$2,677,288.79. The City argues that this exhibit lacked a sufficient predicate and was inadmissible

hearsay. We again disagree. A predicate under this rule requires the offering party to show that the

underlying documents are admissible, that they are voluminous, and that they were made available

to the opposing party for inspection and use in cross-examination. Leander v. Fin & Feather Club

ex rel. Parten, No. 06-10-00135-CV, 2012 WL 75815, at *7 (Tex. App.—Texarkana Jan. 11, 2012,

no pet.) (mem. op.). As explained previously, the records underlying Exhibit 8 were admissible.

The records were approximately 800 pages, and Hopkins testified that they were an “enormous

amount of data.” White Rock’s counsel also represented to the court that the business records

                                                –23–
affidavit proving Exhibit 9 was on file at least fourteen days before trial in compliance with Texas

Rule of Evidence 902(10)(A), thereby establishing that they were made available to the City for

inspection and cross-examination. We thus conclude that the court did not err overruling the City’s

objection to the admission of Exhibit 8.

           In addition, the City urges that the court erred in overruling its objection, on relevancy

grounds, to Hopkins’s testimony regarding section 1.13 of the 380 Agreement. Hopkins testified

that this section “created an expectation that we were going to be reimbursed in full for our cost,

plus 8% per annum interest.” As noted previously, we agree that Hopkins’s testimony could not

alter the unambiguous terms of the Agreement. Brumitt, 519 S.W.3d at 109. However, our

conclusion that the court erred in refusing to credit the EDC’s $1.8 million payment against the

balance owed by the City under the 380 Agreement renders unnecessary our separate consideration

of whether such evidence should have been excluded under Rule 402 of the Texas Rules of

Evidence. We overrule the City’s sixth issue with regard to the purported evidentiary errors that it

asserts.

C.         Legal and Factual Sufficiency

           The City’s sixth issue also raises several challenges under the rubric of legal and factual

sufficiency. The parties each submitted proposed findings of fact and conclusions of law, but the

district court made no findings. The City does not contend that the court erred in this respect, and

we will therefore consider this case as one in which neither party requested findings of fact or

conclusions of law. In this scenario, we will imply all facts necessary to support the court’s

judgment. Shields Ltd, P’ship v. Bradberry, 526 S.W.3d 471, 480 (Tex. 2017). If the reporter’s

record is filed on appeal, as it was here, “implied findings may be challenged on factual-and legal-

insufficiency grounds in the same manner ‘as jury findings or a trial court’s [express] findings of

fact.’” Id. (quoting Roberson v. Robinson, 768 S.W.2d 280, 281 (Tex. 1989) (per curiam)). In

                                                  –24–
reviewing legal sufficiency, we must credit favorable evidence that supports the verdict, if

reasonable jurors could, and disregard contrary evidence unless reasonable jurors could not. City

of Keller, 168 S.W.3d at 827. In contrast, a factual sufficiency review requires us to weigh all of

the evidence and to set aside findings only if they are so against the great weight and preponderance

of the evidence to be clearly wrong and unjust. Ortiz v. Jones, 917 S.W.2d 770, 772 (Tex. 1996).

       1.      Hopkins’s Testimony

       The City challenges the sufficiency of the evidence based on Hopkins’s failure to explain

“what formula [he] used to calculate the damages and/or interest accrued.” Hopkins testified that

White Rock incurred Project Costs of $2,677,288. The court admitted into evidence White Rock’s

Exhibits 8 and 9 which, as explained above, documented these costs. With the exception of the

evidence submitted by White Rock regarding its insurance costs and the installation of a gas line,

which we address below, we conclude that the court could reasonably infer that the foregoing costs

were Project Costs subject to reimbursement. We also conclude that the court’s determination in

this respect was not contrary to the great weight and preponderance of the evidence. We need not

consider whether the evidence was sufficient to support the court’s award of interest because, for

the reasons set forth herein, such interest must be recalculated on remand in light of this Court’s

reduction of White Rock’s damages award.

       2.      Lump Sum Award

       Section 5.3 of the Agreement obligated the City to make annual economic development

grant payments over a twenty-year period. These payments were based on the fair market value of

the infrastructural improvements, as determined by DCAD, multiplied by the tax rate annually

adopted by the City. The City argues that the court’s lump-sum award does not conform to this

provision, given that the provision does not contain an acceleration clause. It also urges that no

evidence was admitted regarding the fair market value of the improvements and that the contract’s

                                               –25–
payment formula, based on future property assessments and future tax rates, precluded the award

of a lump sum.

       White Rock acknowledges that section 5.3 provided the mechanism through which the City

was supposed to reimburse White Rock’s costs, but it contends that the City’s material breach

permitted White Rock to recover a lump sum representing the total amount owed by the City. As

support, White Rock cites Republic Bankers Life Insurance Co. v. Jaeger, in which the Texas

Supreme Court held that “[t]he measure of damages in an action for breach of contract by

repudiation is the total of all accrued payments plus interest, plus the present value of all unaccrued

payments that the plaintiff would have received if the contract had been performed.” 551 S.W.2d

30, 31 (Tex. 1976) (per curiam).

       We agree with White Rock that the City’s breach in this case permitted White Rock to

recover a lump sum award. Cf. Long Trusts v. Griffin, 222 S.W.3d 412, 415 (Tex. 2006) (per

curiam) (noting that, after defendant’s material breach of contract, plaintiff may cease performance

and sue for breach). We decline to consider whether White Rock should have offered evidence of

the present value of the annual grant payments that had not yet accrued at that time. The City did

not raise this issue at trial, nor does it complain on appeal that White Rock should have offered

evidence of a discounted lump sum.

       3.      Non-Reimbursable Costs

       The City urges that four types of costs incurred by White Rock were not reimbursable

Project Costs under the terms of the Agreement. Under section 1.13, Project Costs were the costs

incurred to “plan, design, permit, and construct” the infrastructural improvements, except for costs

expressly excluded by the Agreement. The City claims that White Rock’s reimbursable costs

totaled $2,049,200.98, not the $2,677,288 sum awarded by the district court.




                                                –26–
       Legal fees

       Hopkins testified that White Rock’s evidence of costs included the legal fees that it

incurred related to the project. In Hopkins’s experience, it is customary and advisable to incur such

fees when constructing infrastructural improvements. The City notes that the Agreement contains

no specific reference to legal fees, but it fails to explain why these fees were unnecessary to plan,

design, permit, and construct the infrastructural improvements. We conclude that the foregoing

evidence supports the court’s implied finding that White Rock’s legal fees were within the scope

of section 1.13. We also conclude that this implied finding was not contrary to the great weight

and preponderance of the evidence.

       Insurance costs

       Section 6.1 of the Agreement obligated White Rock or its contractor, at its “sole expense,”

to obtain insurance while constructing the infrastructural improvements. White Rock’s evidence

included the construction-related insurance costs that it had incurred. The City contends that

section 6.1’s “sole expense” requirement excluded White Rock’s insurance costs from

reimbursement. We agree based on the plain language of this provision. We therefore conclude

that no evidence supports a finding awarding reimbursement of White Rock’s insurance costs.

       Title fees

       The City contends that White Rock’s costs incurred from a title company were a non-

reimbursable “soft cost.” As support, it cites the testimony of Dipak Patel, a City Project Manager

whom the City proffered as an expert witness for the purpose of comparing the costs submitted by

White Rock to the Agreement’s definition of Project Costs. The City relies on Patel’s testimony

that title costs are a “soft cost” and that, based on his experience, the title costs incurred in this

case “seem[ ] to be a little bit” high. Patel declined to concede that title companies are always

unnecessary to the development of infrastructural improvements, and the City points to no other

                                                –27–
evidence to support its position. Viewing the evidence in the light most favorable to the court’s

implied findings, we conclude that the court could reasonably determine that White Rock’s title

fees were necessary to the development of the infrastructural improvements. We also conclude

that the court’s implied findings were not contrary to the great weight and preponderance of the

evidence.

               Installation of gas line

       White Rock’s evidence also included invoices related to the construction of a gas line. The

City contends that these costs were not within the 380 Agreement’s definition of “Infrastructural

Improvements,” which, as described previously, relate to storm drainage, sewers, water delivery,

“off-site utility trunk connections,” and streets. We agree that the plain meaning of this definition

does not include costs related to the construction of a gas line. Accordingly, no evidence supports

the court’s implied finding awarding these costs.

               4.      Interest

       The City raises four complaints regarding the court’s award of interest.

       Commencement date for accrual of interest

       The City contests the court’s selection of June 17, 2014—the date that White Rock filed

its original petition—as the commencement date for calculating interest. The City contends that

interest could not have accrued until at least December 2015, when White Rock submitted for the

first time an itemized cost report. We decline to address this argument given our prior

determination that White Rock’s obligation to submit an itemized report was a condition

subsequent that the City never triggered.




                                               –28–
         Effect of $1.8 million payment

         The City also contends that the court erred in awarding interest on an amount of damages

not reduced by the $1.8 million payment referenced above. We agree for the reasons set forth

above.

         Duplicative interest

         In addition, the City contends that the court erred in awarding prejudgment and

postjudgment interest “in that interest is contemplated in the Agreement and the [c]ourt cannot

compound both interest rates on the award of damages.” The City cited no supporting authority

for this argument prior to filing its motion for rehearing, and we therefore decline to analyze the

merits of its position at this late juncture. See Bell v. Zurich Am. Ins. Co., 311 S.W.3d 507, 513

(Tex. App.—Dallas 2009, pet. denied) (concluding that appellant could not present new arguments

not preserved by pre-submission brief (citing TEX. R. APP. P. 38.1(i))).

         Accrual date for postjudgment interest

         The judgment awarded postjudgment interest beginning on February 23, 2017, even though

the judgment was not signed until March 8, 2017. The City contends that this was error. We agree

because postjudgment interest accrues from the judgment date through the date the judgment is

satisfied. Long, 426 S.W.3d at 77.

         In conclusion, we sustain the City’s sixth issue regarding the court’s erroneous award of

insurance costs, its erroneous award of costs for the installation of a gas line, and its award of

postjudgment interest based on an erroneous accrual date. We otherwise overrule the City’s sixth

issue.

                                           CONCLUSION

         The district court did not err in denying the City’s plea to the jurisdiction and in granting




                                                  –29–
White Rock’s motion for partial summary judgment. However, the court’s damages award was

erroneous in certain respects, as set forth above. We reverse in part and remand this cause to the

district court for the limited purpose of determining (i) the amount owed by the City after crediting

the $1.8 million paid by the Lancaster EDC, (ii) the amount of insurance costs and gas-line

installation costs, which we have held must be excluded from the court’s damages award, and

(ii) the recalculation of interest based on the revised damages award. We modify the judgment to

reflect that postjudgment interest shall accrue from March 8, 2017, the date of the judgment. We

otherwise affirm the judgment as modified.


                                                   /Jason Boatright/
                                                   JASON BOATRIGHT
                                                   JUSTICE



170583F.P05




                                               –30–
                                        S
                               Court of Appeals
                        Fifth District of Texas at Dallas
                                      JUDGMENT

 CITY OF LANCASTER, Appellant                       On Appeal from the 191st Judicial District
                                                    Court, Dallas County, Texas
 No. 05-17-00583-CV         V.                      Trial Court Cause No. DC-14-06471.
                                                    Opinion delivered by Justice Boatright.
 WHITE ROCK COMMERCIAL, LLC,                        Justices Bridges and Brown participating.
 Appellee

        In accordance with this Court’s opinion of this date, the judgment of the trial court is
AFFIRMED, as modified, in part and REVERSED and remanded, in part. We REVERSE the
trial court’s damages award and remand this case for the purpose of determining (i) the damages
owed by appellant after deducting the $1.8 million paid by the Lancaster Economic Development
Corporation; (ii) the amount of appellee’s insurance costs and gas-line installation costs to be
excluded from the damages award; and (ii) the calculation of prejudgment interest based on the
revised damages award. We modify the judgment to reflect that postjudgment interest shall
accrue from March 8, 2017, the date of the judgment. In all other respects, the trial court’s
judgment is AFFIRMED.

       It is ORDERED that each party bear its own costs of this appeal.

Judgment entered December 21, 2018.




                                             –31–
